Tenant’s Insurance Tenant shall maintain the following coverages in the following amounts.
Landlord Insurance Insurance shall be procured by Landlord in accordance with its sole discretion. All awards and payments thereunder shall be the property of the Landlord, and Tenant shall have no interest in the same. Notwithstanding the foregoing, Landlord agrees to obtain building liability and hazard insurance required to be carried for the Property and Premises and adequate hazard insurance, which covers replacement cost of the Property and Premises.
Landlord’s Insurance Landlord shall carry at all times during the Term of this Lease (i) commercial general liability insurance with respect to the Buildings in an amount not less than $10,000,000.00 combined single limit per occurrence, (ii) insurance against loss or damage with respect to the Complex covered by the so-called "all risk" type insurance coverage with customary exceptions in an amount equal to one hundred percent (100%) of the replacement value of all improvements within the Complex and (iii) loss of "rental value" insurance in an amount equal to not less than the Annual Fixed Rent and payments on account of Operating Expenses Allocable to the Premises and Landlord's Tax Expenses Allocable to the Premises payable by Tenant under this Lease for not less than a one (1) year period (with a customary deductible). Landlord may also maintain such other insurance as may from time to time be required by a mortgagee holding a mortgage lien on the Buildings. Further, Landlord may also maintain such insurance against loss of annual fixed rent and additional rent and such other risks and perils as Landlord deems proper. Any and all such insurance (x) may be maintained under a blanket policy affecting other properties of Landlord and/or its affiliated business organizations, (y) may be written with deductibles as reasonably determined by Landlord (which such deductible is currently $25,000.00) and (z) shall be subject to reimbursement in accordance with Section 2.6. Nothing contained herein shall be construed so as to require Landlord to maintain terrorism or environmental pollution liability insurance (it being acknowledged, however, that Landlord does in fact maintain such coverages as of the date of this Lease); provided, however, that in the event the Landlord originally named herein shall sell, transfer, assign, conveyor ground lease its interest in the Complex to an unaffiliated third party, such new owner and any subsequent party succeeding to the original Landlord's interest as Landlord under this Lease shall not be entitled to charge to Tenant at any time during the Term as part of Operating Expenses Allocable to the Premises any costs of terrorism or environmental pollution liability insurance in excess of one hundred ten percent (110%) of the costs being paid by Tenant on account of such coverages during the last full calendar year immediately prior to the conveyance by the original named Landlord.
Tenant’s Compliance With Landlord’s Fire and Casualty Insurance Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.
Tenant’s Property Insurance Tenant shall maintain at all times during the Lease Term, and during such earlier time as Tenant may be performing work in or to the Premises or have property, fixtures, furniture, equipment, machinery, goods, supplies, wares or merchandise on the Premises, and continuing thereafter so long as Tenant is in occupancy of any part of the Premises, business interruption insurance and (insurance against loss or damage covered by the so-called “all risk” type insurance coverage with respect to (i) Tenant’s property, fixtures, furniture, equipment, machinery, goods, supplies, wares and merchandise, and (ii) any other improvements which exist in the Premises as of the Lease Commencement Date (excluding the Base Building) (the “Original Improvements”), and all alterations, improvements and other modifications made by or on behalf of the Tenant in the Premises, and (iii) other property of Tenant located at the Premises (collectively “Tenant’s Property”). The business interruption insurance required by this Section shall be in minimum amounts typically carried by prudent tenants engaged in similar operations, but in no event shall be in an amount less than the Base Rent then in effect during any Lease Year, plus any Additional Rent due and payable for the immediately preceding Lease Year. The “all risk” insurance required by this Section shall be in an amount at least equal to the full replacement cost of Tenant’s Property. In addition, during such time as Tenant is performing work in or to the Premises, Tenant, at Tenant’s expense, shall also maintain, or shall cause its contractor(s) to maintain, builder’s risk insurance for the full insurable value of such work. Landlord and such additional persons or entities as Landlord may reasonably request shall be named as loss payees, as their interests may appear, on the policy or policies required by this section. In the event of loss or damage covered by the “all risk” insurance required by this section, the responsibilities for repairing or restoring the loss or damage shall be determined in accordance with Article 11 of this Lease, below. To the extent that Landlord is obligated to pay for the repair or restoration of the loss or damage covered by the policy, Landlord shall be paid the proceeds of the “all risk” insurance covering the loss or damage. To the extent Tenant is obligated to pay for the repair or restoration of the loss or damage, covered by the policy, Tenant shall be paid the proceeds of the “all risk” insurance covering the loss or damage. If both Landlord and Tenant are obligated to pay for the repair or restoration of the loss or damage covered by the policy, the insurance proceeds shall be paid to each of them in the pro rata proportion of their obligations to repair or restore the loss or damage. If the loss or damage is not repaired or restored (for example, if the Lease is terminated pursuant to Section 11.2 of this Lease, below), the insurance proceeds shalt be paid to Landlord and Tenant in the pro rata proportion of their relative contributions to the cost of the leasehold improvements covered by the policy.
