Remedies for Contractor Breach Pertaining to contract-related issues, it is the responsibility of both the Agency and the Contractor to communicate with each in as clear and complete a manner as possible. If at any time during the term of this contract the Agency or the Contractor is not satisfied with any issue, it is the responsibility of that party to deliver to the other party communication, in writing, fully detailing the issue and corrective action (please note that the Agency has the right to issue unilateral addendums to this contract, but the Contractor does not have the same right). The other party shall, within 10 days, respond in writing to the other party (however, the Agency shall retain the right to, if conditions warrant, require the Contractor to respond in a shorter period of time). Further, the Agency shall, at a minimum, employ the following steps in dealing with the Contractor as to any performance issues:
Remedies and Termination In addition to any other of RIM’s rights or remedies set forth in this Agreement:
No Waiver of Obligations No change, waiver or discharge of any liability or obligation hereunder on any one or more occasions shall be deemed a waiver of performance of any continuing or other obligation, or shall prohibit enforcement of any obligation, on any other occasion.
Remedies for Breach of Obligation of Confidentiality Each party acknowledges that breach of its obligation of confidentiality may give rise to irreparable injury to the other party, which damage may be inadequately compensable in the form of monetary damages. Accordingly, a party may seek and obtain injunctive relief against the breach or threatened breach of the foregoing undertakings, in addition to any other legal remedies which may be available, to include, in the case of the State, at the sole election of the State, the immediate termination, without liability to the State, of this Contract or any Statement of Work corresponding to the breach or threatened breach.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
Breach of Covenants If the Company breaches any of the covenants set forth in this Section 4, and in addition to any other remedies available to the Buyer pursuant to this Agreement, it will be considered an event of default under Section 3.4 of the Note.
Survival and Enforceability of this Arbitration Clause This Arbitration Clause shall survive the expiration or termination, or any transfer, of the warranty on your unit. If any part of this Arbitration Clause, except waivers of class-action rights, is found to be unenforceable for any reason, the remainder of this clause and the warranty shall remain enforceable. If, in a case in which class-action allegations have been made, the waiver of class-action rights under this warranty is found to be unenforceable with respect to any part of the dispute, the parts of the dispute as to which the waiver of class-action rights have been found unenforceable will be severed and will proceed in court without reference or application of this Arbitration Clause. Any remaining parts will proceed in arbitration.
APPLICANT’S OBLIGATION TO MAINTAIN VIABLE PRESENCE In order to receive and maintain the limitation authorized by Section 2.4 in addition to the other obligations required by this Agreement, the Applicant shall Maintain Viable Presence in the District commencing at the start of the Tax Limitation Period through the Final Termination Date of this Agreement. Notwithstanding anything contained in this Agreement to the contrary, the Applicant shall not be in breach of, and shall not be subject to any liability for failure to Maintain Viable Presence to the extent such failure is caused by Force Majeure, provided the Applicant makes commercially reasonable efforts to remedy the cause of such Force Majeure.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Failure to Vacate If the Resident does not vacate the Residence on the expiry or early termination of this Agreement, (i) the Resident is liable for any financial loss sustained or incurred by the Institution or the Manager, and (ii) the Manager may remove the property of the Resident from the Room (whether or not the Resident is present at the time), and place the property in temporary storage in a location in the Residence of the Manager’s choice, at the Resident’s expense, without notice to the Resident and without liability to the Manager for any damage to or loss of the Resident’s property.
