Form and Contents of Claim Sample Clauses

Form and Contents of Claim. If Developer intends to submit a Claim for an increase in the Guaranteed Maximum Price and/or Contract Time for any reason including, without limitation, the acts of District or its agents, Developer shall, within thirty (30) days after the event giving rise to the Claim, give notice of the Claim (“Notice of Potential Claim”) in writing, specifically identifying Developer is invoking this Article 25
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Form and Contents of Claim. The Claim shall be submitted to the City within thirty (30) days of receiving the City’s written decision regarding the dispute, or the date the Contractor contends such decision was due, and in no event later than the date of final payment. Contractor’s written claim must identify itself as a “Claim” under this Section 3.3 and must include the following: (1) a narrative of pertinent events; (2) citation to contract provisions; (3) theory of entitlement; (4) complete pricing of all cost impacts; (5) a time impact analysis of all time delays that shows actual time impact on the critical path; (6) documentation supporting items 1 – 5; and (7) verification under penalty of perjury of the claim’s accuracy. The Claim shall be priced like a Change Order, and must be updated every thirty (30) days as to cost and entitlement if it remains a continuing Claim. Routine contract materials, for example, correspondence, RFI, Change Order requests, or payment requests shall not constitute a Claim. Contractor shall bear all costs incurred in preparation, submittal, and administration of a Claim.
Sample 1Sample 2Sample 3See All (5)
Form and Contents of Claim. If CONTRACTOR disagrees with AGENCY’s decision, or if CONTRACTOR contends that AGENCY failed to provide a decision timely, then Contractor’s sole and exclusive remedy is to promptly file a written Claim setting forth CONTRACTOR’s position as required herein. The Claim shall be submitted to AGENCY within thirty (30) calendar days of receiving AGENCY’s written decision, or the date CONTRACTOR contends such decision was due. The CONTRACTOR shall furnish reasonable documentation to support the Claim. CONTRACTOR’s written Claim must identify itself as a “Claim” under this Article 19 and must include the following: (1) a narrative of pertinent events; (2) citation to contract provisions; (3) theory of entitlement; (4) complete pricing of all cost impacts; (5) a time impact analysis of all time delays that shows actual time impact on the critical path; and (6) documentation supporting items (1) through (5). The Claim must be verified under penalty of perjury by CONTRACTOR as to the Claim’s accuracy, and shall be priced like a Change Order, and must be updated monthly as to cost and entitlement if a continuing Claim. The Claim must be sent by sent by registered mail or certified mail with return receipt requested to the AGENCY. Routine contract materials, for example, correspondence, RFI, Change Order requests, or payment requests shall not constitute a Claim. CONTRACTOR shall bear all costs incurred in the preparation and submission of a Claim.
Sample 1

Related to Form and Contents of Claim

  • Exclusion of Claim You acknowledge and agree that you shall have no entitlement to compensation or damages insofar as such entitlement arises or may arise from you ceasing to have rights under or to be entitled to vest in your Restricted Shares as a result of such termination (whether the termination is in breach of contract or otherwise), or from the loss or diminution in value of your Restricted Shares. Upon the grant of your Restricted Shares, you shall be deemed to have waived irrevocably any such entitlement.

  • Status of Claims The CONSULTANT shall give prompt written notice to the LPA any claims made for damages against the CONSULTANT resulting from Services performed under this Contract and shall be responsible for keeping the LPA currently advised as to the status of such claims. The CONSULTANT shall send notice of claims related to work under this Contract to:

  • RELEASES OF CLAIMS Effective on the date when Defendant fully funds the entire Gross Settlement Amount and funds all employer payroll taxes owed on the Wage Portion of the Individual Class Payments, Plaintiff, Class Members, and Class Counsel will release claims against all Released Parties as follows:

  • Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:

  • PRESENTATION OF CLAIMS Presentation and processing of any or all claims arising out of or related to this Agreement shall be made in accordance with the provisions contained in Chapter 1.05 of the Santa Xxxx County Code, which by this reference is incorporated herein.

