Completion Date Completion date" shall be the date on which the improvements erected and to be erected upon the leased premises shall have been completed in accordance with the plans and specifications described in article 6.00. The completion date shall constitute the commencement of the term of this Lease for all purposes, whether or not Lessee has actually taken possession. Lessor shall use its best efforts to establish the completion date as the date set forth in section 1.03. In the event that the improvements have not in fact been completed as of that date, Lessee shall notify Lessor in writing of its objections. Lessor shall have a reasonable time after delivery of the notice in which to take such corrective action as may be necessary and shall notify Lessee in writing as soon as it deems such corrective action has been completed and the improvements are ready for occupancy. Upon completion of construction, Lessee shall deliver to Lessor a letter accepting the leased premises as suitable for the purposes for which they are let and the date of such letter shall constitute the commencement of the term of this Lease. Whether or not Lessee has executed such letter of acceptance, taking possession of the leased premises by Lessee shall be deemed to establish conclusively that the improvements have been completed in accordance with the plans and specifications, are suitable for the purposes for which the leased premises are let, and that the leased premises are in good and satisfactory condition as of the date possession was so taken by Lessee, except for latent defects, if any.
Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Financing Commitment For the period commencing on the date hereof and ending on the fifth anniversary hereof, Atlas America and Resource Energy agree to provide to the MLP funding of up to an aggregate of One Million Five Hundred Thousand Dollars ($1,500,000) per annum to finance the cost of expanding the Gathering System or constructing new additions to the Gathering System. Atlas America and Resource Energy, jointly and severally, commit to provide such funding, upon the MLP's written request therefor, by purchasing Common Units at a price equal to the arithmetic average of the closing prices of the Common Units on the American Stock Exchange, or, if the American Stock Exchange is not the principal trading market for such security, on the principal trading market for such security, for the twenty consecutive trading days ending on the trading day prior to the purchase, or, if the fair market value of the Common Units cannot be calculated for such period on any of the foregoing bases, the average fair market value during such period as reasonably determined in good faith by the members of the managing board of the General Partner.
Post-Closing Operations After the Closing, ACQUIRED COMPANY will be a wholly-owned subsidiary of the Company subject to the terms and conditions outlined in this Agreement. ACQUIRED COMPANY shall be responsible to report to the Company all financial matters and newsworthy events as they materialize, as Seller recognizes Company is a publicly traded company and has certain material obligations of disclosure pursuant to state and federal laws, statutes and regulations.
Refinancing Facilities (a) At any time after the Closing Date, the Borrowers may obtain, from any Lender or any Additional Lender, Credit Agreement Refinancing Indebtedness in respect of (i) all or any portion of the Term Loans then outstanding under this Agreement (which, for purposes of this clause (i), will be deemed to include any then outstanding Other Term Loans and Other Term Loan Commitments) or (ii) all or any portion of the Revolving Loans (or unused Revolving Credit Commitments) under this Agreement (which, for purposes of this clause (ii), will be deemed to include any then outstanding Other Revolving Loans and Other Revolving Commitments), in the form of (x) Other Term Loans or Other Term Loan Commitments or (y) Other Revolving Loans or Other Revolving Commitments, as applicable, in each case, pursuant to a Refinancing Amendment; provided that such Credit Agreement Refinancing Indebtedness (A) shall rank pari passu in right of payment and of security with the other Loans and Commitments hereunder, (B) will have such pricing, fees, premiums, and interest or optional prepayment terms as may be agreed by the Borrowers and the Lenders thereof, (C)(x) with respect to any Other Revolving Loans or Other Revolving Commitments, will have a maturity date that is not prior to the maturity date of Revolving Loans (or unused Revolving Credit Commitments) being refinanced and (y) with respect to any Other Term Loans or Other Term Loan Commitments, will have a maturity date that is not prior to the maturity date of, and will have a Weighted Average Life to Maturity that is not shorter than, the then applicable Weighted Average Life to Maturity of the Term Loans being refinanced (other than to the extent of nominal amortization for periods where amortization has been eliminated or reduced as a result of prepayments of such Term Loans), (D) any Credit Agreement