Delivery of Possession Landlord shall be deemed to have delivered possession of the Premises to Tenant on the Commencement Date, as it may be adjusted pursuant to the Workletter. Landlord shall construct or install in the Premises the improvements to be constructed or installed by Landlord according to the Workletter. If no Workletter is attached to this Lease, it shall be deemed that Landlord delivered to Tenant possession of the Premises "as is" in its present condition on the Commencement Date. Tenant acknowledges that neither Landlord nor its agents or employees have made any representations or warranties as to the suitability or fitness of the Premises for the conduct of Tenant's business or for any other purpose, nor has Landlord or its agents or employees agreed to undertake any alterations or construct any Tenant improvements to the Premises except as expressly provided in this Lease and the Workletter. If for any reason Landlord cannot deliver possession of the Premises to Tenant on the Commencement Date, this Lease will not be void or voidable, Landlord will not be liable to Tenant for any resulting loss or damage and the Term of this Lease shall not be extended by a delayed delivery of possession. The preceding sentence notwithstanding, if Landlord fails to deliver possession to Tenant within sixty (60) days after the Commencement Date for any reason other than a Delay Caused by Tenant, as defined in the Workletter, Tenant, as its sole remedy, shall have the right to terminate this Lease and receive a refund of all prepaid Rent and Security Deposits provided Tenant gives written notice of termination to Landlord within three (3) days after that date. Tenant will execute the Commencement Date Certificate attached to this Lease as Exhibit E, appropriately completed, within fifteen (15) days of Landlord's request.
NON-DELIVERY OF POSSESSION In the event Landlord cannot deliver possession of the Premises to Tenant upon the commencement of the Lease term, through no fault of Landlord or its agents, then Landlord or its agents shall have no liability, but the rental herein provided shall xxxxx until possession is given. Landlord or its agents shall have thirty (30) days in which to give possession, and if possession is tendered within such time, Tenant agrees to accept the demised Premises and pay the rental herein provided from that date. In the event possession cannot be delivered within such time, through no fault of Landlord or its agents, then this Agreement and all rights hereunder shall terminate.
DELIVERY OF PREMISES If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.
Delivery of Equipment (a) We will try to deliver Equipment to you on the delivery date (Delivery Date) and at the address (Site) indicated on your Application during normal business hours in that area.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
Delivery of Software 1. SAP will deliver the Software as described in the Documentation and the Price List and will also provide the appropriate license keys. With regard to the features, quality and functionality of the Software the product description in the Documentation and the Price List is solely decisive. SAP does not own any additional features, quality or functionality. Partner can, in particular, not assert any additional feature, quality or functionality from any public statements, publications or advertisements by SAP except to the extend SAP has expressly confirmed such additional feature, quality or functionality in writing. Any representation, warranty, undertaking or guarantee regarding additional features, quality or functionality is effective only if expressly confirmed by SAP’s management in writing.
DEEMED POSSESSION It is understood by the Allottee that even if the Allottee fails to take possession of the Apartment within the date such possession is offered by the Promoter, the Allottee shall be deemed to have taken possession on the 15 days from the date of such notice which date, for all purposes and irrespective of the actual date when the Allottee takes physical possession of the Apartment, will be deemed to be the possession date (“Possession Date”). On and from the Possession Date:
Surrender of Possession Immediately prior to the expiration or upon the sooner termination of this Lease, Tenant shall remove all of Tenant’s signs from the exterior of the Building and shall remove all of Tenant’s equipment, trade fixtures, furniture, supplies, wall decorations and other personal property from the Leased Premises, and shall vacate and surrender the Leased Premises to Landlord in the same condition, broom clean, as existed at the Lease Commencement Date. Tenant shall repair all damage to the Leased Premises caused by Tenant or by Tenant’s removal of Tenant’s property and all damage to the exterior of the Building caused by Tenant’s removal of Tenant’s signs. Tenant shall patch and refinish, to Landlord’s reasonable satisfaction, all penetrations made by Tenant or its employees to the floor, walls or ceiling of the Leased Premises, whether such penetrations were made with Landlord’s approval or not. Tenant shall clean, repair or replace all stained or damaged ceiling tiles, wall coverings and clean or replace as may be required floor coverings to the reasonable satisfaction of Landlord. Tenant shall replace all burned out light bulbs and damaged light lenses, and clean and repaint all painted walls. Tenant shall repair all damage caused by Tenant to the exterior surface of the Building and the paved surfaces of the outside areas adjoining the Leased Premises and, where necessary, replace or resurface same. Additionally, Tenant shall, prior to the expiration or sooner termination of this Lease, remove any improvements installed by Tenant (other than the initial tenant improvements install pursuant to Exhibit F) and repair all damage caused by such removal, unless Landlord, at the time it consented to such improvements waived the right to require such removal. If the Leased Premises are not surrendered to Landlord in the condition required by this Article at the expiration or sooner termination of this Lease, Landlord may, at Tenant’s expense, so remove Tenant’s signs, property and/or improvements not so removed and make such repairs and replacements not so made or hire, at Tenant’s expense, independent contractors to perform such work. Tenant shall be liable to Landlord for all costs incurred by Landlord in returning the Leased Premises to the required condition, plus interest on all costs incurred from the date paid by Landlord at the then maximum rate of interest not prohibited by Law until paid, payable by Tenant to Landlord within ten days after receipt of a statement therefore from Landlord, and Tenant shall be deemed to have impermissibly held over until such time as such required work is completed, and Tenant shall pay Base Monthly Rent and Additional Rent in accordance with the terms of Section 13.2 (Holding Over) until such work is completed. Tenant shall indemnify Landlord against loss or liability resulting from delay by Tenant in so surrendering the Leased Premises, including, without limitation, any claims made by any succeeding tenant or any losses to Landlord due to lost opportunities to lease to succeeding tenants.
RIGHT OF ENTRY AND INSPECTION OWNER may enter, inspect, and/or repair the premises at any time in case of emergency or suspected abandonment. OWNER shall give 24 hours advance notice and may enter for the purpose of showing the premises during normal business hours to prospective renters, buyers, lenders, for smoke alarm inspections, and/or for normal inspections and repairs. OWNER is permitted to make all alterations, repairs and maintenance that in OWNER'S judgment is necessary to perform.
INSPECTION OF PREMISES Landlord and Landlord's agents shall have the right at all reasonable times during the term of this Agreement and any renewal thereof to enter the Premises for the purpose of inspecting the Premises and all buildings and improvements thereon. And for the purposes of making any repairs, additions or alterations as may be deemed appropriate by Landlord for the preservation of the Premises or the building. Landlord and its agents shall further have the right to exhibit the Premises and to display the usual "for sale", "for rent" or "vacancy" signs on the Premises at any time within forty-five (45) days before the expiration of this Lease. The right of entry shall likewise exist for the purpose of removing placards, signs, fixtures, alterations or additions, that do not conform to this Agreement or to any restrictions, rules or regulations affecting the Premises.
