Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Restoration of Rights on Abandonment of Proceedings In case the Trustee shall have proceeded to enforce any right under this Indenture and such proceedings shall have been discontinued or abandoned for any reason, or shall have been determined adversely to the Trustee, then and in every such case the Issuer and the Trustee shall be restored respectively to their former positions and rights hereunder, and all rights, remedies and powers of the Issuer, the Trustee and the Securityholders shall continue as though no such proceedings had been taken.
Limitation on Out-of-State Litigation Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
Effect of Sale Upon the occurrence of an Event of Default, to the extent permitted by law, Borrower covenants that it will not at any time insist upon or plead, or in any manner whatsoever claim or take any benefit or advantage of, any stay or extension law now or at any time hereafter in force, nor claim, take nor insist upon any benefit or advantage of or from any law now or hereafter in force providing for the valuation or appraisement of the Collateral or any part thereof prior to any sale or sales thereof to be made pursuant to any provision herein contained, or to the decree, judgment or order of any court of competent jurisdiction; nor, after such sale or sales, claim or exercise any right under any statute now or hereafter made or enacted by any state or otherwise to redeem the property so sold or any part thereof, and, to the full extent legally permitted, except as to rights expressly provided herein, hereby expressly waives for itself and on behalf of each and every Person, except decree or judgment creditors of Borrower, acquiring any interest in or title to the Collateral or any part thereof subsequent to the date of this Agreement, all benefit and advantage of any such law or laws, and covenants that it will not invoke or utilize any such law or laws or otherwise hinder, delay or impede the execution of any power herein granted and delegated to Lender, but will suffer and permit the execution of every such power as though no such power, law or laws had been made or enacted. Any sale, whether under any power of sale hereby given or by virtue of judicial proceedings, shall operate to divest all right, title, interest, claim and demand whatsoever, either at law or in equity, of Borrower in and to the Property sold, and shall be a perpetual bar, both at law and in equity, against Borrower, its successors and assigns, and against any and all Persons claiming the Property sold or any part thereof under, by or through Borrower, its successors or assigns.
Effect of Consents After an amendment, supplement, waiver or other action becomes effective as to any series of Securities, a consent to it by a Holder of such series of Securities is a continuing consent conclusive and binding upon such Holder and every subsequent Holder of the same Securities or portion thereof, and of any Security issued upon the transfer thereof or in exchange therefor or in place thereof, even if notation of the consent is not made on any such Security. An amendment, supplement or waiver becomes effective in accordance with its terms and thereafter binds every Holder.
EFFECT OF COMPLIANCE Compliance with and fulfillment of this Agreement shall be deemed to resolve all issues raised in the NOV.
Certain Additional Matters (a) Any arbitration award shall be a bare award limited to a holding for or against a party and shall be without findings as to facts, issues or conclusions of law (including with respect to any matters relating to the validity or infringement of patents or patent applications) and shall be without a statement of the reasoning on which the award rests, but must be in adequate form so that a judgment of a court may be entered thereupon. Judgment upon any arbitration award hereunder may be entered in any court having jurisdiction thereof.
(b) Prior to the time at which an arbitrator is appointed pursuant to Section 8.4, any party may seek one or more temporary restraining orders in a court of competent jurisdiction if necessary in order to preserve and protect the status quo. Neither the request for, or grant or denial of, any such temporary restraining order shall be deemed a waiver of the obligation to arbitrate as set forth herein and the arbitrator may dissolve, continue or modify any such order. Any such temporary restraining order shall remain in effect until the first to occur of the expiration of the order in accordance with its terms or the dissolution thereof by the arbitrator.
(c) Except as required by law, the parties shall hold, and shall cause their respective officers, directors, employees, agents and other representatives to hold, the existence, content and result of mediation or arbitration in confidence in accordance with the provisions of Article VIII and except as may be required in order to enforce any award. Each of the parties shall request that any mediator or arbitrator comply with such confidentiality requirement.
(d) If at any time the sole arbitrator shall fail to serve as an arbitrator for any reason, the parties shall select a new arbitrator who shall be disinterested as to the parties and the matter in accordance with the procedures set forth herein for the selection of the initial arbitrator. The extent, if any, to which testimony previously given shall be repeated or as to which the replacement arbitrator elects to rely on the stenographic record (if there is one) of such testimony shall be determined by the replacement arbitrator.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Compliance with Existing Laws Xxxxxxx, agrees to comply with all federal, state, and municipal laws, rules, and regulations in the performance of this Agreement that are generally applicable to the activities in which the Grantee is engaged in the performance of said contracts.
Effect and invariability of the Clauses These Clauses set out appropriate safeguards, including enforceable data subject rights and effective legal remedies, pursuant to Article 46(1) and Article 46(2)(c) of Regulation (EU) 2016/679 and, with respect to data transfers from controllers to processors and/or processors to processors, standard contractual clauses pursuant to Article 28(7) of Regulation (EU) 2016/679, provided they are not modified, except to select the appropriate Module(s) or to add or update information in the Appendix. This does not prevent the Parties from including the standard contractual clauses laid down in these Clauses in a wider contract and/or to add other clauses or additional safeguards, provided that they do not contradict, directly or indirectly, these Clauses or prejudice the fundamental rights or freedoms of data subjects.
