Delay Events Prior to Substantial Completion) Sample Clauses

Delay Events Prior to Substantial Completion). The Developer will not be entitled to relief from a Delay Event if such events (i) are within any Lead Developer Party’s or Developer Subcontractor’s control, (ii) are caused by any act, omission, negligence, recklessness, willful misconduct, breach of contract or law by any Lead Developer Party or Developer Subcontractor or (iii) (or the effects of such events) could have been avoided by the exercise of caution or due diligence in accordance with Good Industry Practice by any Lead Developer Party or Developer Subcontractor.
AutoNDA by SimpleDocs
Delay Events Prior to Substantial Completion). A Delay Event occurring prior to Substantial Completion of any Project Segment will excuse the Developer from performance of its obligations pursuant to this Development Agreement but only to the extent that such obligations are directly affected by such Delay Event. In addition, prior to a Project Segment’s Substantial Completion, extensions of milestones and/or activities identified on the Project Schedule for Delay Events affecting the Work with respect to such Project Segment will be made based on schedule impact analysis, using the then current Project Schedule for such Project Segment and taking into account impacts of the Delay Events on critical path items, in accordance with the Master Plan Requirements, and will extend, as applicable, milestone completion dates and the applicable Substantial Completion date. If the parties cannot agree upon the extension, then either party will be entitled to refer the matter to the dispute resolution procedures in Article 13 (Dispute Resolution Provisions) of this Development Agreement.

Related to Delay Events Prior to Substantial Completion)

  • Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.

  • At Substantial Completion and Final Completion the Contractor shall provide a certification letter certifying that the Work does not contain asbestos as required by the UTUGCs.

  • TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION (i) The work under this Contract shall commence within seven (7) calendar days of receipt of Notice to Proceed and will be substantially complete within thirty (80) calendar days after the date when the Contract Time commences to run as provided in paragraph 2.03 of the General Conditions and completed and ready for final payment within ninety (90) calendar days after the date when the Contract Time commences to run.

  • After Substantial Completion § 12.2.2.1 In addition to the Contractor’s obligations under Section 3.5, if, within one year after the date of Substantial Completion of the Work or designated portion thereof or after the date for commencement of warranties established under Section 9.9.1, or by terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Contractor and give the Contractor an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor and to make a claim for breach of warranty. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner or Architect, the Owner may correct it in accordance with Section 2.5.

  • Substantial Completion “Substantial Completion” means the stage in the progress of the Work when the Work, or designated portions thereof, may still require minor modifications or adjustments but, in the Owner’s opinion, the Work has progressed to the point such that all parts of the Work under consideration are fully operational and usable for intended purposes, as evidenced by a Certificate of Substantial Completion approved by the Owner. If a Certificate of Occupancy is required by public authorities having jurisdiction over the Work, said certificate shall be issued before the Work or any portion thereof is considered substantially complete. When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify Owner’s Designated Representative (sometimes referred to as the “ODR”) and request a determination as to whether the Work or designated portion thereof is substantially complete. If the ODR does not consider the Work substantially complete, the ODR will notify the Contractor giving reasons therefore. Failure on the Owner’s part to list a reason does not alter the responsibility of the Contractor to complete all Work in accordance with the terms of this Agreement. After satisfactorily completing items identified by Owner’s Designated Representative, the Contractor shall then submit another request for the ODR to determine Substantial Completion. If The ODR considers the Work substantially complete, The ODR will prepare and deliver a certificate of Substantial Completion which shall establish the date of Substantial Completion, shall include a punch list of items to be completed or corrected before final completion and final payment, shall establish the time within which the Contractor shall finish the punch list, and shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, warranty and insurance. Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the terms and conditions of this Agreement. The certificate of Substantial Completion shall be signed by the Owner and the Contractor to evidence acceptance of the responsibilities assigned to them in such certificate. Substantial Completion (as defined in this agreement) for all stages of the Work shall be achieved on or before the following Substantial Completion date: DATE FOR SUBSTANTIAL COMPLETION: TBD Under no circumstances will the time for Substantial Completion exceed this date without a written amendment to this Agreement. THE TIMES SET FORTH IN THE CONSTRUCTION DOCUMENTS ARE AN ESSENTIAL ELEMENT OF THE AGREEMENT. TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THIS AGREEMENT.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • Certificate of Substantial Completion The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the City when construction is sufficiently complete, in accordance with the Contract Documents, so the City of Roanoke, Virginia (City or Owner) can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. ITB NO.: PROJECT: CONTRACTOR: PROJECT OR DESIGNATED PORTION SHALL INCLUDE: . The Work or portion thereof designated above performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby established as . The City will assume possession thereof at a.m./p.m. on that date. A list of items ("punch list"), prepared by the A/E and/or Director, Department of Public Works, to be completed or corrected by the Contractor, is attached hereto. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The Contractor will complete any portion of the Work that is not substantially complete and will complete or correct the work on the punch list in accordance with the Contract Documents. The establishment of a date of substantial completion and/or the acceptance of the Work or designated portion thereof does not relieve the Contractor of any responsibility for any faulty materials or workmanship or operate to relieve the Contractor or its Surety from any obligation under the Contract with the City or the Performance Bond or Labor and Material Payment Bond. This Certificate is subject to the terms and conditions of the Contract Documents, including but not limited to Section 20.8 of the General Conditions. Contractor By Date City of Roanoke, Virginia City By Date CITY OF ROANOKE, VIRGINIA AFFIDAVIT OF PAYMENT OF CLAIMS By: (Insert Exact Name and Address of Firm) This day personally appeared before me, , a Notary Public in and for the City (County) of , and, being by me first duly sworn states that all subcontractors and suppliers of labor and materials have been paid all sums due them for work performed or materials furnished in the performance of the Contract between the City of Roanoke, Virginia, and ,Contractor, dated , 20 , for or arrangements have been made by the Contractor satisfactory to such subcontractors and suppliers with respect to the payment of such sums as may be due from the Contractor to the subcontractors and suppliers. CONTRACTOR: BY: PRINTED OR TYPED NAME AND TITLE: COMMONWEALTH OF VIRGINIA CITY/COUNTY OF I, , a Notary Public in and for the Commonwealth of Virginia, do hereby certify that , whose name is signed to the foregoing, has subscribed, sworn to and acknowledged the same before me this day of , 20 . Seal: Notary Public Registration #: My Commission Expires: CITY OF ROANOKE, VIRGINIA

