Technical Specifications and Drawings a) The Goods and Related Services supplied under this Contract shall conform to the technical specifications and standards mentioned in Section VI, Schedule of Requirements and, when no applicable standard is mentioned, the standard shall be equivalent or superior to the official standards whose application is appropriate to the Goods' country of origin.
b) The Supplier shall be entitled to disclaim responsibility for any design, data, drawing, specification or other document, or any modification thereof provided or designed by or on behalf of the Procuring Entity, by giving a notice of such disclaimer to the Procuring Entity.
c) Wherever references are made in the Contract to codes and standards in accordance with which it shall be executed, the edition or the revised version of such codes and standards shall be those specified in the Schedule of Requirements. During Contract execution, any changes in any such codes and standards shall be applied only after approval by the Procuring Entity and shall be treated in accordance with GCC Clause 33.
Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents.
9.2 Materials or Work described in words that so applied have a well-known technical or trade meaning shall be deemed to refer to recognized standards, unless noted otherwise.
9.3 Trade Name or Trade Term It is not the intention of the Contract Documents to go into detailed descriptions of any materials and/or methods commonly known to the trade under “trade name” or “trade term.” The mere mention or notation of “trade name” or “trade term” shall be considered a sufficient notice to Developer that it will be required to complete the work so named, complete, finished, and operable, with all its appurtenances, according to the best practices of the trade.
9.4 The naming of any material and/or equipment shall mean furnishing and installing of same, including all incidental and accessory items thereto and/or labor therefor, as per best practices of the trade(s) involved, unless specifically noted otherwise.
9.5 Contract Documents are complementary, and what is called for by one shall be binding as if called for by all. As such, Drawings and Specifications are intended to be fully cooperative and to agree. However, if Developer observes that Drawings and Specifications are in conflict with the Contract Documents, Developer shall promptly notify District and Architect in writing, and any necessary changes shall be made as provided in the Contract Documents.
9.6 Figured dimensions shall be followed in preference to scaled dimensions, and Developer shall make all additional measurements necessary for the work and shall be responsible for their accuracy. Before ordering any material or doing any work, each Developer shall verify all measurements at the building and shall be responsible for the correctness of same.
9.7 Should any question arise concerning the intent or meaning of the Contract Documents, including the Plans and Specifications, the question shall be submitted to the District for interpretation. If a conflict exists in the Contract Documents, these Construction Provisions shall control over the Facilities Lease, which shall control over the Site Lease, which shall control over Division 1 Documents, which shall control over Division 2 through Division 49 documents, which shall control over figured dimensions, which shall control over large-scale drawings, which shall control over small-scale drawings. In no case shall a document calling for lower quality and/or quantity of material or workmanship control. However, in the case of discrepancy or ambiguity solely between and among the Drawings and Specifications, the discrepancy or ambiguity shall be resolved in favor of the interpretation that will provide District with the functionally complete and operable Project described in the Drawings and Specifications.
9.8 Drawings and Specifications are intended to comply with all laws, ordinances, rules, and regulations of constituted authorities having jurisdiction, and where referred to in the Contract Documents, the laws, ordinances, rules, and regulations shall be considered as a part of the Contract Documents within the limits specified.
9.9 As required by Section 4-317(c), Part 1, Title 24, CCR: “Should any existing conditions such as deterioration or non-complying construction be discovered which is not covered by the DSA-approved documents wherein the finished work will not comply with Title 24, California Code of Regulations, a construction change document, or a separate set of plans and specifications, detailing and specifying the required repair work shall be submitted to and approved by DSA before proceeding with the repair work.”
Design Development Documents See Section 2, Part 1, Article 2.1.5.
