Excessive Force Majeure Sample Clauses

Excessive Force Majeure. A. Purchaser may, upon written notice to Contractor (“Notice of Termination for Excessive Force Majeure”), immediately terminate this Contract, in whole or in part: if either: (i) Contractor fails to Deliver the Satellite by the date specified in Article 3.1 for Delivery of the Satellite plus [*] due to a Force Majeure in accordance with Article 17, or (ii) the cumulative delay in failure to Deliver the Satellite due to Contractor Force Majeure plus any other non-excused Contractor delay in Delivery of the Satellite by the date specified in Article 3.1 for Delivery of the Satellite shall equal or exceed [*] Upon the occurrence of any of these events and issuance by Purchaser of a Notice of Termination for Excessive Force Majeure, Purchaser shall have the right to terminate the Contract in whole or in part and the rights and obligations of the Parties shall be the same [*]. After the occurrence of an event that would otherwise entitle Purchaser to deliver Notice of Termination for Excessive Force Majeure, Contractor shall have the right to deliver a written request to Purchaser that Purchaser advise Contractor whether Purchaser will deliver the Notice of Termination for Excessive Force Majeure. Within thirty (30) days of receipt of Contractor’s written request, Purchaser will notify Contractor as to its decision to either terminate this Contract or to waive its rights to terminate for such Excessive Force Majeure provided that it shall be a condition to any obligation of Purchaser to provide the requested notice of election that Contractor unconditionally acknowledge Purchaser’s rights to terminate in accordance with this Article 23.3. Failure of Purchaser to provide such requested notice of election in the thirty (30) day period specified above [*] CONFIDENTIAL TREATMENT REQUESTED BY ICO GLOBAL COMMUNICATIONS (HOLDINGS) LIMITED. shall be deemed to be a waiver of Purchaser’s rights to terminate for such Excessive Force Majeure under this Article 23.3.
Sample 1Sample 2
AutoNDA by SimpleDocs
Excessive Force Majeure. A Party may, upon written notice to the other Parties, immediately terminate this Contract, in whole or in part, if and when: (i) a delay in the other Party’s performance of its obligations hereunder exceeds six months due to one or more Force Majeure Events under Section 17.1, or (ii) it becomes reasonably certain that the aggregate delay due to Force Majeure Events under Section 17 will exceed six months.
Sample 1Sample 2
Excessive Force Majeure. Purchaser may, upon written notice to Contractor, immediately terminate this Contract, in whole or in part, if and when: (i) delay in Contractor’s performance of its obligations hereunder exceeds one year due to Force Majeure events under Article 17.3 or (ii) it becomes reasonably certain that the aggregate delay due to Force Majeure events under Article 17.3 will exceed one year; or (iii) Contractor notifies Purchaser that it is [Use or disclosure of the data contained on this page is subject to the restrictions set forth in this Contract.]
Sample 1
Excessive Force Majeure. 22.3.1 [***REDACTED***]
Sample 1
Excessive Force Majeure. TerreStar may, upon written notice to Contractor, immediately terminate this Contract, in whole or in part, if and when: (i) a delay in Contractor’s performance of its obligations hereunder exceeds ninety (90) days due to one or more Force Majeure Events under Article 20.A, or (ii) it becomes reasonably certain that the aggregate delay due to Force Majeure Events under Article 20.A will exceed ninety (90) days; or (iii) Contractor notifies TerreStar that it is reasonably certain that delay in Contractor’s performance of its obligations hereunder due to Force Majeure events under Article 20.A will exceed ninety (90) days. Upon the occurrence of any of these events, if Contractor fails to provide TerreStar with a recovery plan reasonably acceptable to TerreStar, TerreStar may provide Contractor written notice of termination. For the avoidance of doubt, TerreStar may elect not to accept any such recovery plan in its sole discretion if it is likely to cause more than thirty (30) days of additional delay beyond the end of such ninety (90)-day period.
Sample 1

Related to Excessive Force Majeure

  • Force Majeure In no event shall the Trustee be responsible or liable for any failure or delay in the performance of its obligations hereunder arising out of or caused by, directly or indirectly, forces beyond its control, including, without limitation, strikes, work stoppages, accidents, acts of war or terrorism, civil or military disturbances, nuclear or natural catastrophes or acts of God, and interruptions, loss or malfunctions of utilities, communications or computer (software and hardware) services; it being understood that the Trustee shall use reasonable efforts which are consistent with accepted practices in the banking industry to resume performance as soon as practicable under the circumstances.