Lessee’s Insurance Lessee shall procure and maintain policies of insurance, at its own cost and expense, insuring:
(a) The Lessor Protected Parties (as "named insureds"), and the First Mortgagee, and Lessee Protected Parties, from all claims, demands or actions made by or on behalf of any person or persons, firm or corporation and arising from, related to or connected with the leased premises, for bodily injury to or personal injury to or death of any person, or more than one (1) person, or for damage to property in an amount of not less than $2,000,000.00 combined single limit per occurrence/aggregate. Said insurance shall be written on an "occurrence" basis and not on a "claims made" basis. If at any time during the term of this Lease, Lessee owns or rents more than one location, the policy shall provide that the aggregate limit in the policy shall apply separately to each location owned or rented by Lessee. Lessor shall have the right, exercisable by giving written notice thereof to Lessee, to require Lessee to increase such limit if, in Lessor's reasonable judgment, the amount thereof is insufficient to protect the Lessor Protected Parties and Lessee Protected Parties from judgments which might result from such claims, demands or actions;
(b) The Improvements at any time situated upon the leased premises ("Improvements") against loss or damage by fire, lightning, wind, storm, hail storm, aircraft, vehicles, smoke, explosion, sewer back-up, riot or civil commotion as provided by the Standard Fire and Extended Coverage Policy and all other risks of direct physical loss as insured against under Special Form ('all risk" coverage). Such coverage shall be provided under the blanket policy maintained by Lessee. The insurance coverage shall be for not less than 100% of the full replacement cost of such Improvements and will include building ordinance coverage to include demolition and increased loss of construction, which building ordinance coverage endorsement shall be in an amount as Lessor shall reasonably require, all subject only to such deductibles as Lessor shall reasonably approve in writing. If, in Lessor's reasonable judgment, the amount thereof is insufficient to protect the Improvements, by an agreed amount endorsement covering the Improvements, the full replacement cost of the Improvements shall be designated annually by Lessor, in the good faith exercise of Lessor's judgment. In the event that Lessee does not agree with Lessor's designation, Lessee shall have the right to submit the matter to an insurance appraiser reasonably selected by Lessor and paid for by Lessee. The insurance appraiser shall submit a written report of his appraisal and if said report discloses that the 7 Improvements are not insured as therein required, Lessee shall promptly obtain the insurance required. Lessor shall be named as an additional insured and Lessee shall direct its insurer to pay all proceeds for loss or damage to the Improvements only to Lessor. Said insurance shall contain a policy provision waiving the insurer's right of subrogation against any Lessor Protected Party or any Lessee Protected party, provided that such waiver of the right of subrogation shall not be operative in any case where the effect thereof is to invalidate such insurance coverage or increase the cost thereof (except that either party shall have the right, within thirty (30) days following written notice, to pay such increased cost, thereby keeping such waiver in full force and effect);
(c) Lessor's business income, protecting Lessor from loss of rents and other charges during the period while the leased premises are unleaseable due to fire or other casualty (for a twelve (12) month period);
Tenant Insurance Landlord is not liable to Tenant or any of Tenant's invitees, licensees, and/or guests for any damages not proximately caused by Landlord and Landlord will not compensate Tenant or any other person for damages proximately caused by any other source, including acts of God and nature. Tenant is therefore strongly encouraged to purchase insurance to protect Tenant, Tenant's personal property and any person on the Property for Tenant.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Construction Insurance In addition to the requirements of Article 10 of this Lease, in the event that Tenant makes any Alterations, prior to the commencement of such Alterations, Tenant shall provide Landlord with evidence that Tenant carries “Builder’s All Risk” insurance in an amount approved by Landlord covering the construction of such Alterations, and such other insurance as Landlord may reasonably require, it being understood and agreed that all of such Alterations shall be insured by Tenant pursuant to Article 10 of this Lease immediately upon completion thereof. In addition, Landlord may, in its discretion, require Tenant to obtain a lien and completion bond or some alternate form of security satisfactory to Landlord in an amount sufficient to ensure the lien-free completion of such Alterations and naming Landlord as a co-obligee.
Tenant’s Liability Insurance Tenant shall, at Tenants sole cost and expense, provide comprehensive general liability insurance, fully covering and indemnifying Landlord and Landlord’s officers, directors, shareholders, partners, principals, employees, agents, representatives; and other related entities and individuals (together with, at Landlord’s election, Landlord’s lender), as additional insureds, against any and all claims arising from personal injury, death, and/or property damage occurring in or about the Premises or the Property during the period of Tenant’s possession (actual and/or constructive) at the Premises. The initial limits of such insurance shall be at least $2,000,000 combined single liability limit. Tenant shall also, at its sole cost and expense, obtain workers’ compensation insurance for the protection of its employees such as will relieve Landlord of all liability to such employees for any and all accidents that may arise on or about the Premises or the Property. All insurance required to be carried by Tenant shall be primary and noncontributory to any insurance carried by Landlord, regardless of the absence of negligence or other fault of Tenant for alleged injury, death and/or property damage. Each policy of insurance required to be carried by Tenant hereunder shall: (a) contain cross-liability and contractual liability endorsements, (b) provide that no cancellation or reduction in coverage shall be effective until thirty (30) days after written malice to Landlord and Landlord’s lender, (c) be issued by an insurer licensed in California and reasonably approved by Landlord, and (d) shall insure Tenant’s performance of the Indemnity provisions of Article 13, but the amount of such Insurance shall not limit Tenant’s liability nor relieve Tenant of any obligation hereunder. Prior to the Commencement Date, Tenant shall deliver a certificate evidencing all such insurance to Landlord. Tenant shall deliver a renewal or binder of such policy at least thirty (30) days prior to expiration thereof. Tenant shall, at Tenant’s expense, maintain such other liability insurance as Tenant deems necessary to protect Tenant. Tenant shall be in material breach of this Lease if Tenant fails to obtain the insurance required under this Section, or if Tenant obtains insurance with terms, conditions and/or exclusions that are inconsistent with the requirements and terms of this Lease.
