YOUR BILLING RIGHTS - KEEP THIS NOTICE FOR FUTURE USE This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:
Notice of Completion; Copy of Record Set of Plans Within fifteen (15) days after completion of construction of the Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.
Your Billing Rights: Keep this Document for Future Use This notice tells you about your rights and our responsibilities under the Fair Credit Billing Act.
Venue Limitation for TIPS Sales Vendor agrees that if any "Venue" provision is included in any TIPS Sale Agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Venue” clause that conflicts with these terms is rendered void and unenforceable.
Billing for Treatment and Payment Restrictions Grantees will; a. bill for only one intensity of service and service type (either outpatient or residential) per client per day b. not bill for an intensity of service and service type if another System Agency-funded Treatment Grantee is providing and billing System Agency for another intensity of service and service type. The following are the exception to item b.: A client may receive; a. co-occurring psychiatric / substance use disorder services,
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Data for Option W1 W1.1 The Adjudicator the person selected from the ICE-SA Division (or its successor body) of the South African Institution of Civil Engineering Panel of Adjudicators by the Party intending to refer a dispute to him. (see xxx.
