Evidence of Financial Capability; Construction Loan Documents Sample Clauses

Evidence of Financial Capability; Construction Loan Documents. Prior to the commencement of the lease, Lessee shall submit to the City Manager or his or her designee evidence that Lessee has the financial capability necessary to develop the Hotel (herein, "Evidence of Financial Capability"). Such Evidence of Financial Capability shall include without limitation each of the following: (i) a detailed budget showing Lessee's estimated Project Costs (the "Project Budget"); (ii) a financial statement and/or other documentation reasonably satisfactory to Lessor sufficient to demonstrate that Lessee has adequate funds committed to cover the costs set forth in the Project Budget and that such funds will be in Lessee's account as of the Commencement Date; (iii) draft construction loan documents; (v) a copy of the lump sum construction contract or contracts between Lessee and its general contractor(s) for the Hotel, certified by Lessee to be a true and correct copy thereof, covering all of the excavation, grading, demolition, and construction work comprising the Hotel, including without limitation all related utility and offsite work (the "Project Construction Contract"); and (vi) a corporate surety bond or bonds or other security instrument, approved as to form, content, and company by the City Engineer and City Attorney with Lessee's contractor or contractors as xxxxxxxx0(s), in a penal sum not less than one hundred twenty five percent (125%) of the estimated cost of constructing improvements in the public rights-of-way in connection with the construction of the Hotel guaranteeing completion of construction and the payment of wages for services engaged and bills contracted for materials, supplies, and equipment used in the performance of the work, and protecting Lessee and Lessor from any liability, losses, or damages arising therefrom (the "Project Security Instruments"), provided, however, that the City Manager or his or her designee shall have the discretion on behalf of Lessor to accept alternate security in his or her sole and absolute discretion.
Sample 1
AutoNDA by SimpleDocs

Related to Evidence of Financial Capability; Construction Loan Documents

  • Compliance of Agreement, Loan Documents and Borrowing with Laws, Etc The execution, delivery and performance by each Credit Party of the Loan Documents to which each such Person is a party, in accordance with their respective terms, the Extensions of Credit hereunder and the transactions contemplated hereby or thereby do not and will not, by the passage of time, the giving of notice or otherwise, (a) require any Governmental Approval or violate any Applicable Law relating to any Credit Party where the failure to obtain such Governmental Approval or such violation could reasonably be expected to have a Material Adverse Effect, (b) conflict with, result in a breach of or constitute a default under the articles of incorporation, bylaws or other organizational documents of any Credit Party, (c) conflict with, result in a breach of or constitute a default under any indenture, agreement or other instrument to which such Person is a party or by which any of its properties may be bound or any Governmental Approval relating to such Person, which could, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, (d) result in or require the creation or imposition of any Lien upon or with respect to any property now owned or hereafter acquired by such Person other than Permitted Liens or (e) require any consent or authorization of, filing with, or other act in respect of, an arbitrator or Governmental Authority and no consent of any other Person is required in connection with the execution, delivery, performance, validity or enforceability of this Agreement, other than (i) consents, authorizations, filings or other acts or consents previously obtained or for which the failure to obtain or make could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect and (ii) consents or filings under the UCC or other security filings.

  • Compliance with Loan Documents Borrowers will comply in all material respects with any and all covenants and provisions of this Loan Agreement, the Notes and all other of the Loan Documents.

  • No Responsibility for Advances, Creditworthiness, Collateral, Recitals, Etc [Intentionally Omitted. See Sections 7.03 and 7.04 of the Credit Agreement for these provisions.]

  • DESTRUCTION OF BORROWER'S DOCUMENTS Any documents, schedules, invoices or other papers delivered to Bank, may be destroyed or otherwise disposed of by Bank six (6) months after they are delivered to or received by Bank, unless Borrower requests, in writing, the return of the said documents, schedules, invoices or other papers and makes arrangements, at Borrower's expense, for their return.

  • Reference to and Effect on the Credit Agreement and the Other Loan Documents (i) On and after the effective date of this Amendment, each reference in the Credit Agreement to “this Agreement”, “hereunder”, “hereof”, “herein” or words of like import referring to the Credit Agreement and each reference in the other Loan Documents to the “Credit Agreement”, “thereunder”, “thereof” or words of like import referring to the Credit Agreement shall mean and be a reference to the Credit Agreement as amended hereby. (ii) Except as specifically amended by this Amendment, the Credit Agreement and the other Loan Documents shall remain in full force and effect and are hereby ratified and confirmed. (iii) The execution, delivery and performance of this Amendment shall not, except as expressly provided herein, constitute a waiver of any provision of, or operate as a waiver of any right, power or remedy of Administrative Agent or any Lender under the Credit Agreement or any of the other Loan Documents.

  • Non-Compliance with Loan Documents (a) Failure by any Loan Party to comply with or to perform any covenant set forth in Section 10.1.5, 10.3(b), 10.5 or 10.9 or Section 11; or (b) failure by any Loan Party to comply with or to perform any other provision of this Agreement or any other Loan Document (and not constituting an Event of Default under any other provision of this Section 13) and continuance of such failure described in this clause (b) for 30 days.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.

  • Reference to and Effect on the Credit Agreement and the Loan Documents (a) On and after the effectiveness of this Amendment, each reference in the Credit Agreement to “this Agreement”, “hereunder”, “hereof” or words of like import referring to the Credit Agreement, and each reference in the Notes and each of the other Loan Documents to “the Credit Agreement”, “thereunder”, “thereof” or words of like import referring to the Credit Agreement, shall mean and be a reference to the Credit Agreement, as amended by this Amendment. (b) Each of the Credit Agreement, the Notes and each of the other Loan Documents, as specifically amended by this Amendment, is and shall continue to be in full force and effect and is hereby in all respects ratified and confirmed. Without limiting the generality of the foregoing, the Guaranty does and shall continue to guarantee the Guaranteed Obligations, in each case, as amended by this Amendment. (c) The execution, delivery and effectiveness of this Amendment shall not, except as expressly provided herein, operate as a waiver of any right, power or remedy of any Lender or the Administrative Agent under any of the Loan Documents, nor constitute a waiver of any provision of any of the Loan Documents. On and after the effectiveness of this Amendment, this Amendment shall for all purposes constitute a Loan Document.

  • No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!