Trunk Group Architecture and Traffic Routing 5.2.1 The Parties shall jointly establish Access Toll Connecting Trunks between CLEC and CBT by which they will jointly provide Tandem-transported Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic from and to CLEC's Customers. 5.2.2 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access and non-translated Toll Free traffic (e.g., 800/888) to allow CLEC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier that is connected to the CBT access Tandem. 5.2.3 The Access Toll Connecting Trunks shall be one-way or two-way trunks, as mutually agreed, connecting an End Office Switch that CLEC utilizes to provide Telephone Exchange Service and Switched Exchange Access Service in the given LATA to an access Tandem Switch CBT utilizes to provide Exchange Access in the LATA.
Furniture and Equipment The Tenant shall ensure that furniture, equipment and fixtures being moved into or out of the Leased Premises are moved through such entrances, elevators and corridors and at such times as may from time to time be designated by the Landlord and shall promptly pay or cause to be paid to the Landlord the cost of repairing any damage in the Building caused thereby.
Furniture and Equipment and Certain Other Equipment The Receiver hereby grants to the Assuming Bank an option to purchase all Furniture and Equipment or any telecommunications, data processing equipment (including hardware and software) and check processing and similar operating equipment owned by the Failed Bank at Fair Market Value and located at any leased Bank Premises that the Assuming Bank elects to vacate or which it could have, but did not occupy, pursuant to this Section 4.6; provided, that, the Assuming Bank shall give the Receiver notice of its election to purchase such property at the time it gives notice of its intention to vacate such Bank Premises or within ten (10) days after Bank Closing for Bank Premises it could have, but did not, occupy.
Nature and Purpose of Processing The Parties will Process Shared Personal Data only as necessary to perform under and pursuant to the Applicable Agreements, and subject to this Data Processing Addendum, including as further instructed by Data Subjects.
Disclosure and Use Restrictions Executive agrees and covenants: (i) to treat all Confidential Information as strictly confidential; (ii) not to directly or indirectly disclose, publish, communicate, or make available Confidential Information, or allow it to be disclosed, published, communicated, or made available, in whole or part, to any entity or person whatsoever (including other employees of the Company) not having a need to know and authority to know and use the Confidential Information in connection with the business of the Company and, in any event, not to anyone outside of the direct employ of the Company except as required in the performance of Executive’s authorized employment duties to the Company or with the prior consent of the Board acting on behalf of the Company in each instance (and then, such disclosure shall be made only within the limits and to the extent of such duties or consent); and (iii) not to access or use any Confidential Information, and not to copy any documents, records, files, media, or other resources containing any Confidential Information, or remove any such documents, records, files, media, or other resources from the premises or control of the Company, except as required in the performance of Executive’s authorized employment duties to the Company or with the prior consent of the Board acting on behalf of the Company in each instance (and then, such disclosure shall be made only within the limits and to the extent of such duties or consent). Nothing herein shall be construed to prevent disclosure of Confidential Information as may be required by applicable law or regulation, or pursuant to the valid order of a court of competent jurisdiction or an authorized government agency, provided that the disclosure does not exceed the extent of disclosure required by such law, regulation, or order. Executive shall promptly provide written notice of any such order to the Board.
Disclosure and Use 20.2.1 Each Receiving Party agrees that, from and after the Effective Date: (a) all such Proprietary Information communicated or discovered, whether before, on or after the Effective Date, in connection with this Agreement shall be held in confidence to the same extent as such Receiving Party holds its own confidential information; provided, that such Receiving Party shall not use less than a reasonable standard of care in maintaining the confidentiality of such information; (b) it will not, and it will not permit any of its employees, contractors, consultants, agents or affiliates to disclose such Proprietary Information to any other third person; (c) it will disclose Proprietary Information only to those of its employees, contractors, consultants, agents and affiliates who have a need for it in connection with the use or provision of services required to fulfill this Agreement; (d) it will, and will cause each of its employees, contractors, consultants, agents and affiliates to use such Proprietary Information only to effectuate the terms and conditions of this Agreement and for no other purpose; (e) it will cause each of its affiliates to execute individual confidentiality agreements containing the same restrictions as this Article XX; and (f) it will, and will cause each of its employees, contractors, consultants, agents and affiliates, to use such Proprietary Information to create only that Derivative Information necessary for such Receiving Party's compliance with Applicable Law or its performance under the terms of this Agreement. 20.2.2 Any Receiving Party so disclosing Proprietary Information to its employees, contractors, consultants, agents or affiliates shall be responsible for any breach of this Agreement by any of its employees, contractors, consultants, agents or affiliates and such Receiving Party agrees to use its reasonable efforts to restrain its employees, contractors, consultants, agents or affiliates from any prohibited or unauthorized disclosure or use of the Proprietary Information and to assist the Disclosing Party in its efforts to protect such information from disclosure. Each Receiving Party making such disclosure shall notify the Disclosing Party as soon as possible if it has knowledge of a breach of this Agreement in any material respect. 20.2.3 Proprietary Information shall not be reproduced by any Receiving Party in any form except to the extent (i) necessary to comply with the provisions of Section 20.3 and (ii) reasonably necessary to perform its obligations under this Agreement. All such reproductions shall bear the same copyright and proprietary rights notices as are contained in or on the original.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.