Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.
TERMINATION OF EFT SERVICES You may terminate this Agreement or any EFT service under this Agreement at any time by notifying us in writing and stopping your use of your card and any access code. You must return all cards to the Credit Union. You also agree to notify any participating merchants that authority to make xxxx payment transfers has been revoked. We may also terminate this Agreement at any time by notifying you orally or in writing. If we terminate this Agreement, we may notify any participating merchants making preauthorized debits or credits to any of your accounts that this Agreement has been terminated and that we will not accept any further preauthorized transaction instructions. We may also program our computer not to accept your card or access code for any EFT service. Whether you or the Credit Union terminates this Agreement, the termination shall not affect your obligations under this Agreement for any electronic transactions made prior to termination.
Contractor Certification regarding Business with Certain Countries and Organizations Pursuant to Subchapter F, Chapter 2252, Texas Government Code], Contractor certifies Contractor is not engaged in business with Iran, Sudan, or a foreign terrorist organization. Contractor acknowledges this Agreement may be terminated and payment withheld if this certification is inaccurate.
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Termination of Services by the HSP (a) Except as provided in 12.2(b) and (c) below, the HSP may terminate this Agreement at any time, for any reason, upon giving the LHIN at least six months’ Notice.
Certification for Federal-Aid Contracts Lobbying Activities A. The CONSULTANT certifies, by signing and submitting this Contract, to the best of its knowledge and belief after diligent inquiry, and other than as disclosed in writing to the LPA prior to or contemporaneously with the execution and delivery of this Contract by the CONSULTANT, the CONSULTANT has complied with Section 1352, Title 31, U.S. Code, and specifically, that:
PERFORMING AGENCY RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Performing Agency shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Performing Agency. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Performing Agency’s failure to perform any Work in accordance with the terms of the Contract.
Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.
Termination for Cause by The District The District may immediately terminate this Agreement for cause for any of the following reasons:
CONTRACTOR RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.
