Equitable Adjustments for Change Documentation Preparations Sample Clauses

Equitable Adjustments for Change Documentation Preparations. For its effort expended in preparing ECPs, NECPs, and Deviations/Waivers, the Contractor shall receive equitable adjustment under the following circumstances: (1) In the event the Contractor, on its own initiative, and without written request from the Contracting Officer, develops a change document that is later disapproved by the Government, the Contractor shall bear the cost of this effort. (2) To avoid such loss, and at its option, the Contractor may submit a "preliminary" document that outlines intent, but without detailed supporting documentation and request the Contracting Officer's approval for expenditure of effort to complete the detailed supporting documentation. In the event the Contracting Officer denies this request, the Contractor will bear the cost of development of the "preliminary" document, and shall make no further effort to complete detailed supporting documentation. (3) In the event the Contracting Officer approves the Contractor's request to develop supporting documentation, the Contractor shall be equitably compensated for its effort for both the "preliminary" and "final" documentation, regardless of whether or not the change document is later approved. (4) In the event the Contracting Officer requests in writing that the Contractor develop change documentation, the effort expended by the Contractor in developing such documentation shall be subject to equitable adjustment, regardless of whether or not the change document is later approved. (5) In the event the Contractor, on its own initiative, and without written request from the Government, develops a change document that is later approved by the Contracting Officer, the cost of developing such documentation shall be subject to equitable adjustment. (6) Failure to agree to such equitable adjustment in contract price shall constitute a dispute, and shall be adjudicated in accordance with the requirements of the clause entitled "Disputes" (FAR 52.233-1).
Sample 1Sample 2Sample 3See All (37)
Equitable Adjustments for Change Documentation Preparations. For its effort expended in preparing ECPs, NECPs, Deviations and Waivers, the Contractor shall receive equitable adjustment under the following circumstances:
Sample 1

Related to Equitable Adjustments for Change Documentation Preparations

  • Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

  • ADJUSTMENTS FOR CHANGES IN CAPITAL STRUCTURE Subject to any required action by the stockholders of the Company and the requirements of Sections 409A and 424 of the Code to the extent applicable, in the event of any change in the Stock effected without receipt of consideration by the Company, whether through merger, consolidation, reorganization, reincorporation, recapitalization, reclassification, stock dividend, stock split, reverse stock split, split-up, split-off, spin-off, combination of shares, exchange of shares, or similar change in the capital structure of the Company, or in the event of payment of a dividend or distribution to the stockholders of the Company in a form other than Stock (excepting normal cash dividends) that has a material effect on the Fair Market Value of shares of Stock, appropriate and proportionate adjustments shall be made in the number, Exercise Price and kind of shares subject to the Option, in order to prevent dilution or enlargement of the Participant’s rights under the Option. For purposes of the foregoing, conversion of any convertible securities of the Company shall not be treated as “effected without receipt of consideration by the Company.” Any fractional share resulting from an adjustment pursuant to this Section shall be rounded down to the nearest whole number and the Exercise Price shall be rounded up to the nearest whole cent. In no event may the Exercise Price be decreased to an amount less than the par value, if any, of the stock subject to the Option. Such adjustments shall be determined by the Committee, and its determination shall be final, binding and conclusive.

  • Adjustments for Combinations, Etc If the outstanding Shares are combined or consolidated, by reclassification or otherwise, into a lesser number of shares, the Warrant Price shall be proportionately increased. If the outstanding Shares are combined or consolidated, by reclassification or otherwise, into a greater number of shares, the Warrant Price shall be proportionately decreased.

  • Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.

  • Fee Adjustments The fixed fees and other fees expressed as stated dollar amounts in this Schedule C and in this Agreement are subject to annual increases, commencing on the one-year anniversary date of the date of this Agreement, in an amount equal to the percentage increase in consumer prices for services as measured by the United States Consumer Price Index entitled “All Services Less Rent of Shelter,” or a similar index should such index no longer be published, since such one-year anniversary or since the date of the last fee increase, as applicable.

  • Adjustments for Capital Changes In the event of any change in the outstanding shares of Common Stock of the Company by reason of any stock dividend or split, recapitalization, merger, consolidation, spin-off, reorganization, combination or exchange of shares, or other similar corporate change, or other increase or decrease in such shares effected without receipt or payment of consideration by the Company, a duly authorized representative of the Company shall adjust the number of Restricted Shares granted pursuant to the Plan and this Agreement to prevent dilution or enlargement of the rights granted to the Recipient.

  • Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Adjustments for Stock Splits and Combinations If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date) effect a split of the outstanding Common Stock, the applicable Conversion Price in effect immediately prior to the stock split shall be proportionately decreased. If the Maker shall at any time or from time to time after the Closing Date (but whether before or after the Issuance Date), combine the outstanding shares of Common Stock, the applicable Conversion Price in effect immediately prior to the combination shall be proportionately increased. Any adjustments under this Section 3.4(a)(i) shall be effective at the close of business on the date the stock split or combination occurs.

  • Successive Adjustments After an adjustment to the Conversion Rate under this Article 10, any subsequent event requiring an adjustment under this Article 10 shall cause an adjustment to the Conversion Rate as so adjusted.