Analogous Events Anything analogous to or having a substantially similar effect to any of the events specified in Clauses 11.1.5 to 11.1.9 shall occur under the laws of any applicable jurisdiction.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Extraordinary Events No fault if failure due to an Extraordinary Event
15.1 Neither Party will be liable to the other for any failure to perform its obligations under this Contract where the failure is due to an Extraordinary Event. Obligations of the affected Party
15.2 A Party who wishes to claim suspension of its obligations due to an Extraordinary Event must notify the other Party as soon as reasonably possible. The Notice must state:
a. the nature of the circumstances giving rise to the Extraordinary Event
b. the extent of that Party's inability to perform under this Contract
c. the likely duration of that non-performance, and
d. what steps are being taken to minimise the impact of the Extraordinary Event on the delivery of Services. Alternative arrangements requiring immediate termination
15.3 If the Buyer, acting reasonably, requires the Services to be supplied during the period affected by an Extraordinary Event, then despite clause 15.4, the Buyer may terminate this Contract immediately by giving Notice.
Other Events There occurs any other event of a nature that would be required to be reported in response to Item 6(e) of Schedule 14A of Regulation 14A (or any successor rule) (or a response to any similar item on any similar schedule or form) promulgated under the Exchange Act (as defined below), whether or not the Company is then subject to such reporting requirement.
Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:
(a) accident, death or severe injury to any person;
(b) damaged or dislodged fixed equipment;
(c) flooding of Project Highway; and
(d) any other unusual occurrence.
Trigger Events The Employee shall be entitled to collect the severance benefits set forth in Subsection (b) hereof in the event that either (i) the Employee voluntarily terminates employment for any reason within the 30-day period beginning on the date of a Change in Control, (ii) the Employee voluntarily terminates employment within 90 days of an event that both occurs during the Protected Period and constitutes Good Reason, or (iii) the Bank or the Company or their successor(s) in interest terminate the Employee's employment without his written consent and for any reason other than Just Cause during the Protected Period.
Events If either Party hereto is at any time either during this Agreement or thereafter prevented or delayed in complying with any provisions of this Agreement by reason of strikes, walk-outs, labour shortages, power shortages, fires, wars, acts of God, earthquakes, storms, floods, explosions, accidents, protests or demonstrations by environmental lobbyists or native rights groups, delays in transportation, breakdown of machinery, inability to obtain necessary materials in the open market, unavailability of equipment, governmental regulations restricting normal operations, shipping delays or any other reason or reasons beyond the control of that Party, then the time limited for the performance by that Party of its respective obligations hereunder shall be extended by a period of time equal in length to the period of each such prevention or delay.
Dissolution Events The Company shall be terminated and dissolved at such time or upon the happening of such events as shall be determined by the Member.
Accidents and Dangerous Occurrences The Hirer must report all accidents involving injury to the public to a member of the Village Hall management committee as soon as possible and complete the relevant section in the Village Hall’s accident book. Any failure of equipment belonging to the Village Hall or brought in by the Hirer must also be reported as soon as possible. Certain types of accident or injury must be reported on a special form to the local authority. The Hall Secretary will give assistance in completing this form. This is in accordance with the Reporting of Injuries, Diseases and Dangerous Occurrences Regulations 1995 (RIDDOR).
Triggering Events The events referred to in Sections 3(f) and 5(a) hereof are as follows:
