Duty to Give Notice to Owner. If the Owner, the Design Professional, or any other person with whom the Owner or Design Professional respectively has a direct contractual relationship shall, in the judgment of the CM/GC, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, CM/GC shall give prompt notice to Owner so as to permit Owner to take corrective action.
Duty to Give Notice to Owner. If the Owner, the Program Manager, or any other person with whom the Owner has a direct contractual relationship shall, in the judgment of the Design-Builder, acts or fails to act in such a manner as to (i) delay the progress of the construction of the Project or (ii) increase the cost of the Project, Design-Builder shall give prompt notice to Owner so as to permit Owner to take corrective action.
Duty to Give Notice to Owner. PART 3 -