Child Abuse Reporting Requirement Grantee will: a. comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse. b. develop, implement and enforce a written policy that includes at a minimum the System Agency’s Child Abuse Screening, Documenting, and Reporting Policy for Grantees/Providers and train all staff on reporting requirements. c. use the System Agency Child Abuse Reporting Form located at xxxxx://xxx.xxxx.xxxxx.xx.xx/Contact Us/report abuse.asp as required by the System Agency. d. retain reporting documentation on site and make it available for inspection by the System Agency.
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse. B. Grantee shall use the Texas Abuse Hotline Website located at xxxxx://xxx.xxxxxxxxxxxxxx.xxx/Login/Default.aspx as required by the System Agency. Grantee shall retain reporting documentation on site and make it available for inspection by the System Agency.
Specific Requirements compensation insurance with statutory limits required by South Dakota law. Coverage B-Employer’s Liability coverage of not less than $500,000 each accident, $500,000 disease-policy limit, and $500,000 disease-each employee.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Quality Assurance Requirements There are no special Quality Assurance requirements under this Agreement.
Training Requirements Grantee shall: A. Authorize and require staff (including volunteers) to attend training, conferences, and meetings as directed by DSHS; B. Appropriately budget funds in order to meet training requirements in a timely manner, and ensure that staff and volunteers are trained as specified in the training requirements listed at xxxxx://xxx.xxxx.xxxxx.xxx/hivstd/training/ and as otherwise specified by DSHS. Grantee shall document that these training requirements are met; and C. Ensure that staff hired for HIV and syphilis testing are trained to perform blood draws within three (3) months of employment.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
DRUG-FREE WORKPLACE REQUIREMENTS Contractor will comply with the requirements of the Drug-Free Workplace Act of 1990 and will provide a drug-free workplace by taking the following actions: a. Publish a statement notifying employees that unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited and specifying actions to be taken against employees for violations. b. Establish a Drug-Free Awareness Program to inform employees about: 1) the dangers of drug abuse in the workplace; 2) the person's or organization's policy of maintaining a drug-free workplace; 3) any available counseling, rehabilitation and employee assistance programs; and, 4) penalties that may be imposed upon employees for drug abuse violations. c. Every employee who works on the proposed Agreement will: 1) receive a copy of the company's drug-free workplace policy statement; and, 2) agree to abide by the terms of the company's statement as a condition of employment on the Agreement. Failure to comply with these requirements may result in suspension of payments under the Agreement or termination of the Agreement or both and Contractor may be ineligible for award of any future State agreements if the department determines that any of the following has occurred: the Contractor has made false certification, or violated the certification by failing to carry out the requirements as noted above. (Gov. Code §8350 et seq.)
Program Requirements The parties shall comply with the Disadvantaged Business Enterprise Program requirements established in 49 CFR Part 26.
Minimum Standard of Treatment 1. Each Party shall accord to a covered investment treatment in accordance with the customary international law minimum standard of treatment of aliens, including fair and equitable treatment and full protection and security. 2. The concepts of “fair and equitable treatment” and “full protection and security” in paragraph 1 do not require treatment in addition to or beyond that which is required by the customary international law minimum standard of treatment of aliens. 3. A breach of another provision of this Agreement, or of a separate international agreement, does not establish that there has been a breach of this Article.