Selection of Architect/Construction Drawings Landlord shall retain, on behalf of Tenant, FPBA Architects (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. Landlord shall retain, on behalf of Tenant, engineering consultants and/or design-build consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing and HYAC work of the Improvements and any relevant components of the Landlord Work. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to Landlord’s approval as more particularly set forth in Sections 3.2 and 3.3, below. Notwithstanding Landlord’s retention of the Architect and Engineers, Tenant shall be responsible for, and shall fully cooperate and coordinate in good faith with Landlord, the Architect and the Engineers to supply all of the necessary information within Tenant’s possession to allow the Architect and the Engineers to initially prepare and then complete, the Construction Drawings. Landlord hereby agrees (at no cost to Landlord) to cooperate, on a commercially reasonable basis, with Tenant to assist Tenant in the preparation of the Construction Drawings. Landlord’s review of the Construction Drawings applicable to the Improvements (as opposed to Landlord Work) and as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Improvement-related portions of such Construction Drawings are reviewed by Landlord, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in such portions of the Construction Drawings, and Tenant’s waiver and indemnity set forth in this Lease shall specifically apply to such portions of the Construction Drawings.
Design and Drawings (i) Design and Drawings shall be developed in conformity with the Specifications and Standards set forth in Schedule-D. In the event, the Contractor requires any relaxation in design standards due to restricted Right of Way in any section, the alternative design criteria for such section shall be provided for review and approval of the Authority’s Engineer.
(ii) The Contractor shall appoint a proof check consultant (the “Proof Consultant”) after proposing to the Authority a panel of three (3) names of qualified and experienced firms from whom the Authority may choose one (1) to be the Proof Consultant. Provided, however, that if the panel is not acceptable to the Authority and the reasons for the same are furnished to the Contractor, the Contractor shall propose to the Authority a revised panel of three (3) names from the firms empanelled as proof consultants by the [Ministry of Road Transport and Highways] for obtaining the consent of the Authority. The Contractor shall also obtain the consent of the Authority for two (2) key personnel of the Proof Consultant who shall have adequate experience and qualifications in highways and bridges respectively. The Authority shall, within 15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its decision, with reasons, to the Contractor, and if no such decision is conveyed within the said period, the Contractor may proceed with engaging of the Proof Consultant.
(iii) The Proof Consultant shall:
(a) evolve a systems approach with the Design Director so as to minimise the time required for final designs and construction drawings; and
(b) proof check the detailed calculations, drawings and designs, which have been approved by the Design Director.
(iv) In respect of the Contractor’s obligations with respect to the design and Drawings of the Project Highway as set forth in Schedule-I, the following shall apply:
(a) The Contractor shall prepare and submit, with reasonable promptness and in such sequence as is consistent with the Project Completion Schedule, three (3) copies each of the design and Drawings, duly certified by the Proof Consultant, to the Authority’s Engineer for its approval. Provided, however, that in respect of Major Xxxxxxx and Structures, the Authority’s Engineer may require additional drawings for approval in accordance with Good Industry Practice.
