Establishment of Completion Date; Obligation of Borrower to Complete Sample Clauses

Establishment of Completion Date; Obligation of Borrower to Complete. The Completion Date shall be evidenced to the Trustee by a certificate signed by the Authorized Borrower Representative substantially in the form of Exhibit A hereto. The Borrower may withhold payment and direct the Trustee to retain in the Project Fund an amount sufficient to pay any Cost of the Project which has been incurred; such retained moneys shall be disbursed after the Completion Date in the manner provided in Section 3.3 hereof. If the Borrower withholds the payment of any such cost or expense of the Project, the certificate shall state the amount of such withholding and the reason therefor. Notwithstanding the foregoing, such certificate may state that it is given without prejudice to any rights against third parties which exist at the date of such certificate or which may subsequently come into being. (1) for the payment, in accordance with the provisions of this Agreement, of any Cost of the Project consisting of a respective Qualified Cost not theretofore paid, as specified in the Completion Certificate (as hereinafter defined); (2) for the payment of Qualified Costs of any additional related improvements to be installed or constructed on the Project site; (3) for transfer to the Bond Fund to be used to pay principal of or interest on Bonds upon redemption of such Bonds or on any Interest Payment Date. In the event the money in an Account in the Project Fund available for payment of the Cost of the Project shall not be sufficient to make such payment in full, the Borrower agrees to pay directly, or to deposit moneys in the Project Fund for the payment of, such costs of completing the Project as may be in excess of the moneys available therefor in the Project Fund. THE ISSUER DOES NOT MAKE ANY WARRANTY OR REPRESENTATION, EITHER EXPRESS OR IMPLIED, THAT THE MONEYS WHICH WILL BE DEPOSITED INTO THE PROJECT FUND, AND WHICH UNDER THE PROVISIONS OF THIS LOAN AGREEMENT WILL BE AVAILABLE FOR PAYMENT OF THE COST OF THE PROJECT, WILL BE SUFFICIENT TO PAY ALL OF THE COSTS WHICH WILL BE INCURRED IN
Sample 1See All (8)
AutoNDA by SimpleDocs
Establishment of Completion Date; Obligation of Borrower to Complete. As soon as the Project is completed, the Authorized Borrower Representative, on behalf of the Borrower, shall evidence the Completion Date by providing a certificate to the Trustee and the Issuer stating the Cost of the Project and further stating that (i) the acquisition, equipping and construction of the Project has been completed substantially in accordance with the plans, specifications and work orders therefor, and all labor, services, materials and supplies used in the acquisition, equipping, rehabilitation and construction have been paid or provided for, and (ii) all other facilities necessary in connection with the Project have been acquired, constructed and installed substantially in accordance with the plans and specifications and work orders therefor and all costs and expenses incurred in connection therewith have been paid or provided for. Notwithstanding the foregoing, such certificate may state that it is given without prejudice to any rights of the Borrower against third parties for any claims or for the payment of any amount not then due and payable which exists at the date of such certificate or which may subsequently exist. At the time such certificate is delivered to the Trustee, moneys remaining in the Construction Fund, including any earnings resulting from the investment of such moneys, shall be used as provided in Section 6.07 of the Indenture.
Sample 1Sample 2See All (5)
Establishment of Completion Date; Obligation of Borrower to Complete. As soon as the Construction of the Project is completed, an Authorized Representative of the Borrower, on behalf of the Borrower, shall evidence the completion date by providing a certificate to the Trustee, with a copy to the Authority and the Bank, stating the Costs of the Project and further stating that (a) Construction of the Project has been completed substantially in accordance with the plans and specifications therefor, and all labor, services, materials and supplies used in Construction have been paid for or stating the amount required to be retained in the Project Fund to fully provide for any disputed amounts, and (b) all other equipment and facilities for the operation of the Project have been acquired, constructed and installed in accordance with the plans and specifications therefor and all costs and expenses incurred in connection therewith have been paid or provided for. Notwithstanding the foregoing, such certificate may state that it is given without prejudice to any rights of the Borrower against third parties.
Sample 1
Establishment of Completion Date; Obligation of Borrower to Complete. Upon the final disbursement from the Project Fund, an Authorized Representative of the Borrower, on behalf of the Borrower, shall evidence the Completion Date by providing a Final Project Completion Certificate, substantially in the form attached hereto as Exhibit C, to the Trustee and the Authority.
Sample 1Sample 2
Establishment of Completion Date; Obligation of Borrower to Complete. As soon as the Project is completed, the Authorized Borrower Representative, on behalf of the Borrower, shall evidence the Completion Date by providing a certificate to the Trustee and the Issuer stating the Cost of the Project and further stating that (i) the acquisition, equipping and construction of the Project has been completed substantially in accordance with the plans, specifications and work orders therefor, and all labor, services, materials and supplies used in the acquisition, equipping, rehabilitation and construction have been paid or provided for, and (ii) all other facilities necessary in connection with the Project have been acquired, constructed and installed in accordance with the plans and specifications and work orders therefor and all costs and expenses incurred in connection therewith have been paid or provided for. Notwithstanding the foregoing, such certificate may state that it is given without prejudice to any rights of the Borrower against third parties for any claims or for the payment of any amount not then due and payable which exists at the date of such certificate or which may subsequently exist. At the time
Sample 1
Establishment of Completion Date; Obligation of Borrower to Complete. As soon as the Construction of the Project is completed, an Authorized Representative of the Borrower, on behalf of the Borrower, shall evidence the completion date by providing a certificate to the Trustee, with a copy to the Authority, stating the Costs of the Project and further stating that (i) Construction of the Project has been completed substantially in accordance with the plans and specifications therefor, and all labor, services, materials and supplies used in Construction have been paid for or stating the amount required to be retained in the Project Fund to fully provide for any disputed amounts, and (ii) all other equipment and facilities for the operation of the Project have been acquired, constructed and installed in accordance with the plans and specifications therefor and all costs and expenses incurred in connection therewith have been paid or provided for. Notwithstanding the foregoing, such certificate may state that it is given without prejudice to any rights of the Borrower against third parties. At the time such certificate is delivered to the Trustee, moneys remaining in the Project Fund, less an amount representing a reasonable retainage determined by the Borrower,
Sample 1

