Mobilization Design-Builder shall mobilize, transport and assemble its equipment, materials, and supplies, as well as construct such temporary systems as are necessary and required at the Site, all in adequate time for satisfactory performance of the Work.
Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.
CLEC OUTAGE For a problem limited to one CLEC (or a building with multiple CLECs), BellSouth has several options available for restoring service quickly. For those CLECs that have agreements with other CLECs, BellSouth can immediately start directing traffic to a provisional CLEC for completion. This alternative is dependent upon BellSouth having concurrence from the affected CLECs. Whether or not the affected CLECs have requested a traffic transfer to another CLEC will not impact BellSouth's resolve to re-establish traffic to the original destination as quickly as possible.
Post-Stabilization Services The PH-MCO must cover Post-Stabilization Services, as defined in 42 C.F.R. §438.114. The PH-MCO must limit charges to Members for Post-Stabilization Services to an amount no greater than what the PH-MCO would charge the Member if he or she had obtained the services through a Network Provider. The PH-MCO must cover Post-Stabilization Services without authorization, and regardless of whether the Member obtains the services within or outside its Provider Network if any of the following situations exist:
Deployment (a) In filling a position vacancy at a location NAV CANADA may proceed by the transfer of an employee at the same level.
Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
Building Commissioning Services The Owner may provide as a part of its testing services the Building Commissioning services involving the project’s HVAC and exhaust systems, temperature control systems, fire detection and alarm systems, emergency power and lighting system, fire suppression system, security locks and security locking control systems, food service equipment (if applicable), and laundry equipment (if applicable). In the event the Using Agency’s Program specifies additional commissioning services, the Owner shall procure such services as well. The Owner, through its Executive Administrator, may engage an independent Commissioning Authority. It is the intent of this Article that the Commissioning Authority enforce the requirements mentioned herein and certify that the systems and equipment listed all function properly prior to the initiation of each final inspection.
Utilization Scale STATE shall scale logs or portions of logs that are broken, wasted, or not removed by PURCHASER due to: (1) improper felling or bucking of the logs; (2) failure to remove the logs prior to deterioration; and (3) logs remaining on the timber sale area after completion of logging, provided the logs were merchantable prior to breakage or wastage. Material used to meet down material requirements in the section titled, "Reserved Timber," shall not be considered for utilization scale. PURCHASER shall pay for the logs at the contract price designated in Section 44. STATE shall notify PURCHASER of the volume of logs so scaled. Payment shall be considered due on such volume as if the logs were removed on the date of said notification. In the event PURCHASER disagrees with the findings made by STATE under this section, PURCHASER may furnish scaling by a third-party scaling organization acceptable to STATE. Costs and expenses of such third party shall be paid for by PURCHASER, and the findings of the third party shall be final.
Cyber incident damage assessment activities If DoD elects to conduct a damage assessment, the Contracting Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.
