Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors Sample Clauses

Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors. (a) The Issuer hereby authorizes the Company, as agent of the Issuer or in its own behalf, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require all manufacturers, fabricators, vendors, contractors and subcontractors and suppliers to complete their contracts relating to the Project diligently in accordance with the terms of such contracts, including, without limitation, the correction of any defects. The Issuer agrees that the Company may, from time to time, in its own name, or in the name of the Issuer, take such action as the Company may elect in its sole discretion against such manufacturers, fabricators, vendors, contractors and subcontractors and suppliers, and their sureties, to insure the proper acquisition, construction and equipping of the Project. (b) To the extent that the Project is not complete, or is under construction as of the effective date of this Lease, all plans, specifications, drawings and similar documentation governing the planning, development and construction of the Project shall be prepared and may be amended, supplemented or replaced, as the case may be, at the sole discretion of the Company so long as the elements of the Project covered thereunder are consistent with the objectives and requirements of the Act and the general description of the Project in this Lease. The Company may engage or disengage architects, engineers and other professionals in the preparation of all such work product. (c) All warranties, bonds, letters of credit or other security or other undertakings furnished by or on behalf of any contractors, subcontractors, fabricators, vendors, manufacturers or suppliers which provide labor or materials (including building fixtures) for the Project shall be in the name of the Company for the benefit of the Issuer, the Holder, and the Company and may be enforced by the Company, at its own risk and expense, without consultation with or direction by either the Issuer or the Holder. (d) The Issuer hereby authorizes the Company, as agent of the Issuer or on its own behalf, and at the sole expense of the Company, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require any contractors, subcontractors, fabricators, vendors, manufacturers and suppliers that have provided labor or materials (including building fixtures) for the Project to fulfill their warranties and contractual responsibilities di...
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors. The Issuer hereby authorizes the Company, as agent of the Issuer or in its own behalf, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require all manufacturers, fabricators, vendors, contractors and subcontractors and suppliers to complete their contracts relating to the Project diligently in accordance with the terms of such contracts, including, without limitation, the correction of any defects. The Issuer agrees that the Company may, from time to time, in its own name, or in the name of the Issuer, take such action as the Company may elect in its sole discretion against such manufacturers, fabricators, vendors, contractors and subcontractors and suppliers, and their sureties, to insure the proper acquisition, construction and equipping of the Project. The Issuer hereby authorizes the Company, as agent of the Issuer or on its own behalf, and at the sole expense of the Company, to take such action and institute such proceedings as the Company may elect in its sole discretion to cause and require any contractors, manufacturers and dealers that have provided labor or materials (including building fixtures) for the Project to fulfill their warranties and contractual responsibilities diligently in accordance with the terms of any purchase or installation contracts, including, without limitation, the correction of any defective parts or workmanship. The Issuer agrees that the Company may, from time to time, take such action as the Company may elect in its sole discretion to insure the conformity of the Project to the specifications therefor.
Sample 1

Related to Enforcement of Remedies Against Contractors and Subcontractors and Their Sureties and Against Manufacturers and Vendors

  • Pursuit of Claims Against Third Parties If (i) a Party incurs any Liability arising out of this Agreement or any Ancillary Agreement; (ii) an adequate legal or equitable remedy is not available for any reason against the other Party to satisfy the Liability incurred by the incurring Party; and (iii) a legal or equitable remedy may be available to the other Party against a Third Party for such Liability, then the other Party shall use its commercially reasonable efforts to cooperate with the incurring Party, at the incurring Party’s expense, to permit the incurring Party to obtain the benefits of such legal or equitable remedy against the Third Party.

  • Claims Against Third Parties The Licensee shall, as soon as it becomes aware, give DACS in writing full particulars of any infringements or violations of any of DACS’ / the Artist’s rights in the Work.

  • Rights and Remedies are Cumulative Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party.

