Damages and Related Costs Sample Clauses

Damages and Related Costs. Any cost arising out of a breach of this Contract or the fault, failure or negligence of CM, its Subcontractors, or any person or entity for whom they may be liable. These costs include, without limitation: costs to remedy defective, rejected, or nonconforming work, materials or equipment; costs due to failure to coordinate the Work or meet CPM Schedule milestones; costs arising from CM’s contractual indemnification obligations; liquidated or actual damages imposed by Owner for failure to complete the Work within the Contract Time; costs due to the bankruptcy or insolvency of any Subcontractor; and damage or losses to persons or property.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Damages and Related Costs. Any cost arising out of a breach of this Contract or the fault, failure or negligence of Job Order Contractor, its Subcontractors, or any person or entity for whom they may be liable. These costs include, without limitation: costs to remedy defective, rejected, or nonconforming work, materials or equipment; costs due to failure to coordinate the Work or meet Critical Path schedule milestones; costs arising from Job Order Contractor’s contractual indemnification obligations; liquidated or actual damages imposed by the City for failure to complete the Work within the Contract Time; costs due to the bankruptcy or insolvency of any Subcontractor; and damage or losses to persons or property.
Sample 1Sample 2Sample 3See All (7)

Related to Damages and Related Costs

  • BID AND RELATED COSTS By submission of a bid, the Bidder agrees that any and all costs associated with the preparation of the bid will be the sole responsibility of the Bidder. The Bidder also agrees that the County shall bear no responsibility for any costs associated with the preparation of the bid including but not limited to any administrative or judicial proceedings resulting from the solicitation process.

  • Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11

  • Reimbursement of Attorneys’ Fees and Costs The Parties acknowledge that Xxxxxxx and his counsel offered to resolve this dispute without reaching terms on the amount of fees and costs to be reimbursed to them, thereby leaving the issue to be resolved after the material terms of the agreement had been settled.

  • Legal Fees and Costs In the event a party elects to incur legal expenses to enforce or interpret any provision of this Agreement by judicial proceedings, the prevailing party will be entitled to recover such legal expenses, including, without limitation, reasonable attorneys’ fees, costs, and necessary disbursements at all court levels, in addition to any other relief to which such party shall be entitled.

  • REIMBURSEMENT OF FEES AND COSTS The Parties acknowledge that Xxxxxxx and her counsel offered to reach preliminary agreement on the material terms of this dispute before reaching terms on the amount of fees and costs to be reimbursed to them. The Parties thereafter reached an accord on the compensation due to Xxxxxxx and her counsel under general contract principles and the private attorney general doctrine and principles codified at California Code of Civil Procedure § 1021.5, for all work performed through the mutual execution of this agreement. Under these legal principles, ABG shall reimburse Xxxxxxx’s counsel for fees and costs incurred as a result of investigating and bringing this matter to ABG’s attention, and negotiating a settlement in the public interest. Within ten (10) days of the Effective Date, ABG shall issue a check payable to “Xxxxxxx & Xxxxx” in the amount of $4,500.00 for delivery to the address identified in § 3.2(a)(i), above.

  • Attorneys’ Fees and Costs If any action at law or in equity is necessary to enforce or interpret the terms of this Agreement, the prevailing party shall be entitled to reasonable attorney's fees, costs and necessary disbursements in addition to any other relief to which he may be entitled.

  • Fees and Costs As part of the Appeal Panel Award, the Appeal Panel is hereby directed to require the losing party (the party being awarded the least amount of money by the arbitrator, which, for the avoidance of doubt, shall be determined without regard to any statutory fines, penalties, fees, or other charges awarded to any party) to (a) pay the full amount of any unpaid costs and fees of the Arbitration and the Appeal Panel, and (b) reimburse the prevailing party (the party being awarded the most amount of money by the Appeal Panel, which, for the avoidance of doubt, shall be determined without regard to any statutory fines, penalties, fees, or other charges awarded to any part) the reasonable attorneys’ fees, arbitrator and Appeal Panel costs and fees, deposition costs, other discovery costs, and other expenses, costs or fees paid or otherwise incurred by the prevailing party in connection with the Arbitration (including without limitation in connection with the Appeal).

  • A ttorney’s Fees If either Party commences an action against the other Party, either legal, administrative or otherwise, arising out of or in connection with this Agreement, the prevailing Party in such litigation shall be entitled to have and recover from the losing Party reasonable attorney’s fees and all other costs of such action.

  • Disbursements Payments and Costs 5.1 Request for Credit. Each request for an advance under the Line of Credit will be made by a disbursement request in a form acceptable to Bank executed by an Authorized Officer, or by any other means acceptable to Bank.

  • Costs and Attorneys’ Fees In the event that any action, suit or other proceeding is instituted concerning or arising out of this Agreement or any transaction contemplated hereunder, the prevailing party shall recover all of such party’s costs and attorneys’ fees incurred in each such action, suit or other proceeding, including any and all appeals or petitions therefrom.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!