Refinancing Indebtedness in the form of Other Term Loans or Other Term Loan Commitments will share ratably in any voluntary and mandatory prepayments or repayments of Term Loans (unless the Lenders providing the Other Term Loans agree to participate on a less than pro rata basis in any voluntary or mandatory prepayments or repayments), (E) will, in the case of any Credit Agreement Refinancing Indebtedness in the form of Other Revolving Loans or Other Revolving Commitments, provide that (1) the borrowing and repayment (except for (i) payments of interest and fees at different rates on Other Revolving Commitments (and related outstandings), (ii) repayments required upon the maturity date of the Other Revolving Commitments and (iii) repayments made in connection with a permanent repayment and termination of commitments (subject to clause (3) below)) of Loans with respect to Other Revolving Commitments after the date of obtaining any Other Revolving Commitments shall be made on a pro rata basis with all other Revolving Credit Commitments, (2) subject to the provisions of Section 2.3 and Section 2.4 to the extent dealing with Swing Line Loans and Letters of Credit which mature or expire after a maturity date when there exists Incremental Revolving Credit Commitments with a longer maturity date, all Swing Line Loans and Letters of Credit shall be participated on a pro rata basis by all Lenders with Other Revolving Commitments in accordance with their percentage of the Revolving Credit Commitments (and except as provided in Section 2.3 and Section 2.4, without giving effect to changes thereto on an earlier maturity date with respect to Swing Line Loans and Letters of Credit theretofore incurred or issued), (3) the permanent repayment of Revolving Loans with respect to, and termination of, Other Revolving Commitments after the date of obtaining any Other Revolving Commitments shall be made on a pro rata basis with all other Revolving Credit Commitments, except that the Borrowers shall be permitted to permanently repay and terminate commitments of any such Class on a better than a pro rata basis as compared to any other Class with a later maturity date than such Class and (4) assignments and participations of Other Revolving Commitments and Other Revolving Loans be governed by the same assignment and participation provisions applicable to Revolving Credit Commitments and Revolving Loans, (F) such Credit Agreement Refinancing Indebtedness shall be subject to the Intercreditor Agreement and (G) will have terms and conditions that are not materially more restrictive, taken as a whole, to Holdings and its Restricted Subsidiaries than those applicable to the Refinanced Debt, taken as a whole, as determined in Holdings’ good faith judgment in consultation with the Administrative Agent (except for (A) covenants and events of default applicable only to periods after the Latest Maturity Date in effect at the time of the incurrence or issuance of any such Credit Agreement Refinancing Indebtedness or (B) unless the Borrowers enter into an amendment to this Agreement with the Administrative Agent (which amendment shall not require the consent of any other Lender) to add such more restrictive terms for the benefit of the Lenders). Each Class of Credit Agreement Refinancing Indebtedness incurred under this Section 2.26 shall be in an aggregate principal amount that is (x) not less than $10,000,000 in the case of Other Term Loans or $5,000,000 in the case of Other Revolving Loans and (y) an integral multiple of the Dollar Amount of $1,000,000 in excess thereof. Any Refinancing Amendment may provide for the issuance of Letters of Credit for the account of the Borrowers, or the provision to the Borrowers of Swing Line Loans, pursuant to any Other Revolving Commitments established thereby, in each case on terms substantially equivalent to the terms applicable to Letters of Credit and Swing Line Loans under the Revolving Credit Commitments.
Project Financing Tenant acknowledges that as a material inducement to Landlord to execute this Lease, (i) Tenant shall timely acknowledge and deliver to Landlord all such documents and instruments as may be customarily those documents and instruments which may be required under Paragraph 16, and (iii) if any prospective lender to Landlord shall request or require in connection with the placement of any financing to Landlord or pursuant to the provisions of any Security Document any modification of this Lease, Tenant shall not delay or withhold its agreement to such proposed modification provided in the same shall not modify the Basic Annual Rent payable hereunder nor materially and adversely affect the obligations of Tenant hereunder. Tenant shall be responsible for any and all liability, loss, cost, damage and expense, including, without limitation, attorneys' fees, which Landlord shall incur in connection with Tenant's failure or delay in executing, acknowledging and delivering such documents and instrument or Tenant's breach of any other covenant or agreement embodied in this Lease that results in the delay, impairment or cancellation of such financing.