  • CERTIFICATION PROHIBITING DISCRIMINATION AGAINST FIREARM AND AMMUNITION INDUSTRIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has at least ten (10) full-time employees; (c) this contract has a value of at least $100,000 that is paid wholly or partly from public funds; (d) the contract is not excepted under Tex. Gov’t Code § 2274.003 of SB 19 (87th leg.); and (e) governmental entity has determined that company is not a sole-source provider or governmental entity has not received any bids from a company that is able to provide this written verification, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 19 (87th session), the company hereby certifies and verifies that the company, or association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, including a wholly owned subsidiary, majority-owned subsidiary parent company, or affiliate of these entities or associations, that exists to make a profit, does not have a practice, policy, guidance, or directive that discriminates against a firearm entity or firearm trade association and will not discriminate during the term of this contract against a firearm entity or firearm trade association. For purposes of this contract, “discriminate against a firearm entity or firearm trade association” shall mean, with respect to the entity or association, to: “ (1) refuse to engage in the trade of any goods or services with the entity or association based solely on its status as a firearm entity or firearm trade association; (2) refrain from continuing an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association; or (3) terminate an existing business relationship with the entity or association based solely on its status as a firearm entity or firearm trade association. See Tex. Gov’t Code § 2274.001(3) of SB 19. “Discrimination against a firearm entity or firearm trade association” does not include: “ (1) the established policies of a merchant, retail seller, or platform that restrict or prohibit the listing or selling of ammunition, firearms, or firearm accessories; and (2) a company’s refusal to engage in the trade of any goods or services, decision to refrain from continuing an existing business relationship, or decision to terminate an existing business relationship to comply with federal, state, or local law, policy, or regulations or a directive by a regulatory agency, or for any traditional business reason that is specific to the customer or potential customer and not based solely on an entity’s or association’s status as a firearm entity or firearm trade association.” See Tex. Gov’t Code § 2274.001(3) of SB 19.

  • No Waiver of Provisional Remedies, Self-Help and Foreclosure The arbitration requirement does not limit the right of any party to (i) foreclose against real or personal property collateral; (ii) exercise self-help remedies relating to collateral or proceeds of collateral such as setoff or repossession; or (iii) obtain provisional or ancillary remedies such as replevin, injunctive relief, attachment or the appointment of a receiver, before during or after the pendency of any arbitration proceeding. This exclusion does not constitute a waiver of the right or obligation of any party to submit any dispute to arbitration or reference hereunder, including those arising from the exercise of the actions detailed in sections (i), (ii) and (iii) of this paragraph.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

  • Complaints Against Teachers Communication between the Community and the School ideally should be such that most complaints may be resolved through personal conferences at the School level. Various avenues of contact between teacher, pupil, parent, principal and other appropriate staff personnel should be pursued before using the formal procedures outlined below. The following process shall not be used when allegations involve legal or criminal violations or allegations of misconduct towards a student, such as abuse or discrimination. Such allegations shall be investigated in accordance with board policy and in conjunction with the authorities, consistent with principles of due process. 1. The Complainant shall be given a copy of this Part II, Section J and be told that there are contractual requirements for the District to follow. 2. If such conferences do not lead to understanding and resolution of problems involved, a parent may pursue further action by submitting a complaint against a teacher, which must be submitted in writing to the principal of the school. The principal shall give a copy to the teacher. Likewise, the teacher may request in writing to the principal that such a written complaint must be filed or the matter shall be considered closed. The principal shall give a copy to the parent. 3. After a written complaint is filed, if requested by the complainant or the teacher, a meeting involving the teacher, the principal, and the complainant will be arranged as soon as possible to discuss the complaint. 4. If it is not resolved at that level to the satisfaction of the Complainant, the Complainant may appeal to the Superintendent. 5. If it is still unresolved to the satisfaction of the Complainant, the Complainant may appeal to the Board of Education.

