Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Management of REO Property (a) Prior to the acquisition by it of title to a Mortgaged Property (other than a Mortgaged Property that secures an Outside Serviced Loan Combination), the Special Servicer shall review the operation of such Mortgaged Property and determine the nature of the income that would be derived from such property if it were acquired by the Trust Fund. If the Special Servicer determines from such review that:
(i) None of the income from Directly Operating such Mortgaged Property would be subject to tax as "net income from foreclosure property" within the meaning of the REMIC Provisions or would be subject to the tax imposed on "prohibited transactions" under Section 860F of the Code (either such tax referred to herein as an "REO Tax"), then such Mortgaged Property may be Directly Operated by the Special Servicer as REO Property;
(ii) Directly Operating such Mortgaged Property as REO Property could result in income from such property that would be subject to an REO Tax, but that a lease of such property to another party to operate such property, or the performance of some services by an Independent Contractor with respect to such property, or another method of operating such property would not result in income subject to an REO Tax, then the Special Servicer may (provided that in the good faith and reasonable judgment of the Special Servicer, it is commercially reasonable) acquire such Mortgaged Property as REO Property and so lease or operate such REO Property; or
(iii) It is reasonable to believe that Directly Operating such property as REO Property could result in income subject to an REO Tax and that no commercially reasonable means exists to operate such property as REO Property without the Trust Fund incurring or possibly incurring an REO Tax on income from such property, the Special Servicer shall deliver to the Tax Administrator, in writing, a proposed plan (the "Proposed Plan") to manage such property as REO Property. Such plan shall include potential sources of income, and, to the extent reasonably possible, estimates of the amount of income from each such source. Upon request of the Special Servicer, the Tax Administrator shall advise the Special Servicer of the Tax Administrator's federal income tax reporting position with respect to the various sources of income that the Trust Fund would derive under the Proposed Plan. After receiving the information described in the preceding sentence from the Tax Administrator, the Special Servicer shall implement the Proposed Plan (after acquiring the respective Mortgaged Property as REO Property), with any amendments required to be made thereto as a result of the Tax Administrator's tax reporting position. The Special Servicer's decision as to how each Administered REO Property shall be managed and operated shall be based on the Servicing Standard and, further, based on the good faith and reasonable judgment of the Special Servicer as to which means would be in the best interest of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)), as a collective whole, by maximizing (to the extent commercially reasonable and consistent with Section 3.17(b)) the net after-tax REO Revenues received with respect to such property without materially impairing the Special Servicer's ability to promptly sell such property for a fair price. In connection with performing their respective duties under this Section 3.17(a), both the Special Servicer and the Tax Administrator may consult with counsel and tax accountants, the reasonable cost of which consultation shall be covered by, and be reimbursable as, a Servicing Advance to be made by the Special Servicer.
(b) If title to any Administered REO Property is acquired, the Special Servicer shall manage, conserve, protect and operate such REO Property for the benefit of the Certificateholders (and, in the case of any Administered REO Property related to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) solely for the purpose of its prompt disposition and sale in a manner that does not and will not: (i) cause such REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code; or (ii) except as contemplated by Section 3.17(a), either result in the receipt by any REMIC Pool of any "income from non-permitted assets" within the meaning of Section 860F(a)(2)(B) of the Code or result in an Adverse REMIC Event or an Adverse Grantor Trust Event. Subject to the foregoing, however, the Special Servicer shall have full power and authority to do any and all things in connection therewith as are consistent with the Servicing Standard and, consistent therewith, shall withdraw from the related REO Account, to the extent of amounts on deposit therein with respect to any Administered REO Property, funds necessary for the proper operation, management, maintenance and disposition of such REO Property, including:
(i) all insurance premiums due and payable in respect of such REO Property;
(ii) all real estate taxes and assessments in respect of such REO Property that may result in the imposition of a lien thereon;
(iii) any ground rents in respect of such REO Property; and
(iv) all costs and expenses necessary to maintain, lease, sell, protect, manage, operate and restore such REO Property. To the extent that amounts on deposit in the related REO Account in respect of any Administered REO Property are insufficient for the purposes set forth in the preceding sentence with respect to such REO Property, the Master Servicer shall, at the direction of the Special Servicer, make Servicing Advances in such amounts as are necessary for such purposes unless the Master Servicer determines, in accordance with the Servicing Standard, that such payment would be a Nonrecoverable Advance; provided, however, that the Master Servicer may make any such Servicing Advance without regard to recoverability if it is a necessary fee or expense incurred in connection with the defense or prosecution of legal proceedings.