Related to Establishment of Completion Date; Obligation of Borrower to Complete

  • Condition of Borrowers Each Guarantor acknowledges and agrees that it has the sole responsibility for, and has adequate means of, obtaining from the Borrowers and any other guarantor such information concerning the financial condition, business and operations of the Borrowers and any such other guarantor as such Guarantor requires, and that none of the Secured Parties has any duty, and such Guarantor is not relying on the Secured Parties at any time, to disclose to it any information relating to the business, operations or financial condition of the Borrowers or any other guarantor (each Guarantor waiving any duty on the part of the Secured Parties to disclose such information and any defense relating to the failure to provide the same).

  • Evidence of Compliance with Conditions Precedent The Guarantor shall provide to the Guarantee Trustee such evidence of compliance with such conditions precedent, if any, provided for in this Guarantee Agreement that relate to any of the matters set forth in Section 314(c) of the Trust Indenture Act. Any certificate or opinion required to be given by an officer pursuant to Section 314(c)(1) may be given in the form of an Officers' Certificate.

  • Authorization of Borrowing Etc (a) Each Obligor has duly authorized by all necessary corporate action the execution, delivery and performance of the Loan Documents to which it is a party. The execution, delivery and performance by each Obligor of the Loan Documents to which it is a party and the consummation of the transactions contemplated by the Loan Documents to which it is a party do not and will not (i) (A) violate any provision of any law or any governmental rule or regulation or order applicable to or binding on such Obligor, (B) violate any provision of the Certificate or Articles of Incorporation or Bylaws of such Obligor, (C) conflict with, result in a breach of or constitute (with due notice or lapse of time or both) a default under any Contractual Obligation of such Obligor or any of its Subsidiaries except to the extent of any such violation, conflict, breach, default, or imposition of Lien (of which no Obligor has Actual Knowledge) which could not reasonably be expected to have a Material Adverse Effect, or (D) result in or require the creation or imposition of any Lien on any of the Collateral (except as permitted in the applicable Collateral Document) or on any other property (except as permitted under Section 5.13 hereof), or (ii) require any approval of stockholders or any approval or consent of any Person under any Contractual Obligation of such Obligor or any of its Subsidiaries, except for such approvals or consents which will have been obtained on or before the Closing Date, except for any such approval or consent under a Contractual Obligation and the failure to obtain which could not reasonably be expected to result in a Material Adverse Effect. (b) The execution, delivery and performance by each Obligor of the Loan Documents to which it is a party and the consummation of the transactions contemplated by the Loan Documents to which it is a party and the use of the proceeds of the Loans do not and will not require any registration with, consent or approval of, or notice to, or other action to, with or by, any federal, state or other Governmental Authority or regulatory body or any other Person which is required to be obtained or made on or prior to the Closing Date and which has not previously been obtained or made. (c) Each Obligor has duly executed and delivered each of the Loan Documents to which it is party and each such Loan Document is the legally valid and binding obligation of such Obligor, enforceable against such Obligor in accordance with its respective terms, except as may be limited by bankruptcy, insolvency, reorganization, moratorium, fraudulent transfer or other similar laws relating to or affecting the enforcement of creditors' rights generally, including materiality, reasonableness, good faith and fair dealing, and by general principles of equity (regardless of whether considered in a proceeding in equity or at law). (d) No part of the proceeds of the Loans will be used, directly or indirectly, for any purpose that entails a violation of Regulations U or X of the Federal Reserve Board.