Debt Financing (a) The Company, MCK and Echo Holdco and their respective Subsidiaries shall use their reasonable best efforts to assist the Company to arrange and obtain the Debt Financing on the terms and conditions described in the Debt Commitment Letters as promptly as practicable after the date hereof, including their reasonable best efforts to (i) maintain in effect the Debt Commitment Letters, (ii) negotiate and enter into definitive agreements with respect thereto on the terms and conditions contained in the Debt Commitment Letters (including any flex provisions) or on other terms no less favorable to the Company, (iii) satisfy on a timely basis all conditions in the Debt Commitment Letters that are within their control and (iv) upon satisfaction of the conditions set forth in the Debt Commitment Letters, consummate the Debt Financing at or prior to the Closing; it being understood that, if any portion of the Debt Financing to be provided as contemplated by the Debt Commitment Letters pursuant to a public offering, private offering under Rule 144A or otherwise has not been provided, and all conditions precedent to the Parties’ obligations hereunder shall have been satisfied or waived (other than receipt of the Debt Financing and those conditions which by their nature will not be satisfied except by actions taken at the Closing, but subject to the their satisfaction at the Closing), the Company shall draw upon the commitments under the Debt Commitment Letters to provide the bridge financing contemplated by and on the terms and conditions (including any applicable “flex” provisions) set forth in the Debt Commitment Letters. Each of the Company, MCK and Echo Holdco shall keep each other reasonably informed with respect to all material activity concerning the status of the Debt Financing contemplated by the Debt Commitment Letters and shall give each other notice of any material adverse change with respect to such Debt Financing as promptly as practicable.
Pre-Closing Restructuring (a) Prior to the Principal Closing (in respect of the Principal Business Equity Interests and the Principal Business Transferred Assets) and prior to the applicable Deferred Closing (in respect of the Deferred Business Equity Interests and the Deferred Business Transferred Assets), Sapphire (i) shall use reasonable best efforts to effect, or cause the other Sellers or the Transferred Entities, at all times in accordance with applicable Law (including notifying clients and customers), to effect, all transfers and take all such actions as are necessary so that as of the Relevant Closing (A) the internal restructuring transactions set forth on Schedule 2.06(a)(i)(A), shall be consummated in the manner described on such Schedule, (B) assets, properties and businesses of the Transferred Entities that, if held by the Retained Entities, would constitute Excluded Assets (applying Section 2.03 mutatis mutandis) (collectively, the “Non-Business Assets”) shall be transferred to any of the Retained Entities and (C) except as otherwise set forth in this Agreement, any Liability of the Transferred Entities that, if a Liability of a Retained Entity, would constitute an Excluded Liability applying Section 2.05 mutatis mutandis (collectively, the “Non-Business Liabilities”) shall be assigned to any of the Retained Entities and (ii) may effect, or cause the Transferred Entities to effect, any transfer or other action as necessary to undertake any other restructurings that would not reasonably be expected, individually or in the aggregate (A) to materially interfere with, prevent or materially delay the ability of Sellers to perform their obligations under the Transaction Documents or consummate the transactions contemplated thereby, (B) to change the overall scope of the Businesses being sold to Buyer under this Agreement or the allocation of assets and Liabilities otherwise contemplated by this Agreement or (C) to result in material adverse Tax consequences to Buyer, its Affiliates or any Transferred Entities (taking into account Sapphire’s obligations pursuant to Article VI and Section 9.02) (collectively referred to as the “Restructurings”); provided, however, that (1) Restructurings that would not otherwise be permitted under the foregoing clause (ii) may be completed with the prior written consent of Buyer (not to be unreasonably withheld, conditioned, or delayed), (2) the completion of any or all such Restructurings shall not be a condition to any Closing, (3) no Restructurings (other than in a manner consistent in all material respects with that set forth on Schedules 2.06(a)(i)(A) in respect of any Brexit Assets shall be completed without the prior written consent of Buyer (not to be unreasonably withheld, conditioned or delayed) and (4) with respect to UK Newco, Sapphire shall consult in good faith with Buyer regarding such Restructurings and shall consider in good faith Buyer’s reasonable comments in respect of such implementation. At Buyer’s reasonable request, Sapphire shall provide Buyer with reasonable updates from time to time on the status of the Restructurings.
