System Enhancements State Street will provide to the Fund any enhancements to the System developed by State Street and made a part of the System; provided that State Street offer the Fund reasonable training on the enhancement. Charges for system enhancements shall be as provided in the Fee Schedule. State Street retains the right to charge for related systems or products that may be developed and separately made available for use other than through the System.
Enhancements No Enhancement shall be provided in respect of any Series of Notes, nor will any Enhancement Provider have any rights hereunder, as third-party beneficiary or otherwise, unless the Servicer has provided its prior written consent to such Enhancement, such consent not to be unreasonably withheld.
Maintenance Programme (i) The Contractor shall prepare a monthly maintenance programme (the “Maintenance Programme”) in consultation with the Authority’s Engineer and submit the same to the Authority’s Engineer not later than 10 (ten) days prior to the commencement of the month in which the Maintenance is to be carried out. For this purpose a joint monthly inspection by the Contractor and the Authority’s Engineer shall be undertaken. The Maintenance Programme shall contain the following:
(a) The condition of the road in the format prescribed by the Authority’s Engineer;
(b) the proposed maintenance Works; and
(c) deployment of resources for maintenance Works.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Maintenance and Insurance (a) The Company shall maintain or cause to be maintained, at its own expense, all of its assets and properties in good working order and condition, making all necessary repairs thereto and renewals and replacements thereof.
(b) The Company shall maintain or cause to be maintained, at its own expense, insurance in form, substance and amounts (including deductibles), which the Company deems reasonably necessary to the Company's business, (i) adequate to insure all assets and properties of the Company, which assets and properties are of a character usually insured by persons engaged in the same or similar business against loss or damage resulting from fire or other risks included in an extended coverage policy; (ii) against public liability and other tort claims that may be incurred by the Company; (iii) as may be required by the Transaction Documents and/or applicable law and (iv) as may be reasonably requested by Secured Party, all with adequate, financially sound and reputable insurers.
Structures Airport facilities such as bridges; culverts; catch basins, inlets, retaining walls, cribbing; storm and sanitary sewer lines; water lines; underdrains; electrical ducts, manholes, handholes, lighting fixtures and bases; transformers; flexible and rigid pavements; navigational aids; buildings; vaults; and, other manmade features of the airport that may be encountered in the work and not otherwise classified herein. 10-50 SUBGRADE. The soil which forms the pavement foundation.
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Maintenance Program LESSEE's Maintenance Program
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Maintenance of Properties and Insurance (a) The Company shall cause all properties used or held for use in the conduct of its business or the business of any Subsidiary to be maintained and kept in good condition, repair and working order (ordinary wear and tear excepted) and supplied with all necessary equipment and shall cause to be made all necessary repairs, renewals, replacements, betterments and improvements thereof, all as in the judgment of the Company may be necessary so that the business carried on in connection therewith may be properly and advantageously conducted at all times; provided, however, that nothing in this Section shall prevent the Company from discontinuing the operation or maintenance of any such property, or disposing of it, if such discontinuance or disposal is, in the judgment of the Company, desirable in the conduct of its business and not disadvantageous in any material respect to the Holders.
(b) The Company shall provide or cause to be provided, for itself and each of its Subsidiaries, insurance (including appropriate self-insurance) against loss or damage of the kinds that, in the reasonable, good faith opinion of the Company, are adequate and appropriate for the conduct of the business of the Company and such Subsidiaries in a prudent manner, with reputable insurers or with the government of the United States or an agency or instrumentality thereof, in such amounts, with such deductibles, and by such methods as shall be customary, in the reasonable, good faith opinion of the Company, for corporations similarly situated in the industry.