  • to Compliance Certificate Financial Covenants of Borrower In the event of a conflict between this Schedule and the Loan Agreement, the terms of the Loan Agreement shall govern. Dated:

  • Performance of Borrowers’ Obligations Agent may, in its discretion at any time and from time to time, at Borrowers’ expense, pay any amount or do any act required of a Borrower under any Loan Documents or otherwise lawfully requested by Agent to (a) enforce any Loan Documents or collect any Obligations; (b) protect, insure, maintain or realize upon any Collateral; or (c) defend or maintain the validity or priority of Agent’s Liens in any Collateral, including any payment of a judgment, insurance premium, warehouse charge, finishing or processing charge, or landlord claim, or any discharge of a Lien. All payments, costs and expenses (including Extraordinary Expenses) of Agent under this Section shall be reimbursed to Agent by Borrowers, on demand, with interest from the date incurred to the date of payment thereof at the Default Rate applicable to Base Rate Revolver Loans. Any payment made or action taken by Agent under this Section shall be without prejudice to any right to assert an Event of Default or to exercise any other rights or remedies under the Loan Documents.

  • Condition of Borrower Each Guarantor acknowledges and agrees that it has the sole responsibility for, and has adequate means of, obtaining from the Borrower and any other guarantor such information concerning the financial condition, business and operations of the Borrower and any such other guarantor as such Guarantor requires, and that none of the Secured Parties has any duty, and such Guarantor is not relying on the Secured Parties at any time, to disclose to it any information relating to the business, operations or financial condition of the Borrower or any other guarantor (each Guarantor waiving any duty on the part of the Secured Parties to disclose such information and any defense relating to the failure to provide the same).