  • Force Majeur Except with respect to obligations to make payments hereunder, neither party shall be deemed in default hereunder, nor shall it hold the other party responsible for, any cessation, interruption or delay in the performance of its obligations hereunder due to causes beyond its reasonable control including, but not limited to: earthquake, flood, fire, storm or other natural disaster, act of God, labor controversy or threat thereof, civil disturbance or commotion, disruption of the public markets, war or armed conflict or the inability to obtain sufficient material, supplies, labor, transportation, power or other essential commodity or service required in the conduct of its business, including internet access, or any change in or the adoption of any law, ordinance, rule, regulation, order, judgment or decree.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Force Majeure Events The Parties shall be excused from any failure to perform any obligation hereunder to the extent such failure is caused by a Force Majeure Event. A Force Majeure Event shall operate to excuse a failure to perform an obligation hereunder only for the period of time during which the Force Majeure Event renders performance impossible or infeasible and only if the Party asserting Force Majeure as an excuse for its failure to perform has provided written notice to the other Party specifying the obligation to be excused and describing the events or conditions constituting the Force Majeure Event. As used herein, “Force Majeure Event” means the occurrence of an event or circumstance beyond the reasonable control of the party failing to perform, including, without limitation, (a) explosions, fires, flood, earthquakes, catastrophic weather conditions, or other elements of nature or acts of God; (b) acts of war (declared or undeclared), acts of terrorism, insurrection, riots, civil disorders, rebellion or sabotage; (c) acts of federal, state, local or foreign governmental authorities or courts; (d) labor disputes, lockouts, strikes or other industrial action, whether direct or indirect and whether lawful or unlawful; (e) failures or fluctuations in electrical power or telecommunications service or equipment; and (f) delays caused by the other Party’s nonperformance hereunder.

  • Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—

  • MAJEURE A party is not liable for failure to perform the party’s obligations if such failure is as a result of acts of God (including fire, flood, earthquake, storm, hurricane or other natural disaster), pandemic, war, invasion, act of foreign enemies, hostilities (regardless of whether war is declared), civil war, rebellion, revolution, insurrection, military or usurped power or confiscation, terrorist activities, nationalization, decrees of a court, tribunal or governmental authority, government sanction, blockage, embargo, labor dispute, strike, or lockout. If a party asserts any force majeure as an excuse for failure to perform, such non-performing party must prove that it took reasonable steps to minimize delay or damages caused by foreseeable events and that the other Party was timely notified of the likelihood or actual occurrence of a force majeure event. In the event of non-performance and/or termination pursuant to this Section 8.16, notwithstanding any other provision of this Agreement, the Xxxxxxx Money shall be returned to the Operating Partnership in full.

  • No Force Majeure Event There shall not have been any delay, error, failure or interruption in the conduct of the business of the Acquiror Company, or any loss, injury, delay, damage, distress, or other casualty, due to force majeure including but not limited to (a) acts of God; (b) fire or explosion; (c) war, acts of terrorism or other civil unrest; or (d) national emergency.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Unavoidable Delay Except for the monetary obligations of Tenant under this Lease, neither party shall be chargeable with, liable for, or responsible to the other for anything or in any amount for any Unavoidable Delay and any Unavoidable Delay shall not be deemed a breach of or default in the performance of this Lease, it being specifically agreed that any time limit provision contained in this Lease (other than the scheduled expiration of the Term) shall be extended for the same period of time lost by Unavoidable Delay.

  • Termination for Force Majeure In the event of a force majeure that lasts longer than thirty (30) days from the date that a Party claiming relief due to the force majeure event gives notice to the other Party, the Party not claiming relief under the force majeure event may terminate this Agreement upon written notice to the other Party. For the avoidance of doubt, the COVID-19 pandemic does not constitute a force majeure event.

Time is Money Join Law Insider Premium to draft better contracts faster.