Department Review and Comment Sample Clauses

Department Review and Comment. Whenever the Contract Documents indicate that a Submittal or other matter is subject to the Department’s review and comment and the Department delivers no comments, exceptions, objections, or rejections within the applicable time period under the Contract Documents, then Developer may proceed thereafter at its election and risk, without prejudice to the Department’s rights to later object or disapprove the Submittal on the basis that such Submittal is not in accordance with the requirements of the Contract Documents. No such failure or delay by the Department to object to or disapprove Work not in compliance with the Contract Documents within the applicable time period under the Contract Documents shall constitute a basis for any claim for Extra Work Costs, Delay Costs, time extensions or other relief.
Sample 1Sample 2
AutoNDA by SimpleDocs
Department Review and Comment. ‌ 1. No such failure or delay by the Department to object to, disapprove or reject a Submittal or other matter not in compliance with the Contract Documents within the applicable time period under the Contract Documents shall constitute a basis for any claim for Extra Work Costs, Delay Costs, time, Financial Close Deadline or Completion Deadline extensions, compensation for losses due to delays in commencement of Availability Payments or for additional interest costs due to delayed receipt of the Milestone Payment, or other relief.
Sample 1Sample 2
Department Review and Comment. Whenever the Contract Documents indicate that a Submittal or other matter is subject to the Department’s review and comment and the Department delivers no comments, exceptions, objections, disapprovals or rejections within the applicable time period under the Contract Documents, then Developer may proceed thereafter at its election and risk, without prejudice to the Department’s rights to later object to, disapprove or reject the Submittal or other matter on the bases set forth in Section 3.3.6. 1. No such failure or delay by the Department to object to, disapprove or reject a Submittal or other matter not in compliance with the Contract Documents within the applicable time period under the Contract Documents shall constitute a basis for any claim for Extra Work Costs, Delay Costs, time, Financial Close Deadline or Completion Deadline extensions, compensation for losses due to delays in commencement of Availability Payments or for additional interest costs due to delayed receipt of the Milestone Payment, or other relief.
Sample 1

Related to Department Review and Comment

  • Review Scope The parties confirm that the Asset Representations Review is not responsible for (a) reviewing the Receivables for compliance with the representations and warranties under the Transaction Documents, except as described in this Agreement or (b) determining whether noncompliance with the representations and warranties constitutes a breach of the Eligibility Representations. For the avoidance of doubt, the parties confirm that the review is not designed to determine why an Obligor is delinquent or the creditworthiness of the Obligor, either at the time of any Asset Review or at the time of origination of the related Receivable. Further, the Asset Review is not designed to establish cause, materiality or recourse for any Test Fail (as defined in Section 3.05).

  • Review Protocol A narrative description of how the Claims Review was conducted and what was evaluated.

  • Agreement Review If, pursuant to section 25.10 (Review of Agreement) of the Bilateral Agreement, the Bilateral Agreement is reviewed after three or five years, or both, of the effective date of the Bilateral Agreement, and any changes to the Bilateral Agreement are required as a result, the Parties agree to amend the Agreement as necessary and in a manner that is consistent with such changes.

  • AUDIT REVIEW PROCEDURES Any dispute concerning a question of fact arising under an interim or post audit of this AGREEMENT that is not disposed of by agreement, shall be reviewed by ALAMEDA CTC’s Deputy Executive Director of Finance and Administration. Not later than thirty (30) calendar days after issuance of the final audit report, CONSULTANT may request a review by ALAMEDA CTC’s Deputy Executive Director of Finance and Administration of unresolved audit issues. The request for review will be submitted in writing. Neither the pendency of a dispute nor its consideration by ALAMEDA CTC will excuse CONSULTANT from full and timely performance, in accordance with the terms of this AGREEMENT. CONSULTANT and subconsultants’ contracts, including cost proposals and ICRs, may be subject to audits or reviews such as, but not limited to, an AGREEMENT Audit, an Incurred Cost Audit, an ICR Audit, or a certified public accountant (“CPA”) ICR Audit Workpaper Review. If selected for audit or review, the AGREEMENT, cost proposal and ICR and related workpapers, if applicable, will be reviewed to verify compliance with 48 CFR, Chapter 1, Part 31 and other related laws and regulations. In the instances of a CPA ICR Audit Workpaper Review it is CONSULTANT’s responsibility to ensure federal, state, or local government officials are allowed full access to the CPA’s workpapers including making copies as necessary. The AGREEMENT, cost proposal, and ICR shall be adjusted by CONSULTANT and approved by ALAMEDA CTC to conform to the audit or review recommendations. CONSULTANT agrees that individual terms of costs identified in the audit report shall be incorporated into the contract by this reference if directed by ALAMEDA CTC at its sole discretion. Refusal by CONSULTANT to incorporate audit or review recommendations, or to ensure that the federal, state, or local governments have access to CPA workpapers, will be considered a breach of contract terms and cause for termination of the AGREEMENT and disallowance of prior reimbursed costs.

  • Review and Appeal 1. Each Party shall ensure that the importers in its territory have access to administrative review within the customs administration that issued the decision subject to review or, where applicable, the higher authority supervising the administration and/or judicial review of the determination taken at the final level of administrative review, in accordance with the Party's domestic law. 2. The decision on appeal shall be given to the appellant and the reasons for such decision shall be provided in writing. 3. The level of administrative review may include any authority supervising the customs administration of a Party.

  • Project Review A. Programmatic Allowances 1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification. 2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination. 3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review. 4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments. B. Expedited Review for Emergency Undertakings

  • Review and Approval The Supplier confirms and agrees that it shall apply to receive ISR's written consent, wherever ISR's consent, explicitly or implied, is required according to this Agreement. This requirement and the provision of ISR consent, shall not derogate in any way from Supplier's responsibilities and liabilities under this Agreement, and ISR shall bear no responsibility or liability whatsoever in connection with the review (whether or not there are objections) and/or with any approval given to, or denied from, Supplier, with respect to any matter and/or document, including but without limitation, drawings, designs (at all phases), plans, tests or otherwise.

  • Log Reviews All systems processing and/or storing PHI COUNTY discloses to 11 CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY 12 must have a routine procedure in place to review system logs for unauthorized access.

  • Commercialization Reports Throughout the term of this Agreement and during the Sell-Off Period, and within thirty (30) days of December 31st of each year, Company will deliver to University written reports of Company’s and Sublicensees’ efforts and plans to develop and commercialize the innovations covered by the Licensed Rights and to make and sell Licensed Products. Company will have no obligation to prepare commercialization reports in years where (a) Company delivers to University a written Sales Report with active sales, and (b) Company has fulfilled all Performance Milestones. In relation to each of the Performance Milestones each commercialization report will include sufficient information to demonstrate achievement of those Performance Milestones and will set out timeframes and plans for achieving those Performance Milestones which have not yet been met.

  • Claims Review Population A description of the Population subject to the Claims Review.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!