CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “
(1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “
(1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.
Certification Regarding Prohibition of Boycotting Israel (Tex Gov. Code 2271)
Application and Operation of Agreement Table Of Contents
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Survival of Representations, Warranties and Agreements; Third Party Beneficiary Notwithstanding any investigation made by any party to this Agreement or by the Placement Agent, all covenants, agreements, representations and warranties made by the Company and the Investor herein will survive the execution of this Agreement, the delivery to the Investor of the Shares and Warrants being purchased and the payment therefor. The Placement Agent shall be a third party beneficiary with respect to the representations, warranties and agreements of the Investor in Section 4 hereof.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Application of Agreement If the Company has secured work outside of the County of Cumberland, an employee whom normally works within the County of Cumberland:
i) Will be paid at the rates outlined in this agreement if specifically requested by the Company to work on that site.
ii) May be offered work at that location at the rates that apply for that area and if applicable, taking into account clause 27, Distant Work.
iii) May determine that redundancy would be more appropriate. Where there is any inconsistency between this Agreement and the Parent Award, the Agreement shall prevail to the extent of the inconsistency.
Term; Termination; Survival of Provisions The term of this Agreement shall commence on the date hereof and shall continue, unless earlier terminated pursuant to the provisions of this section, for twelve (12) months, automatically renewed thereafter for monthly periods unless either Party informs the other in writing thirty (30) days prior to the end of the current term of its intent to terminate this Agreement. This Agreement may be terminated prior to the end of the current term, by mutual written consent of the Parties hereto, or:
a. by any Party, upon thirty (30) days’ prior written notice; and
b. by either Co-Manager (with respect to such Co-Manager, but not to the other Co-Manager) in the event that Client fails to pay any amount due hereunder within thirty (30) days of that due date or otherwise breaches its obligations to such Co-Manager. Termination of this Agreement will not affect either Co-Manager’s right to receive continuing compensation with respect to investments made prior to such termination. It is understood and agreed that the provisions of this Agreement relating to the payment of fees and expenses, confidentiality, and indemnification shall survive any termination of this Agreement.
PROCEDURE FOR NOTIFICATION AND APPLICATION FOR INDEMNIFICATION (a) Indemnitee agrees to notify promptly the Company in writing upon being served with any summons, citation, subpoena, complaint, indictment, information or other document relating to any Proceeding, claim, issue or matter therein which may be subject to indemnification, hold harmless or exoneration rights, or advancement of Expenses covered hereunder. The failure of Indemnitee to so notify the Company shall not relieve the Company of any obligation which it may have to Indemnitee under this Agreement, or otherwise.
(b) Indemnitee may deliver to the Company a written application to indemnify, hold harmless or exonerate Indemnitee in accordance with this Agreement. Such application(s) may be delivered from time to time and at such time(s) as Indemnitee deems appropriate in his or her sole discretion. Following such a written application for indemnification by Indemnitee, Indemnitee’s entitlement to indemnification shall be determined according to Section 12(a) of this Agreement.
Submission of Agreement Submission of this Lease to Tenant for signature does not constitute a reservation of space or an option to acquire a right of entry. This Lease is not binding or effective until execution by and delivery to both Landlord and Tenant.
