FINAL PAYMENT DELAY Sample Clauses

FINAL PAYMENT DELAY. If the Owner or its designated agent does not issue a certificate for final payment or the Contractor does not receive such payment for any cause which is not the fault of the Subcontractor, the Contractor shall promptly inform the Subcontractor. The Contractor shall also diligently pursue, with the assistance of the Subcontractor, the prompt release by the Owner of the final payment due for the Subcontract Work. At the Subcontractor's request and expense, to the extent agreed upon in writing, the Contractor shall institute reasonable legal remedies to mitigate the damages and pursue payment of the Subcontractor's final payment including interest.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
FINAL PAYMENT DELAY. If Owner or its designated agent does not issue a certificate for final payment or CH2M HILL does not receive such payment for any cause that is not the fault of Subcontractor, CH2M HILL shall promptly inform Subcontractor in writing. CH2M HILL shall also diligently pursue, with the assistance of Subcontractor, the prompt release by Owner of the final payment due for Subcontractor’s Work. At Subcontractor’s request and expense, to the extent agreed upon in writing, CH2M HILL shall institute reasonable legal remedies to mitigate the damages and pursue payment of Subcontractor’s final payment including interest.
Sample 1Sample 2
FINAL PAYMENT DELAY. If the Customer does not waive all claims related to the Subcontractor’s Work, the Contractor shall promptly inform the Subcontractor in writing. The Contractor shall also diligently pursue, with the assistance of the Subcontractor, the prompt release by the Customer of all claims and the final payment due for the Subcontractor’s Work. At the Subcontractor’s request and expense, to the extent agreed upon in writing, the Contractor shall institute reasonable legal remedies to mitigate the damages and pursue payment of the Subcontractor’s final payment including interest thereon.
Sample 1
FINAL PAYMENT DELAY. If the Owner or its designated agent does not issue a Certificate for Final Payment or if the General Contractor does not receive such payment for any cause which is not the fault of the Subcontractor, the General Contractor shall promptly inform the Subcontractor in writing. The General Contractor shall also diligently pursue, with the assistance of the Subcontractor, the prompt release by the Owner of the final payment due for the Subcontractor's Work. In all events no payment, whether interim or final, shall be due to the Subcontractor from the General Contractor unless and until the Owner has made payment to the General Contractor for the Subcontractor's work.
Sample 1
FINAL PAYMENT DELAY. If the Owner or its designated agent does not issue a certificate for final payment or the Constructor does not receive such payment for any cause which is not the fault of the Subcontractor, the Constructor shall promptly inform the Subcontractor in writing. If final payment from the Owner for such Subcontract Work is not received by the Constructor, through no fault of the Subcontractor, the Constructor will make payment to the Subcontractor within a reasonable time. The Constructor shall also diligently pursue, with the assistance of Subcontractor, the prompt release by the Owner of the final payment due for the Subcontractor Work. At the Subcontractor's request and expense, to the extent agreed upon in writing, the Constructor shall institute reasonable legal remedies to mitigate the damages and pursue payment of the Subcontractor's final payment including interest.
Sample 1

Related to FINAL PAYMENT DELAY

  • Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.

  • Final Payment All items or Automated Clearing House (ACH) transfers credited to your account are provisional until we receive final payment. If final payment is not received, we may charge your account for the amount of such items or ACH transfers and impose a return item charge on your account. Any collection fees we incur may be charged to your account. We reserve the right to refuse or return any item or funds transfer.

  • Additional Payment In addition to any Spousal Support, in the event of Divorce: (check one) ☐ - There shall be No Additional Payment made by either Spouse to the other than those listed in this Agreement. ☐ - There shall be an Additional One (1) Time payment in the amount of $ made by the ☐ Husband ☐ Wife to the ☐ Husband ☐ Wife (“Additional Payment”). The Additional Payment shall be made within thirty (30) days after a divorce judgment, decree, or similar document that certifies the Divorce. ☐ - Other. .

  • Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.

  • Final Pay Regardless of whether the termination is on notice or without notice, the employee’s final pay is payable in the next available pay cycle, unless the employee requests of the employer in writing to receive the final pay on the last day of the employee’s work.

Time is Money Join Law Insider Premium to draft better contracts faster.