  • Notification of Claims (a) Except as otherwise provided in this Agreement, a Person that may be entitled to be indemnified under this Agreement (the “Indemnified Party”), shall promptly notify the party liable for such indemnification (the “Indemnifying Party”) in writing of any pending or threatened claim, demand or circumstance that the Indemnified Party has determined has given or would reasonably be expected to give rise to a right of indemnification under this Agreement (including a pending or threatened claim or demand asserted by a third party against the Indemnified Party, such claim being a “Third Party Claim”), describing in reasonable detail the facts and circumstances with respect to the subject matter of such claim, demand or circumstance (a “Claim Notice”); provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article XI except to the extent the Indemnifying Party is prejudiced by such failure, it being understood that notices for claims in respect of a breach or inaccuracy of a representation or warranty or breach of or default under any obligation or covenant must be delivered before the expiration of any applicable survival period specified in Section 11.4(a). (b) Upon receipt of a notice of a claim for indemnity from an Indemnified Party pursuant to Section 11.5(a) with respect to any Third Party Claim, the Indemnifying Party shall have the right (but not the obligation) to assume the defense and control of any Third Party Claim upon written notice to the Indemnified Party delivered within fifteen (15) Business Days of the Indemnifying Party’s receipt of the applicable Claim Notice and, in the event that the Indemnifying Party shall assume the defense of such claim, it shall allow the Indemnified Party a reasonable opportunity to participate in the defense of such Third Party Claim with its own counsel and at its own expense. The Person that shall control the defense of any such Third Party Claim (the “Controlling Party”) shall select counsel, contractors and consultants of recognized standing and competence after consultation with the other party and shall take all steps reasonably necessary in the defense or settlement of such Third Party Claim. (c) The Sellers or the Buyer, as the case may be, shall, and shall cause each of its Affiliates and representatives to, reasonably cooperate with the Controlling Party in the defense of any Third Party Claim. The Indemnifying Party shall be authorized to consent to a settlement of, or the entry of any judgment arising from, any Third Party Claim, without the consent of any Indemnified Party; provided that (i) such settlement shall not encumber any of the assets of the Indemnified Party or contain any restriction or condition that would apply to such Indemnified Party or to the conduct of the Indemnified Party’s business, (ii) the Indemnifying Party shall pay all amounts arising out of such settlement or judgment concurrently with the effectiveness of such settlement (subject to Section 11.3, if applicable), and (iii) the Indemnifying Party shall obtain, as a condition of any settlement or other resolution, a complete release of any Indemnified Party potentially affected by such Third Party Claim.

  • Notification of Claim Executive shall notify the Company in writing of any claim by the Internal Revenue Service that, if successful, would require the payment by the Company of the Gross-Up Payment. Such notification shall be given as soon as practicable but no later than ten (10) business days after Executive is informed in writing of such claim and shall apprise the Company of the nature of such claim and the date on which such claim is requested to be paid. Executive shall not pay such claim prior to the expiration of the thirty (30) day period following the date on which he gives such notice to the Company (or such shorter period ending on the date that any payment of taxes with respect to such claim is due). If the Company notifies Executive in writing prior to the expiration of such period that it desires to contest such claim, Executive shall: (a) give the Company any information requested by the Company relating to such claim; (b) take such action in connection with contesting such claim as the Company shall reasonably request in writing from time to time, including, without limitation, accepting legal representation with respect to such claim by an attorney reasonably selected by the Company; (c) cooperate with the Company in good faith in order to effectively contest such claim; and (d) permit the Company to participate in any proceedings relating to such claim; provided, however, that the Company shall bear and pay directly all costs and expenses (including additional interest and penalties) incurred in connection with such contest and shall indemnify and hold Executive harmless, on an after-tax basis, for any Excise Tax or income tax (including interest and penalties with respect thereto) imposed as a result of such representation and payment of costs and expenses. Without limiting the foregoing provisions of this Section 3, the Company shall control all proceedings taken in connection with such contest and, at its sole option, may pursue or forego any and all administrative appeals, proceedings, hearings and conferences with the taxing authority in respect of such claim and may, at its sole option, either direct Executive to pay the tax claimed and xxx for a refund or contest the claim in any permissible manner, and Executive agrees to prosecute such contest to a determination before any administrative tribunal, in a court of initial jurisdiction and in one or more appellate courts, as the Company shall determine; provided, however, that if the Company directs Executive to pay such claim and xxx for a refund, the Company shall advance the amount of such payment to Executive, on an interest-free basis, and shall indemnify and hold Executive harmless, on an after-tax basis, from any Excise Tax or income tax (including interest or penalties with respect thereto) imposed with respect to such advance or with respect to any imputed income with respect to such advance; and provided, further, that if Executive is required to extend the statute of limitations to enable the Company to contest such claim, Executive may limit this extension solely to such contested amount. The Company’s control of the contest shall be limited to issues with respect to which a Gross-Up Payment would be payable hereunder and Executive shall be entitled to settle or contest, as the case may be, any other issue raised by the Internal Revenue Service or any other taxing authority.

