REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing.
(b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD.
(c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article.
(d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.
Effect of Decision The decision or award of the arbitrator shall be final and binding upon the University, the UFF, and the grievant, provided that either party may appeal to an appropriate court of law a decision that was rendered by the arbitrator acting outside of or beyond the arbitrator's jurisdiction, pursuant to Section 682.13, Florida Statutes.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.
35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.
Effect of Failure to Comply Failure to comply with reporting requirements shall result in the withholding of funds, the return of improper payments or Unallowable Costs, will be considered a material breach of this Agreement and may be the basis to recover Grant Funds. Grantee's failure to comply with this ARTICLE XIII, ARTICLE XIV, or ARTICLE XV shall be considered prima facie evidence of a breach and may be admitted as such, without further proof, into evidence in an administrative proceeding before Grantor, or in any other legal proceeding. Grantee should refer to the State of Illinois Grantee Compliance Enforcement System for policy and consequences for failure to comply.
Effect of Default If Tenant is in Default, Landlord is irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any transferee under any sublease, license or other occupancy agreement to make all payments under such agreement directly to Landlord (which Landlord shall apply towards Tenant’s obligations hereunder) until such Default is cured. Such transferee shall rely upon any representation by Landlord that Tenant is in Default, whether or not confirmed by Tenant.
Effect of Breach In the event that Executive breaches any provision of this Agreement, Executive agrees that the Company may suspend all payments to Executive under this Agreement (including any Severance Payment), recover from Executive any damages suffered as a result of such breach and recover from Executive any reasonable attorneys’ fees or costs it incurs as a result of such breach. In addition, Executive agrees that the Company may seek injunctive or other equitable relief, without the necessity of posting bond, as a result of a breach by Executive of any provision of this Agreement.
Effect of Entries The entries made in the records maintained pursuant to paragraph (c) or (d) of this Section shall be prima facie evidence, absent obvious error, of the existence and amounts of the obligations recorded therein; provided that the failure of any Lender or the Administrative Agent to maintain such records or any error therein shall not in any manner affect the obligation of the Borrower to repay the Loans in accordance with the terms of this Agreement.
Effect of Sale Upon the occurrence of an Event of Default, to the extent permitted by law, Borrower covenants that it will not at any time insist upon or plead, or in any manner whatsoever claim or take any benefit or advantage of, any stay or extension law now or at any time hereafter in force, nor claim, take nor insist upon any benefit or advantage of or from any law now or hereafter in force providing for the valuation or appraisement of the Collateral or any part thereof prior to any sale or sales thereof to be made pursuant to any provision herein contained, or to the decree, judgment or order of any court of competent jurisdiction; nor, after such sale or sales, claim or exercise any right under any statute now or hereafter made or enacted by any state or otherwise to redeem the property so sold or any part thereof, and, to the full extent legally permitted, except as to rights expressly provided herein, hereby expressly waives for itself and on behalf of each and every Person, except decree or judgment creditors of Borrower, acquiring any interest in or title to the Collateral or any part thereof subsequent to the date of this Agreement, all benefit and advantage of any such law or laws, and covenants that it will not invoke or utilize any such law or laws or otherwise hinder, delay or impede the execution of any power herein granted and delegated to Lender, but will suffer and permit the execution of every such power as though no such power, law or laws had been made or enacted. Any sale, whether under any power of sale hereby given or by virtue of judicial proceedings, shall operate to divest all right, title, interest, claim and demand whatsoever, either at law or in equity, of Borrower in and to the Property sold, and shall be a perpetual bar, both at law and in equity, against Borrower, its successors and assigns, and against any and all Persons claiming the Property sold or any part thereof under, by or through Borrower, its successors or assigns.
EFFECT OF COMPLIANCE Compliance with and fulfillment of this Agreement shall be deemed to resolve all issues raised in the NOV.
Effect of Waiver or Consent A waiver or consent, express or implied, to or of any breach or default by any Person in the performance by that Person of its obligations with respect to the Company is not a consent or waiver to or of any other breach or default in the performance by that Person of the same or any other obligations of that Person with respect to the Company. Failure on the part of a Person to complain of any act of any Person or to declare any Person in default with respect to the Company, irrespective of how long that failure continues, does not constitute a waiver by that Person of its rights with respect to that default until the applicable statute-of-limitations period has run.
