Disputes, Etc Prompt written notice of (i) any claims, legal or arbitration proceedings, proceedings before any Governmental Authority, or disputes, or to the knowledge of the Borrower threatened, or affecting the Borrower, or any of its Subsidiaries which, if adversely determined, could reasonably be expected to cause a Material Adverse Change, or any material labor controversy of which the Borrower or any of its Subsidiaries has knowledge resulting in or reasonably considered to be likely to result in a strike against the Borrower or any of its Subsidiaries and (ii) any claim, judgment, Lien or other encumbrance (other than a Permitted Lien) affecting any Property of the Borrower or any Subsidiary if the value of the claim, judgment, Lien, or other encumbrance affecting such Property shall exceed $1,000,000;
Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.
Disputes and Law I1 Governing Law and Jurisdiction
Disputes concerning labor standards Disputes arising out of the labor standards provisions of this contract shall not be subject to the general disputes clause of this contract. Such disputes shall be resolved in accordance with the procedures of the Department of Labor set forth in 29 CFR parts 5, 6, and
DISPUTES AND GRIEVANCES Section 1. This Agreement is intended to provide close cooperation between management and labor. Each of the Unions will assign a representative to this project for the purpose of completing the construction of the project economically, efficiently, continuously, and without interruptions, delays, or work stoppages. Section 2. The Port of Seattle, Contractors, Unions, and the employees, collectively and individually, realize the importance to all parties to maintain continuous and uninterrupted performance of the work of the project, and agree to resolve disputes in accordance with the grievance-arbitration provisions set forth in this Article. Section 3. Any question or dispute arising out of and during the term of this Project Agreement (other than trade jurisdictional disputes) shall be considered a grievance and subject to resolution under the following procedures: (a) When any employee subject to the provisions of this Agreement feels he/she is aggrieved by a violation of this Agreement, he/she, through his/her local union business representative or designated Union Representative, shall, within five (5) working days after the occurrence, or had knowledge of or should have known of the alleged violation, give notice to the work-site representative of the involved Contractor stating the provision(s) alleged to have been violated. The business representative of the local union or the designated Union Representative and the work-site representative of the involved Contractor and the Owners Representative shall meet and endeavor to adjust the matter within three (3) working days after timely notice has been given. The representative of the Contractor shall keep the meeting minutes and shall respond to the Union representative in writing and the Owners Representatives at the conclusion of the meeting but not later than twenty-four (24) hours thereafter. If they fail to resolve the matter within the prescribed period, the grieving party may, within forty-eight (48) hours thereafter, pursue Step 2 of the Grievance Procedure, provided the grievance is reduced to writing, setting forth the relevant information concerning the alleged grievance, including a short description thereof, the date on which the grievance occurred, and the provision(s) of the Agreement alleged to have been violated. (b) Should the Local Union(s) or the Project Contractor or any Sub-Contractor of whatever tier have a dispute with the other party and, if after conferring, a settlement is not reached within three (3) working days, the dispute may be reduced to writing and proceed to Step 2 in the same manner as outlined herein for the adjustment of an employee complaint. Step 2. The International Union Representative and the involved Contractor shall meet within seven (7) working days of the referral of a dispute to this second step to arrive at a satisfactory settlement thereof. Meeting minutes shall be kept by the Contractor. If the parties fail to reach an agreement, the dispute may be appealed in writing in accordance with the provisions of Step 3 within seven (7) calendar days thereafter.
Disputes between a Contracting Party and an Investor (1) Any dispute which may arise between an investor of one Contracting Party and the other Contracting Party in connection with an investment on the territory of that other Contracting Party shall be subject to negotiations between the parties in dispute. (2) If any dispute between an investor of one Contracting Party and the other Contracting Party continues to exist after a period of three months, investor shall be entitled to submit the case either to: (a) The International Centre for Settlement of Investment Disputes having regard to the applicable provisions of the Convention on the Settlement of Investment Disputes between States and Nationals of other States opened for signature at Washington D.C. on 18 March 1965, or in case both Contracting Parties have not become parties to this Convention, (b) An arbitrator or international ad hoc arb1 tral tribunal established under the Arbitration Rules of the United Nations Commission on International Trade Law. The parties to the dispute may agree in writing to modify these Rules. The arbitral awards shall be final and binding on both Parties to the dispute.Arbitration Rules of the United Nations Commission on International Trade Law. The parties to the dispute may agree in writing to modify these Rules. The arbitral awards shall be final and binding on both Parties to the dispute.
Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.
Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.
Formal Disputes concerning a pending or awarded Contract must be filed within ten (10) business days by an Interested Party (see II.B(1)(c)) after the disputing party knew or should have known of the facts which form the basis of the Formal Dispute; however, a Formal Dispute may not be filed later than ten (10) business days after issuance of the Contract award.
Disputes Concerning Work or Cost Any dispute concerning the work hereunder or additional costs, or any non-procurement issues shall be settled in accordance with 43 Texas Administrative Code §9.2.