  • CONDITIONS OF BORROWING The obligation of each Lender to make its Loan hereunder on the Closing Date is subject to satisfaction of the following conditions precedent: (a) The Administrative Agent’s receipt of the following, each of which shall be originals or telecopies (followed promptly by originals) unless otherwise specified, each properly executed by a Responsible Officer of the signing Loan Party, each dated the Closing Date (or, in the case of certificates of governmental officials, a recent date before the Closing Date) and each in form and substance satisfactory to the Administrative Agent: (i) executed counterparts of this Agreement sufficient in number for distribution to the Administrative Agent, each Lender and the Borrower; (ii) a Note executed by the Borrower in favor of each Lender requesting a Note; (iii) such certificates of resolutions or other action, incumbency certificates and/or other certificates of Responsible Officers of each Loan Party as the Administrative Agent may require evidencing (A) the authority of each Loan Party to enter into this Agreement and the other Loan Documents to which such Loan Party is a party or is to be a party and (B) the identity, authority and capacity of each Responsible Officer thereof authorized to act as a Responsible Officer in connection with this Agreement and the other Loan Documents to which such Loan Party is a party or is to be a party; (iv) copies of each Loan Party’s Organization Documents and such other documents and certifications as the Administrative Agent may reasonably require to evidence that each Loan Party is duly organized or formed, and that each Loan Party is validly existing, in good standing and qualified to engage in business in each jurisdiction where its ownership, lease or operation of properties or the conduct of its business requires such qualification, except to the extent that failure to do so could not reasonably be expected to have a Material Adverse Effect; (v) a favorable opinion of Xxxxxx, Xxxx & Xxxxxxxx LLP, counsel to the Loan Parties, addressed to the Administrative Agent and each Lender and as to such matters concerning the Loan Parties and the Loan Documents as the Administrative Agent may reasonably request (including, without limitation, with respect to enforceability, due authorization, perfection of the Liens in favor the Collateral Agent and “no conflicts” with the First Lien Loan Documents); (vi) a certificate signed by a Responsible Officer of the Borrower certifying (a) that (1) the representations and warranties of the Loan Parties contained in Article V or any other Loan Document, or which are contained in any document furnished at any time under or in connection herewith or therewith, (A) which are qualified by materiality are true and correct, and (B) which are not qualified by materiality are true and correct in all material respects, in each case, on and as of the Closing Date, except to the extent that such representations and warranties specifically refer to an earlier date, in which case they are true and correct, or true and correct in all material respects, as the case may be, as of such earlier date and (2) no Default exists or would result from the borrowing of the Loans or from the application of the proceeds thereof, (b) that there has been no event or circumstance since May 1, 2021, that has had or could be reasonably expected to have, either individually or in the aggregate, a Material Adverse Effect, and (c) either that (1) no consents, licenses or approvals are required in connection with the execution, delivery and performance by such Loan Party and the validity against such Loan Party of the Loan Documents to which it is a party, or (2) that all such consents, licenses and approvals have been obtained and are in full force and effect; (vii) a certificate from the chief financial officer of the Borrower, satisfactory in form and substance to the Administrative Agent, attesting to the Solvency of the Borrower and its Subsidiaries on a consolidated basis as of the Closing Date after giving effect to the transactions contemplated hereby; (viii) the Perfection Certificate; (ix) the Security Documents, each duly executed by the applicable Loan Parties; (x) all other Loan Documents, each duly executed by the applicable Loan Parties; and (xi) all documents and instruments, including Uniform Commercial Code financing statements, required by law or reasonably requested by the Collateral Agent to be filed, registered or recorded to create or perfect the first priority Liens intended to be created under the Loan Documents and all such documents and instruments shall have been so filed, registered or recorded, in each case, to the reasonable satisfaction of the Collateral Agent. (b) The Administrative Agent and each Lender shall have received all documentation and other information required by regulatory authorities under applicable “know your customer” and anti-money laundering rules and regulations, including without limitation the USA PATRIOT Act (Title III of Pub. L. 107-56 (signed into law October 26, 2001)) (the “Patriot Act”). (c) The Administrative Agent and each Lender shall have received all fees and other amounts due and payable to them by the Borrower on or prior to the Closing Date, including, to the extent invoiced, reimbursement or payment of all reasonable and documented out-of-pocket fees and expenses (including the legal fees and expenses of King & Spalding LLP, Xxxxxxxx & Xxxxx LLP and Xxxxx Xxxxxxx Xxxxxx & Ashton LLP, counsel to the Agents and the Lenders, as applicable); provided that, in the case of costs and expenses, an invoice for all such fees and expenses shall be received by the Borrower at least one (1) Business Day prior to the Closing Date for payment to be required as a condition to the Closing Date. Without limiting the generality of the provisions of Section 9.04, for purposes of determining compliance with the conditions specified in this Section 4.01, each Lender that has signed this Agreement shall be deemed to have Consented to, approved or accepted or to be satisfied with, each document or other matter required thereunder to be Consented to or approved by or acceptable or satisfactory to a Lender unless the Administrative Agent shall have received notice from such Lender prior to the proposed Closing Date specifying its objection thereto.

  • Conditions Precedent to the Initial Extension of Credit The obligation of each Lender to make the initial extensions of credit provided for hereunder is subject to the fulfillment, to the satisfaction of Agent and each Lender, of each of the conditions precedent set forth on Schedule 3.1 to this Agreement (the making of such initial extensions of credit by a Lender being conclusively deemed to be its satisfaction or waiver of the conditions precedent).