  • Payment of Claims A. If advance payment of all or a portion of the Grant funds is permitted by statute or regulation, and the State agrees to provide such advance payment, advance payment shall be made only upon submission of a proper claim setting out the intended purposes of those funds. After such funds have been expended, Grantee shall provide State with a reconciliation of those expenditures. Otherwise, all payments shall be made thirty five (35) days in arrears in conformance with State fiscal policies and procedures. As required by IC § 4-13-2-14.8, all payments will be by the direct deposit by electronic funds transfer to the financial institution designated by the Grantee in writing unless a specific waiver has been obtained from the Indiana Auditor of State B. Requests for payment will be processed only upon presentation of a Claim Voucher in the form designated by the State. Such Claim Vouchers must be submitted with the budget expenditure report detailing disbursements of state, local and/or private funds by project budget line items. C. The State may require evidence furnished by the Grantee that substantial progress has been made toward completion of the Project prior to making the first payment under this Grant. All payments are subject to the State's determination that the Grantee's performance to date conforms with the Project as approved, notwithstanding any other provision of this Grant Agreement. D. Claims shall be submitted to the State within 10 calendar days following the end of the month in which work on or for the Project was performed. The State has the discretion, and reserves the right, to NOT pay any claims submitted later than 35 calendar days following the end of the month in which the services were provided. All final claims and reports must be submitted to the State within 10 calendar days after the expiration or termination of this agreement. Payment for claims submitted after that time may, at the discretion of the State, be denied. Claims may be submitted on a monthly basis only. If Grant funds have been advanced and are unexpended at the time that the final claim is submitted, all such unexpended Grant funds must be returned to the State. E. Claims must be submitted with accompanying supportive documentation as designated by the State. Claims submitted without supportive documentation will be returned to the Grantee and not processed for payment. Failure to comply with the provisions of this Grant Agreement may result in the denial of a claim for payment.

  • Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.

  • Claims Procedures Each Party entitled to be indemnified by the other Party (an “Indemnified Party”) pursuant to Section 8.1 or 8.2 hereof shall give notice to the other Party (an “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of any threatened or asserted claim as to which indemnity may be sought, and shall permit the Indemnifying Party to assume the defense of any such claim or any litigation resulting therefrom; provided: (a) That counsel for the Indemnifying Party, who shall conduct the defense of such claim or any litigation resulting therefrom, shall be approved by the Indemnified Party (whose approval shall not unreasonably be withheld) and the Indemnified Party may participate in such defense at such party’s expense (unless (i) the employment of counsel by such Indemnified Party has been authorized by the Indemnifying Party; or (ii) the Indemnified Party shall have reasonably concluded that there may be a conflict of interest between the Indemnifying Party and the Indemnified Party in the defense of such action, in each of which cases the Indemnifying Party shall pay the reasonable fees and expenses of one law firm serving as counsel for the Indemnified Party, which law firm shall be subject to approval, not to be unreasonably withheld, by the Indemnifying Party); and (b) The failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its obligations under this Agreement to the extent that the failure to give notice did not result in harm to the Indemnifying Party. (c) No Indemnifying Party, in the defense of any such claim or litigation, shall, except with the approval of each Indemnified Party which approval shall not be unreasonably withheld, consent to entry of any judgment or enter into any settlement which (i) would result in injunctive or other relief being imposed against the Indemnified Party; or (ii) does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect to such claim or litigation. (d) Each Indemnified Party shall furnish such information regarding itself or the claim in question as an Indemnifying Party may reasonably request in writing and shall be reasonably required in connection with the defense of such claim and litigation resulting therefrom.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!