(b) by submitting the Drawings for review and approval to the Authority’s Engineer, the Contractor shall be deemed to have represented that it has determined and verified that the design and engineering, including field construction criteria related thereto, are in conformity with the Scope of the Project, the Specifications and Standards and the Applicable Laws;
(c) within 15 (fifteen) days of the receipt of the Drawings, the Authority’s Engineer shall review the same and convey its approval/observations to the Contractor with particular reference to their conformity or otherwise with the Scope of the Project and the Specifications and Standards. Provided, however that in case of a major bridge or structure, the aforesaid period of 15 (fifteen) days may be extended up to 30 (thirty) days;
(d) if the aforesaid observations of the Authority’s Engineer indicate that the Drawings are not in conformity with the Scope of the Project or the Specifications and Standards, such Drawings shall be revised by the Contractor in conformity with the provisions of this Agreement and resubmitted to the Authority’s Engineer for review and approval. The Authority’s Engineer shall give its observations, if any, within 10 (ten) days of receipt of the revised Drawings. In the event the Contractor fails to revise and resubmit such Drawings to the Authority’s Engineer for review/approval as aforesaid, the Authority’s Engineer may withhold the payment for the affected works in accordance with the provisions of Clause 19.5 (iv). If the Contractor disputes any decision, direction or determination of the Authority’s Engineer hereunder, the Dispute shall be resolved in accordance with the Dispute Resolution Procedure;
(e) no review/approval and/or observation of the Authority’s Engineer and/or its failure to review/approval and/or convey its observations on any Drawings shall relieve the Contractor of its obligations and liabilities under this Agreement in any manner nor shall the Authority’s Engineer or the Authority be liable for the same in any manner; and if errors, omissions, ambiguities, inconsistencies, inadequacies or other Defects are found in the Drawings, they and the construction works shall be corrected at the Contractor's cost, notwithstanding any approval under this Article 10;
(f) the Contractor shall be responsible for delays in submitting the Drawing as set forth in Schedule-I caused by reason of delays in surveys and field investigations, and shall not be entitled to seek any relief in that regard from the Authority; and
(g) the Contractor warrants that its designers, including any third parties engaged by it, shall have the required experience and capability in accordance with Good Industry Practice and it shall indemnify the Authority against any damage, expense, liability, loss or claim, which the Authority might incur, sustain or be subject to arising from any breach of the Contractor’s design responsibility and/or warranty set out in this Clause.
(h) the Contractor shall ensure that all the designs and drawings shall be approved from the Authority’s Engineer within 90 days (ninety) from the Appointed Date.
(v) Any cost or delay in construction arising from review/approval by the Authority’s Engineer shall be borne by the Contractor.
(vi) Works shall be executed in accordance with the Drawings provided by the Contractor in accordance with the provisions of this Clause 10.2 and the approval of the Authority’s Engineer thereon as communicated pursuant to the provisions of sub- Clause (c) & (d) of Clause 10.2 (iv). Such Drawings shall not be amended or altered without prior written notice to the Authority’s Engineer. If a Party becomes aware of an error or defect of a technical nature in the design or Drawings, that Party shall promptly give notice to the other Party of such error or defect.
(vii) Within 90 (ninety) days of the Project Completion Date, the Contractor shall furnish to the Authority and the Authority’s Engineer a complete set of as- built Drawings, in 2 (two) hard copies and in micro film form or in such other medium as may be acceptable to the Authority, reflecting the Project Highway as actually designed, engineered and constructed, including an as-built survey illustrating the layout of the Project Highway and setback lines, if any, of the buildings and structures forming part of Project Facilities.
Software and Documentation Licensee may make as many copies of the Software necessary for it to use the Software as licensed. Each copy of the Software made by Licensee must contain the same copyright and other notices that appear on the original copy. Licensee will not modify the Documentation. Documentation may: (a) only be used to support Licensee’s use of the Software; (b) not be republished or redistributed to any unauthorized third party; and (c) not be distributed or used to conduct training for which Licensee, or any other party, receives a fee. Licensee will not copy any system schema reference document related to the Software.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Agreement to Repay Letter of Credit Drawings (a) The Borrower agrees to reimburse each Issuing Lender, by making payment to the Administrative Agent in immediately available funds at the Payment Office, for any payment or disbursement made by such Issuing Lender under any Letter of Credit issued by it (each such amount, so paid until reimbursed by the Borrower, an “Unpaid Drawing”), not later than one Business Day following receipt by the Borrower of notice of such payment or disbursement (provided that no such notice shall be required to be given if a Default or an Event of Default under Section 11.05 shall have occurred and be continuing, in which case the Unpaid Drawing shall be due and payable immediately without presentment, demand, protest or notice of any kind (all of which are hereby waived by the Borrower)), with interest on the amount so paid or disbursed by such Issuing Lender, to the extent not reimbursed prior to 12:00 Noon (New York time) on the date of such payment or disbursement, from and including the date paid or disbursed to but excluding the date such Issuing Lender was reimbursed by the Borrower therefor at a rate per annum equal to the Base Rate as in effect from time to time plus the Applicable Margin as in effect from time to time for Revolving Loans that are maintained as Base Rate Loans; provided, however, to the extent such amounts are not reimbursed prior to 12:00 Noon (New York time) on the third Business Day following the receipt by the Borrower of notice of such payment or disbursement or following the occurrence of a Default or an Event of Default under Section 11.05, interest shall thereafter accrue on the amounts so paid or disbursed by such Issuing Lender (and until reimbursed by the Borrower) at a rate per annum equal to the Base Rate as in effect from time to time plus the Applicable Margin for Revolving Loans that are maintained as Base Rate Loans as in effect from time to time plus 2%, with such interest to be payable on demand. Each Issuing Lender shall give the Borrower prompt written notice of each Drawing under any Letter of Credit issued by it, provided that the failure to give any such notice shall in no way affect, impair or diminish the Borrower’s obligations hereunder.