(c) Without limiting the generality of the foregoing, the Special Servicer shall not, with respect to any Administered REO Property:
(i) enter into, renew or extend any New Lease with respect to such Administered REO Property, if the New Lease, by its terms would give rise to any income that does not constitute Rents from Real Property;
(ii) permit any amount to be received or accrued under any New Lease other than amounts that will constitute Rents from Real Property;
(iii) authorize or permit any construction on such Administered REO Property, other than the completion of a building or other improvement thereon, and then only if more than 10% of the construction of such building or other improvement was completed before default on the related Serviced Mortgage Loan became imminent, all within the meaning of Section 856(e)(4)(B) of the Code; or
(iv) Directly Operate, or allow any other Person, other than an Independent Contractor, to Directly Operate such Administered REO Property on any date more than 90 days after the related REO Acquisition; unless, in any such case, the Special Servicer has obtained an Opinion of Counsel (the cost of which shall be paid by the Master Servicer, at the direction of the Special Servicer, and shall be reimbursable as a Servicing Advance) to the effect that such action would not cause such Administered REO Property to fail to qualify as "foreclosure property" within the meaning of Section 860G(a)(8) of the Code for purposes of Section 860D(a) of the Code at any time that it is held by a REMIC Pool, in which case the Special Servicer may take such actions as are specified in such Opinion of Counsel.
(d) The Special Servicer may contract with any Independent Contractor for the operation and management of any Administered REO Property; provided that:
(i) the terms and conditions of any such contract shall not be inconsistent herewith and shall reflect an agreement reached at arm's length;
(ii) the fees of such Independent Contractor (which shall be expenses of the Trust Fund and, in the case of any Administered REO Property that relates to a Serviced Loan Combination, the related Serviced Non-Trust Mortgage Loan Noteholder(s)) shall be reasonable and customary in consideration of the nature and locality of such Administered REO Property;
(iii) except as permitted under Section 3.17(a), any such contract shall require, or shall be administered to require, that the Independent Contractor, in a timely manner, (A) pay out of related REO Revenues all costs and expenses incurred in connection with the operation and management of such Administered REO Property, including those listed in Section 3.17(b) above, and (B) except to the extent that such revenues are derived from any services rendered by the Independent Contractor to tenants of such Administered REO Property that are not customarily furnished or rendered in connection with the rental of real property (within the meaning of Section 1.856-4(b)(5) of the Treasury regulations or any successor provision), remit all related revenues collected (net of its fees and such costs and expenses) to the Special Servicer upon receipt;
(iv) none of the provisions of this Section 3.17(d) relating to any such contract or to actions taken through any such Independent Contractor shall be deemed to relieve the Special Servicer of any of its duties and obligations hereunder with respect to the operation and management of such Administered REO Property; and
(v) the Special Servicer shall be obligated with respect thereto to the same extent as if it alone were performing all duties and obligations in connection with the operation and management of such Administered REO Property. The Special Servicer shall be entitled to enter into any agreement with any Independent Contractor performing services for it related to its duties and obligations under Section 3.16 and this Section 3.17 for indemnification of the Special Servicer by any such Independent Contractor, and nothing in this Agreement shall be deemed to limit or modify such indemnification. No agreement entered into pursuant to this Section 3.17(d) shall be deemed a Sub-Servicing Agreement for purposes of Section 3.22.
(e) Notwithstanding anything to the contrary, this Section 3.17 shall not apply to any Outside Administered REO Property.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Upon completion of the Project the Recipient shall make a full and complete accounting to the OPWC of the Eligible Project Cost.
Access to Project Site Redeveloper shall permit the representatives of the City to enter Project Site at any and all reasonable times, as the City may deem necessary for the purposes of this Redevelopment Agreement, including but not limited to work and inspection of all work being performed in connection with the construction of the Redeveloper Improvements. Similarly, the City shall permit Redeveloper such entry upon the public rights of way for such purposes. No compensation shall be payable nor shall any charges be made in any form by any party for the access or inspection provided for in this Section. The City’s right of access granted under this Section shall terminate upon issuance by the City of the Redeveloper’s Certificate of Completion of Redeveloper Improvements. Notwithstanding the above, Redeveloper shall not be relieved of the provisions contained in Chapter 14.29 of the Lincoln Municipal Code regarding the use of streets for private construction purposes.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.
The Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part.