  • Status Substantial Compliance Analysis The Compliance Officer found that PPB is in substantial compliance with Paragraph 80. See Sections IV and VII Report, p. 17. COCL carefully outlines the steps PPB has taken—and we, too, have observed—to do so. Id. We agree with the Compliance Officer’s assessment. In 2018, the Training Division provided an extensive, separate analysis of data concerning ECIT training. See Evaluation Report: 2018 Enhanced Crisis Intervention Training, Training usefulness, on-the-job applications, and reinforcing training objectives, February 2019. The Training Division assessed survey data showing broad officer support for the 2018 ECIT training. The survey data also showed a dramatic increase in the proportion of officers who strongly agree that their supervisors are very supportive of the ECIT program, reaching 64.3% in 2018, compared to only 14.3% in 2015: The Training Division analyzed the survey results of the police vehicle operator training and supervisory in-service training, as well. These analyses were helpful in understanding attendees’ impressions of training and its application to their jobs, though the analyses did not reach as far as the ECIT’s analysis of post-training on- the-job assessment. In all three training analyses, Training Division applied a feedback model to shape future training. This feedback loop was the intended purpose of Paragraph 80. PPB’s utilization of feedback shows PPB’s internalization of the remedy. We reviewed surveys of Advanced Academy attendees, as well. Attendees were overwhelmingly positive in response to the content of most classes. Though most respondents agreed on the positive aspects of keeping the selected course in the curriculum, a handful of attendees chose options like “redundant” and “slightly disagree,” indicating that the survey tools could be used for critical assessment and not merely PPB self-validation. We directly observed PPB training and evaluations since our last report. PPB provided training materials to the Compliance Officer and DOJ in advance of training. Where either identified issues, PPB worked through those issues and honed its materials. As Paragraph 80 requires, PPB’s training included competency-based evaluations, namely: knowledge checks (i.e., quizzes on directives), in-class responsive quizzes (using clickers to respond to questions presented to the group); knowledge tests (examinations via links PPB sent to each student’s Bureau-issued iPhone); demonstrated skills and oral examination (officers had to show proficiency in first aid skills, weapons use, and defensive tactics); and scenario evaluations (officers had to explain their reasoning for choices after acting through scenarios). These were the same sort of competency-based evaluations we commended in our last report. In this monitoring period, PPB applied the same type of evaluations to supervisory-level training as well as in-service training for all sworn members. PPB successfully has used the surveys, testing, and the training audit.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ « » ] The date of this Agreement. [ « » ] A date set forth in a notice to proceed issued by the Owner. [ « » ] Established as follows: (Insert a date or a means to determine the date of commencement of the Work.) « » If a date of commencement of the Work is not selected, then the date of commencement shall be the date of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!