We use cookies on our site to analyze traffic, enhance your experience, and provide you with tailored content.
For more information visit our privacy policy.Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.
PERFORMANCE OF THE CONTRACT II.1.1. The Contractor shall perform the Contract to the highest professional standards. The Contractor shall have sole responsibility for complying with any legal obligations incumbent on him, notably those resulting from employment, tax and social legislation. II.1.2. The Contractor shall have sole responsibility for taking the necessary steps to obtain any permit or licence required for performance of the Contract under the laws and regulations in force at the place where the tasks assigned to him are to be executed. II.1.3. Without prejudice to Article II.3 any reference made to the Contractor’s staff in the Contract shall relate exclusively to individuals involved in the performance of the Contract. II.1.4. The Contractor must ensure that any staff performing the Contract have the professional qualifications and experience required for the execution of the tasks assigned to them. II.1.5. The Contractor shall neither represent the Agency nor behave in any way that would give such an impression. The Contractor shall inform third parties that he does not belong to the European public service. II.1.6. The Contractor shall have sole responsibility for the staff who execute the tasks assigned to him. II.1.7. In the event of disruption resulting from the action of a member of the Contractor's staff working on Agency premises or in the event of the expertise of a member of the Contractor's staff failing to correspond to the profile required by the Contract, the Contractor shall replace him without delay. The Agency shall have the right to request the replacement of any such member of staff, stating its reasons for so doing. Replacement staff must have the necessary qualifications and be capable of performing the Contract under the same contractual conditions. The Contractor shall be responsible for any delay in the execution of the tasks assigned to him resulting from the replacement of staff in accordance with this Article. II.1.8. Should any unforeseen event, action or omission directly or indirectly hamper execution of the tasks, either partially or totally, the Contractor shall immediately and on his own initiative record it and report it to the Agency. The report shall include a description of the problem and an indication of the date on which it started and of the remedial action taken by the Contractor to ensure full compliance with his obligations under the Contract. In such event the Contractor shall give priority to solving the problem rather than determining liability. II.1.9. Should the Contractor fail to perform his obligations under the Contract in accordance with the provisions laid down therein, the Agency may - without prejudice to its right to terminate the Contract - reduce or recover payments in proportion to the scale of the failure. In addition, the Agency may impose penalties or liquidated damages provided for in Article II.16.
Duration of the contract framework agreement or dynamic purchasing system II.2.10) Information about variants II.2.11) Information about options
CONDITIONS FOR EMERGENCY/HURRICANE OR DISASTER - TERM CONTRACTS It is hereby made a part of this Invitation for Bids that before, during and after a public emergency, disaster, hurricane, flood, or other acts of God that Orange County shall require a “first priority” basis for goods and services. It is vital and imperative that the majority of citizens are protected from any emergency situation which threatens public health and safety, as determined by the County. Contractor agrees to rent/sell/lease all goods and services to the County or other governmental entities as opposed to a private citizen, on a first priority basis. The County expects to pay contractual prices for all goods or services required during an emergency situation. Contractor shall furnish a twenty-four (24) hour phone number in the event of such an emergency.
SCOPE OF THE CONTRACT The Contractor shall perform the Services set out [in Schedule 1] [below2] in accordance with the Contract. [The Contractor’s key personnel assigned to perform the Services are: [provide a list] During the provision of the Services, if substitution of Contractor’s [key personnel] [experts] is necessary, the Contractor shall propose other experts or at least the same level of qualifications for approval by the Fund. [The Contractor shall obtain the Fund’s prior approval in writing before entering into a subcontract for engaging a subconsultant for the performance of any part of the Services.]
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Language of the contract The language of the contract and of all written communications between the contractor and the contracting authority and/or the project manager shall be English.
Termination for Catastrophe In event of Catastrophic Damage, this contract may be modified un- der B8.32, following rate redetermination under B3.32, or terminated under this Subsection. Such termination shall not be considered a termination under B8.34.
Control of the Contract F1 Transfer and Sub-Contracting F1.1 Except where F1.4 and F1.5 applies, the Contractor shall not assign, sub-contract or in any other way dispose of the Contract or any part of it without prior Approval. Sub-contracting any part of the Contract shall not relieve the Contractor of any of its obligations or duties under the Contract. F1.2 The Contractor shall be responsible for the acts and omissions of its Sub-contractors as though they are its own. F1.3 Where the Authority has consented to the placing of sub-contracts, copies of each sub-contract shall, at the request of the Authority, be sent by the Contractor to the Authority as soon as reasonably practicable. F1.4 Notwithstanding clause F1.1, the Contractor may assign to a third party (“the Assignee”) the right to receive payment of the Contract Price or any part thereof due to the Contractor under this Contract (including any interest which the Authority incurs under clause C2.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.