(b) The obligations of the Borrower under this Section 3.05 to reimburse each Issuing Lender with respect to drafts, demands and other presentations for payment under Letters of Credit issued by it (each, a “Drawing”) (including, in each case, interest thereon) shall be absolute and unconditional under any and all circumstances and irrespective of any setoff, counterclaim or defense to payment which the Borrower or any Subsidiary of the Borrower may have or have had against any Lender (including in its capacity as an Issuing Lender or as a Participant), including, without limitation, any defense based upon the failure of any drawing under a Letter of Credit to conform to the terms of the Letter of Credit or any nonapplication or misapplication by the beneficiary of the proceeds of such Drawing; provided, however, that the Borrower shall not be obligated to reimburse any Issuing Lender for any wrongful payment made by such Issuing Lender under a Letter of Credit issued by it as a result of acts or omissions constituting willful misconduct or gross negligence on the part of such Issuing Lender (as determined by a court of competent jurisdiction in a final and non-appealable decision).
Construction materials (1) The restrictions of section 1605 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5) (Recovery Act) do not apply to Recovery Act designated country manufactured construction material. The restrictions of the Buy American statute do not apply to designated country unmanufactured construction material. Consistent with U.S. obligations under international agreements, this clause implements--
Issuance of and Drawings and Reimbursement Under Letters of Credit (a) Request for Issuance. Each Letter of Credit shall be issued upon notice, given not later than 2:00 P.M. (New York, New York time) on the fifth Business Day prior to the date of the proposed issuance of such Letter of Credit (or such later day as the Issuing Bank in its sole discretion shall agree), by the Borrower to the Issuing Bank, which shall give to the Administrative Agent and each Revolving Credit Lender prompt notice thereof. Each notice of issuance of a Letter of Credit (a "Notice of Issuance") shall be by telephone, confirmed immediately in writing, or by telecopier, shall be duly executed by a Responsible Officer of the Borrower, and shall specify therein: (i) the requested date of such issuance (which shall be a Business Day); (ii) the requested Available Amount of such Letter of Credit; (iii) the requested expiration date of such Letter of Credit (which shall comply with the requirements of Section 2.01(e)); (iv) the name and address of the proposed beneficiary of such Letter of Credit; and (v) the proposed form of such Letter of Credit, and shall be accompanied by such application and agreement for letters of credit as the Issuing Bank may specify to the Borrower for use in connection with such requested Letter of Credit (such applications and agreements, and all similar agreements entered into in connection with an Existing Letter of Credit, a "Letter of Credit Agreement"). If the requested form of such Letter of Credit is acceptable to the Issuing Bank in its sole discretion, the Issuing Bank will, upon fulfillment of the applicable conditions set forth in Article III, make such Letter of Credit available to the Borrower at its office referred to in Section 8.02 or as otherwise agreed with the Borrower in connection with the issuance of such Letter of Credit. If and to the extent that the provisions of any Letter of Credit Agreement shall conflict with this Agreement, the provisions of this Agreement shall govern.