  • Contracts (Rights of Third Parties) Xxx 0000 No term of this Agreement is enforceable under the Contracts (Rights of Third Parties) Xxx 0000 by a person who is not a party to this Agreement.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined). 22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees), (a) based on allegations that, if true, would establish (i) the Indemnifying Party’s breach of this Agreement; (ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct; (iii) the Indemnifying Party’s negligent or willful misconduct or omissions; (iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party; (v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or (vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or (b) that arises out of: (i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement; (ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement; (iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement; (iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or (v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)). 22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section. 22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.

  • Rights and Remedies of the Collateral Agent (a) In addition to the rights and remedies set forth herein or otherwise available at law or in equity, after a collateral event of default (as specified in Section 13.01(b)) hereunder, the Collateral Agent shall have all of the rights and remedies with respect to the Collateral of a secured party under the UCC (whether or not the UCC is in effect in the jurisdiction where the rights and remedies are asserted) and the TRADES Regulations and such additional rights and remedies to which a secured party is entitled under the laws in effect in any jurisdiction where any rights and remedies hereunder may be asserted. Without limiting the generality of the foregoing, such remedies may include, to the extent permitted by applicable law, (1) retention of the Notes underlying Pledged Applicable Ownership Interests in Notes, the Pledged Treasury Securities and/or the Pledged Applicable Ownership Interests in the Treasury Portfolio in full satisfaction of the Holders’ obligations under the Purchase Contracts and the Purchase Contract Agreement and/or (2) sale of the Notes underlying Pledged Applicable Ownership Interests in Notes, the Pledged Treasury Securities or the Pledged Applicable Ownership Interests in the Treasury Portfolio in one or more public or private sales. (b) Without limiting any rights or powers otherwise granted by this Agreement to the Collateral Agent or under applicable law, in the event the Collateral Agent is unable to make payments to the Company on account of Proceeds of (i) the Notes underlying Pledged Applicable Ownership Interests in Notes (other than any interest payments thereon), (ii) Pledged Applicable Ownership Interests in the Treasury Portfolio, or (iii) the Pledged Treasury Securities as provided in this Agreement in satisfaction of the Obligations of the Holder of the Units of which such Notes underlying Pledged Applicable Ownership Interests in Notes, such Pledged Applicable Ownership Interests in the Treasury Portfolio or such Pledged Treasury Securities are a part under the related Purchase Contracts, the inability to make such payments shall constitute a “collateral event of default” hereunder and the Collateral Agent shall, for the benefit of the Company, have and may exercise, with reference to such Notes underlying Pledged Applicable Ownership Interests in Notes, Pledged Treasury Securities or Pledged Applicable Ownership Interests in the Treasury Portfolio, as applicable, any and all of the rights and remedies available to a secured party under the UCC and the TRADES Regulations after default by a debtor, and as otherwise granted herein or under any applicable law. (c) Without limiting any rights or powers otherwise granted by this Agreement to the Collateral Agent or under applicable law, the Collateral Agent is hereby irrevocably authorized to receive, collect and apply to the satisfaction of the Obligations all payments with respect to (i) the Notes underlying Pledged Applicable Ownership Interests in Notes (other than any interest payments thereon), (ii) the Pledged Treasury Securities and (iii) the Pledged Applicable Ownership Interests in the Treasury Portfolio, subject, in each case, to the provisions of this Agreement, and as otherwise provided herein. (d) The Purchase Contract Agent and each Holder agrees that, from time to time, upon the written request of the Collateral Agent, the Purchase Contract Agent, on behalf of such Holder, shall execute and deliver such further documents and do such other acts and things as the Collateral Agent may reasonably request in order to maintain the Pledge, and the perfection and priority thereof, and to confirm the rights of the Collateral Agent hereunder. The Purchase Contract Agent shall have no liability to any Holder for executing any documents or taking any such acts requested by the Collateral Agent hereunder, except for liability for its own negligent acts, its own negligent failure to act or its own willful misconduct.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!