Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Vacation Scheduling for All Employees A. Vacation leave will be charged in the amount actually used by the employee.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Refresh Provision for Permanent Employees Permanent Employees returning from LTD or workplace insurance leave to resume their regular working hours must complete eleven (11) consecutive working days at their regular working hours to receive a new allocation of sick/short-term disability leave. If the Employee has a recurrence of the same illness or injury, s/he is required to apply to reopen the previous LTD or WSIB claim, as applicable. The Local union and Local school board agree to continue to cooperate in the implementation and administration of early intervention and safe return to work processes as a component of the Short-Term Leave and Long-Term Disability Plans. In the event the Employee exhausts his/her sick/short-term disability leave allocation from the previous year and continues to work part-time, their salary will be reduced accordingly and a pro-rated sick/short-term allocation for the employee’s working portion of the current year will be provided. The new pro-rated sick/short-term leave allocation may not be used to top-up from part-time to full-time hours. Any changes to hours of work during a fiscal year shall result in an adjustment to the allocation.
