FPL’s Representative Sample Clauses

FPL’s Representative. No later than the date of this Agreement, FPL shall designate in writing one or more representatives at the Property Site (at least one of whom shall be at the Job Site during normal business hours) who shall act as the point of contact for both Contractor and the Independent Engineer with respect to the prosecution of the Work, administration of the Contract Documents on behalf of FPL, approval of Contractor’s submissions hereunder and inspection of the Work, as reasonably necessary for Contractor’s performance of the Work; provided that such representative(s) shall not be authorized to execute or make any amendments to, authorize Change Orders in respect of, or provide waivers under, this Agreement. FPL shall provide Contractor with prior written notice in the event that it designates any additional representatives or removes any existing representatives.
Sample 1
AutoNDA by SimpleDocs

Related to FPL’s Representative

  • City’s Representative The City hereby designates Xxx Xxxxx, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Consultant shall not accept direction or orders from any person other than the City’s Representative or his or her designee.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxx Xxxxxxxxx, Principal 00000 Xxxxxx Xxxxxxxx Xxxxxxx, Xxxxx 000, Xxxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: Xxx@XXXX.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx, Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Owner’s Representative Owner designates the individual listed below as its Owner’s Representative to provide direct interface with Construction Manager with respect to Owner’s responsibilities: Xxxxx Xxxxxx, Owner’s Project Manager.

  • Owner’s Representatives 9.1.1 Owner designates the individual listed below as its Senior Representative (“Owner Senior Representative”), which individual has the authority and responsibility for avoiding and resolving disputes under Section 10.2 of the General Conditions: 9.1.2 Owner designates the individual listed below as its Owner’s Representative, which individual has the authority and responsibility set forth in Section 3.3 of the General Conditions:

  • Company Representative Whenever under the provisions of this Agreement the approval of Company is required or Company is required to take some action at the request of Issuer, such approval shall be made or such action shall be taken by Company Representative and Issuer or Trustee shall be authorized to act on any such approval or action and Company shall have no redress against Issuer or Trustee as a result of any such action taken.

  • Safety Representative On every job site, workers may elect a Workers’ Safety Representative in accordance with the Act.

  • Sellers’ Representative (a) Each of the Sellers hereby appoints Xxxx Xxxxx as Seller’s Representative hereunder for the purposes of representing his or its individual interests. Each of the Sellers hereby authorizes the Sellers’ Representative to act on his or its behalf with respect to all matters arising under this Agreement requiring or contemplating the possibility of some notice to be sent to or from, or some action to be taken by, the Sellers, including acting as the Sellers’ representative for the purpose of settling on behalf of the Sellers any claims made by Buyer under Section 12.1(a)(i), representing the Sellers in any indemnification proceedings under Section 12.3, approving any waivers or amendments in accordance with Section 13.6, but excluding the settling of any claims made by Buyer under Section 12.1(a)(ii) against a Seller. Except as aforesaid, each Seller hereby agrees to be bound by any and all notices sent and actions taken (and notices not sent and actions not taken) by the Sellers’ Representative on his or its behalf pursuant to this Agreement. If for any reason the Sellers’ Representative shall be unable to perform its duties hereunder as Sellers’ Representative, the holders of a majority in interest of the Interests owned immediately prior to the Initial Closing shall appoint a replacement Sellers’ Representative. Buyer shall be entitled to rely exclusively upon any communications or writings given or executed by the Sellers’ Representative and shall not be liable in any manner whatsoever for any action taken or not taken in reliance upon the actions taken or not taken or communications or writings given or executed by the Sellers’ Representative. Buyer shall be entitled to disregard any notices or communications given or made by any Seller, in his or its individual capacity, which is contrary to a notice or communication given or made by the Sellers’ Representative. (b) In performing his duties under this Agreement, and in exercising or failing to exercise all or any of the powers conferred upon the Sellers’ Representative hereunder or thereunder, (i) the Sellers’ Representative shall not assume any, and shall incur no, responsibility whatsoever to any Seller by reason of any error in judgment or other act or omission performed or omitted hereunder or in connection with this Agreement, unless by the Sellers’ Representative’s gross negligence or willful misconduct, and (ii) the Sellers’ Representative shall be entitled to rely on the advice of counsel, public accountants or other independent experts experienced in the matter at issue, and any error in judgment or other act or omission of the Sellers’ Representative pursuant to such advice shall in no event subject the Sellers’ Representative to liability to any Seller unless by the Sellers’ Representative’s gross negligence or willful misconduct. All of the immunities and powers granted to the Sellers’ Representative under this Agreement shall survive the Initial Closing, any Subsequent Closing and/or any termination of this Agreement.

  • Contractor Representative The Contractor shall appoint a Contractor Representative fluent in English, who shall:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!