Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the contractor, contractor's subcontractors, or their agents or employees.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Notice of Decision If the Plan Administrator denies part or all of the claim, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth: (a) The specific reasons for the denial; (b) A reference to the specific provisions of the Agreement on which the denial is based; (c) A description of any additional information or material necessary for the claimant to perfect the claim and an explanation of why it is needed; (d) An explanation of the Agreement’s review procedures and the time limits applicable to such procedures; and (e) A statement of the claimant’s right to bring a civil action under ERISA Section 502(a) following an adverse benefit determination on review.
Failure to Provide Notice of Expiry If the HSP fails to provide the required 6 months’ Notice that it intends to allow this Agreement to expire, or fails to provide a Transition Plan along with any such Notice, this Agreement shall automatically be extended and the HSP will continue to provide the Services under this Agreement for so long as the Funder may reasonably require to enable all clients of the HSP to transition to new service providers.
Failure to Complete If Artist becomes ill, dies, or is otherwise unable or unwilling to complete the Project in accordance with the Agreement, any work already done on the Project will be the City’s property. The City will be entitled to withhold any sums not yet paid to Artist, and may use any such sums toward completion of the Project in any manner the City deems appropriate.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Failure to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
Borrower’s Failure to Notify If the Borrower fails to give notice pursuant to Section 1.6(a) above of the continuation or conversion of any outstanding principal amount of a Borrowing of Eurodollar Loans before the last day of its then current Interest Period within the period required by Section 1.6(a) and such Borrowing is not prepaid in accordance with Section 1.8(a), the Borrower shall be deemed to have given the notice three (3) Business Days prior to the end of the then current Interest Period and such Borrowing shall automatically be continued as a Borrowing of a Eurodollar Loan with a one (1) month Interest Period; provided that all Lenders are able to accommodate such one (1) month Interest Period and such Eurodollar Loan shall be subject to the funding indemnity set forth in Section 1.11 hereof in the event it is prepaid prior to the end of the Interest Period. In the event the Borrower fails to give notice pursuant to Section 1.6(a) above of a Borrowing equal to the amount of a Reimbursement Obligation and has not notified the Administrative Agent by 12:00 noon (Chicago time) on the day such Reimbursement Obligation becomes due that it intends to repay such Reimbursement Obligation through funds not borrowed under this Agreement, the Borrower shall be deemed to have requested a Borrowing of Base Rate Loans under the Revolving Credit (or at the option of the Swing Line Lender under the Swing Line) on such day in the amount of the Reimbursement Obligation then due, which Borrowing shall be applied to pay the Reimbursement Obligation then due.
Failure to Report No compensation shall be granted for the total period of standby if the employee is unable to report for duty when required.
Notice of Violation The Concessioner shall give the Director in writing immediate notice of any written threatened or actual notice of violation from other regulatory agencies of any Applicable Law arising out of the activities of the Concessioner, its agents or employees.