  • Compliance of Agreement, Loan Documents and Borrowing with Laws, Etc The execution, delivery and performance by each Credit Party of the Loan Documents to which each such Person is a party, in accordance with their respective terms, the Extensions of Credit hereunder and the transactions contemplated hereby or thereby do not and will not, by the passage of time, the giving of notice or otherwise, (a) require any Governmental Approval or violate any Applicable Law relating to any Credit Party where the failure to obtain such Governmental Approval or such violation could reasonably be expected to have a Material Adverse Effect, (b) conflict with, result in a breach of or constitute a default under the articles of incorporation, bylaws or other organizational documents of any Credit Party, (c) conflict with, result in a breach of or constitute a default under any indenture, agreement or other instrument to which such Person is a party or by which any of its properties may be bound or any Governmental Approval relating to such Person, which could, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, (d) result in or require the creation or imposition of any Lien upon or with respect to any property now owned or hereafter acquired by such Person other than Permitted Liens or (e) require any consent or authorization of, filing with, or other act in respect of, an arbitrator or Governmental Authority and no consent of any other Person is required in connection with the execution, delivery, performance, validity or enforceability of this Agreement, other than (i) consents, authorizations, filings or other acts or consents previously obtained or for which the failure to obtain or make could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect and (ii) consents or filings under the UCC or other security filings.

  • Calculation of Borrowing Base For purposes of this Agreement, the “Borrowing Base” shall be determined, as at any date of determination, as the sum of the Advance Rates of the Value of each Portfolio Investment (excluding any Cash Collateral held by the Administrative Agent pursuant to Section 2.05(k) or the last paragraph of Section 2.09(a)); provided that: (a) the Advance Rate applicable to that portion of the aggregate Value of the Portfolio Investments in a consolidated group of corporations or other entities (collectively, a “Consolidated Group”), in accordance with GAAP, that exceeds 10% of Shareholders’ Equity of the Borrower (which, for purposes of this calculation shall exclude the aggregate amount of investments in, and advances to, Financing Subsidiaries) shall be 50% of the Advance Rate otherwise applicable; provided that, with respect to the Portfolio Investments in a single Consolidated Group designated by the Borrower to the Administrative Agent such 10% figure shall be increased to 12.5%; (b) the Advance Rate applicable to that portion of the aggregate Value of the Portfolio Investments of all issuers in a Consolidated Group exceeding 20% of Shareholders’ Equity of the Borrower (which, for purposes of this calculation shall exclude the aggregate amount of investments in, and advances to, Financing Subsidiaries) shall be 0%; (c) the Advance Rate applicable to that portion of the aggregate Value of the Portfolio Investments in any single Industry Classification Group that exceeds 20% of Shareholders’ Equity of the Borrower (which for purposes of this calculation shall exclude the aggregate amount of investments in, and advances to, Financing Subsidiaries) shall be 0%; provided that, with respect to the Portfolio Investments in a single Industry Classification Group from time to time designated by the Borrower to the Administrative Agent such 20% figure shall be increased to 30% and, accordingly, only to the extent that the Value for such single Industry Classification Group exceeds 30% of the Shareholders’ Equity shall the Advance Rate applicable to such excess Value be 0%; (d) no Portfolio Investment may be included in the Borrowing Base unless the Collateral Agent maintains a first priority, perfected Lien (subject to Permitted Liens) on such Portfolio Investment and such Portfolio Investment has been Delivered (as such term is used in and to the extent required under Section 7.01(a) of the Guarantee and Security Agreement) to the Collateral Agent, and then only for so long as such Portfolio Investment continues to be Delivered as contemplated therein; (e) the portion of the Borrowing Base attributable to Performing Non-Cash Pay High Yield Securities, Performing Non-Cash Pay Mezzanine Investments, Equity Interests and Non-Performing Portfolio Investments shall not exceed 20%; (f) the portion of the Borrowing Base attributable to Equity Interests shall not exceed 10% (it being understood that in no event shall Equity Interests of Financing Subsidiaries be included in the Borrowing Base); (g) the portion of the Borrowing Base attributable to Non-Performing Portfolio Investments shall not exceed 15% and the portion of the Borrowing Base attributable to Portfolio Investments that were Non-Performing Portfolio Investments at the time such Portfolio Investments were acquired shall not exceed 5%; and (h) the portion of the Borrowing Base attributable to Portfolio Investments invested outside the United States, Canada, the United Kingdom, Australia, Germany, France, Belgium, the Netherlands, Luxembourg, Switzerland, Denmark, Finland, Norway and Sweden shall not exceed 5% without the consent of the Administrative Agent. As used herein, the following terms have the following meanings:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!