Financial Close Deadline definition

Financial Close Deadline means the deadline set forth in Section 13.7.2 of the PPA.
Sample 1Sample 2Sample 3
Financial Close Deadline means the date by which Financial Close must occur, which is the first to occur of (a) 270 days following the date on which Concessionaire has submitted an application to USDOT to obtain financing under any credit assistance program under TIFIA for the Project, or (b) 270 days following the date on which USDOT provides written notice to Concessionaire that the Project will not receive financing under any credit assistance program under XXXXX for the Project.
Sample 1Sample 2
Financial Close Deadline means November 30, 2015, as such deadline may be extended pursuant to Section 3.3.1.
Sample 1

Examples of Financial Close Deadline in a sentence

  • In the event Financial Close is not achieved by the Financial Close Deadline, either party may terminate this Agreement pursuant to Section 20.04.

  • The SIB Loan will not bear interest, but will be repaid in full by the Developer on or before the Financial Close Date or as required by the terms of Section 20.04 if this Agreement is terminated for failure to reach Financial Close by the Financial Close Deadline.

  • Subject to the termination rights of each party pursuant to Section 20.04, the Department and the Developer each agree to: (i) use reasonable commercial efforts to satisfy the conditions within their control to reach Financial Close on or prior to the Financial Close Deadline; and (ii) use reasonable commercial efforts to cooperate and assist the other party to reach Financial Close by the Financial Close Deadline.

  • Project Schedule Deadline means one or more of the NTP1 Conditions Deadline, Financial Close Deadline, NTP2 Conditions Deadline, Baseline Substantial Completion Date, Final Acceptance Deadline and Long Stop Date, as the case may be.

  • The Developer’s debt that it will borrow to contribute to the Project construction costs will be comprised of private activity bonds ($141 million) and a TIFIA loan ($404 million) from the Build America Bureau, part of the U.S. Department of Transportation.The Developer is obligated to achieve Financial Close of the Project by the Financial Close Deadline of January 28, 2018, subject to relief for a limited number of events outside of the Developer’s control.

  • According to (Tony et al., 2017) such effects are conflict determinants that can result in social tension and even violent conflict within the community or between the community and the mining company or government (IIED, 2002).In that case, governments, civil society groups, and some investors and mining companies increasingly recognize that mining should not leave affected communities worse off than they were before mining started.

  • Developer shall be required to achieve financial close on or before the Financial Close Deadline as set forth in the Agreement.

  • If approval is subject to the sole or absolute discretion of the Department, then its decision shall be final, binding and not subject to dispute resolution, and such decision shall not constitute a basis for any claim for Extra Work Costs, Delay Costs, time, Financial Close Deadline or Completion Deadline extensions, compensation for losses due to delays in commencement of Availability Payments or for additional interest costs due to delayed receipt of the Milestone Payment, or other relief.

  • The schedule milestones shall be consistent with all completion deadlines and shall allow Developer sufficient time to reach Financial Close by the Financial Close Deadline.

  • The schedule milestones shall be consistent with all completion deadlines and shall allow Developer ample time to reach Financial Close by the Financial Close Deadline.


More Definitions of Financial Close Deadline

Financial Close Deadline has the meaning set forth in Section 5.2 (Financial Close Deadline).
Sample 1
Financial Close Deadline is the date that is the later of (i) 60 days following the Effective Date and (ii) 180 days from the Financial Proposal Due Date. If, however:
Sample 1
Financial Close Deadline means the date that is 180 Days after the Signing Date16 December 2019; «Ֆինանսավորման Ամփոփման Վերջնաժամկետ» նշանակում է Ստորագրման Ամսաթվից 180 Օր անց ընկնող ամսաթիվը.2019 թվականի դեկտեմբերի 16-ը․
Sample 1
Financial Close Deadline means 16 December 2019; «Ֆինանսավորման Ամփոփման Վերջնաժամկետ» նշանակում է 2019 թվականի դեկտեմբերի 16-ը․
Sample 1
Financial Close Deadline means the date by which Financial Close must occur, which is 210 Days following the Agreement Date, which date may be extended according to the procedures set forth in Section 7.06(c).
Sample 1

Related to Financial Close Deadline

  • Financial Close means the Capacity Market Seller has demonstrated that the Capacity Market Seller or its agent has completed the act of executing the material contracts and/or other documents necessary to (1) authorize construction of the project and (2) establish the necessary funding for the project under the control of an independent third-party entity. A sworn, notarized certification of an independent engineer certifying to such facts, and that the engineer has personal knowledge of, or has engaged in a diligent inquiry to determine, such facts, shall be sufficient to make such demonstration. For resources that do not have external financing, Financial Close shall mean the project has full funding available, and that the project has been duly authorized to proceed with full construction of the material portions of the project by the appropriate governing body of the company funding such project. A sworn, notarized certification by an officer of such company certifying to such facts, and that the officer has personal knowledge of, or has engaged in a diligent inquiry to determine, such facts, shall be sufficient to make such demonstration.

  • Original Closing Date means the "Closing Date" as defined in the Existing Credit Agreement.

  • Opt-Out Deadline means the deadline set by the Court for the timely submission of requests by Settlement Class Members to be excluded from the Settlement Class.

  • Closing Day means (a) the Restatement Date and (b) with respect to any Accepted Note, the Business Day specified for the closing of the purchase and sale of such Accepted Note in the Confirmation of Acceptance for such Accepted Note, provided that (i) if the Company and the Purchaser which is obligated to purchase such Accepted Note agree on an earlier Business Day for such closing, the “Closing Day” for such Accepted Note shall be such earlier Business Day, and (ii) if the closing of the purchase and sale of such Accepted Note is rescheduled pursuant to Section 3.2, the Closing Day for such Accepted Note, for all purposes of this Agreement except references to “original Closing Day” in Section 2.7(b), shall mean the Rescheduled Closing Day with respect to such Accepted Note.