Prosecution of the Work. 1. All construction activities shall be conducted so as to avoid disturbance of other tenants. Landlord may require that all demolition and other categories of work that may inconvenience other tenants or disturb Building operations be scheduled and performed before or after Normal Building Operating Hours (at times determined by Landlord), and Tenant shall provide the Building manager with at least two Business Days’ notice prior to proceeding with any such work.
2. Unless Landlord directs otherwise, Tenant’s contractors shall have access to the Building during the Normal Building Operating Hours only. If Tenant’s contractors desire access to the Building at any other time, Landlord shall use reasonable efforts to provide such access, provided, however, that Tenant shall pay Landlord any additional cost incurred by Landlord to provide such access, including, without limitation, additional costs for utilities, personnel, and security.
3. Prior arrangements for elevator use shall be made with the Building manager by Tenant or the General Contractor. Elevator cabs shall be properly padded and no material or equipment shall be carried under or on top of elevators. If an operating engineer is required by any union rules, such engineer shall be paid for by Tenant.
4. Under no circumstances will any material related to Tenant’s Alterations be allowed access through the Building’s front entrance without advance written approval of the Building manager.
5. If shutdown of risers and mains for electrical, HVAC, sprinkler or plumbing work is required, such work shall be supervised by Landlord’s representative at Tenant’s expense. No work will be performed in Building mechanical equipment rooms except under Landlord’s supervision.
6. Alterations shall be performed under the supervision of a superintendent or xxxxxxx of the General Contractor at all times.
7. All areas adjacent to the construction area shall be sealed with plastic so as to not be affected by dust and debris. All floors shall be protected from the construction process.
8. The General Contractor or HVAC subcontractor shall block off supply and return grilles, diffusers and ducts to keep dust from entering into the Building HVAC system and thoroughly clean all HVAC units in the work area at the completion of the Alterations.
9. Construction debris shall be removed from the construction area daily and the construction area shall be kept neat and reasonably clean at all times. All construction debris is to ...
Prosecution of the Work. The time of beginning, rate of progress, and time of completion of the work are the essence of this Agreement. The Artist must do the work at such time, and in such order, as will result in successful completion of the Project during the time specified in the Agreement and the approved construction schedule. The Artist must furnish tools and equipment for the Project in sufficient quantity and of a capacity and type that will safely perform the work specified without delay in the progress of the work.
Prosecution of the Work. The Design/Builder shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Schedule. If the rate of progress is such that the total amount of Work and/or the degree of completion of the Project accomplished by the Design/Builder within any time period required by the Schedule is less than the amount therein specified, the Design/Builder shall so notify the Owner. If the delay is an Unexcused Delay, the Design/Builder shall prepare a recovery schedule for the Owner's review and approval, showing how the Design/Builder will compensate for the delays and achieve Substantial Completion by the date shown on the Schedule. If the Design/Builder is unable to demonstrate how it will overcome Unexcused Delays, the Owner may order the Design/Builder to employ such extraordinary measures as are necessary to bring the Work into conformity with the Substantial Completion Date set forth therein, the costs of which shall be paid as Cost of the Work. If the delay is an Excusable Delay, the Owner shall either (a) authorize an equitable extension in the Schedule to account for such delay, and equitably adjust the GMP on account of such delay, to the extent permitted by Article 6; or (b) request that the Design/Builder prepare a recovery schedule showing how (if possible) the Design/Builder can achieve Substantial Completion by the date shown on the Schedule, and equitably adjust the GMP in accordance with the Change Order provisions of this Agreement on account of any extraordinary activities required of the Design/Builder on account of such recovery schedule.
Prosecution of the Work. 2.2.1 The Contractor shall proceed with the Work and every part and detail thereof in a prompt and diligent manner and shall do the several parts thereof at such times and in such order as the Owner’s Representative and the Owner may direct and in accordance with Project Schedule.
2.2.2 Where the dates for the commencement and completion of any portion of the Work or for deliveries of Material and Equipment are not specified, the Contractor shall commence such Work or make such deliveries within the time set forth in a Notice from the Owner or Owner’s Representative to do so, but in no event later than three (3) days after receipt of such Notice if no time period is set forth in such Notice. Such work or deliveries shall be prosecuted and completed with all possible diligence, or as otherwise directed by the Owner’s Representative or the Owner.
2.2.3 The Contractor shall prosecute and complete the Work:
2.2.3.1 in strict accordance with the Contract Documents;
2.2.3.2 in such manner as may be necessary to maintain the progress of construction on the Project;
2.2.3.3 in accordance with the Project Schedule and any other time schedules, starting dates, completion dates and milestones established by the Owner or the Owner’s Representative for any portion of the Work;
2.2.3.4 to the full satisfaction of the Owner; and
2.2.3.5 no later than the Completion Date.
2.2.4 The Contractor agrees to supply all necessary Materials and Equipment, labor, and all other items required, in the quantities, and at the times necessary, to complete the Contract Work in accordance with the Project Schedule and all Work Schedules approved by the Owner.
Prosecution of the Work. The Contractor agrees to prosecute all work under this Contract continuously and diligently and to meet all milestones contained in the Contract. The Contractor further agrees that no charges or claims for damages shall be made by it for any delays or hindrances from any cause whatsoever during the progress of any portion of the work specified in this Contract. Time extensions will be granted only for excusable delays that arise from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including but not restricted to, acts of God, acts of the public enemy, acts of the State in either its sovereign or contractual capacity, acts of another Contractor in the performance of a contract with the State, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, or delays of subcontractors or suppliers arising from unforeseeable causes beyond the control and without the fault or negligence of either the Contractor or the subcontractors or suppliers.
Prosecution of the Work. 3.1 Time is of the essence as to the prosecution of the Subcontractor's Work. If requested, the Subcontractor shall provide the Contractor with scheduling information and Subcontractor's proposed schedule for the Subcontractor's Work. The Contractor may prepare the Schedule of Work for the Project and, as may be necessary, revise the same as the Work progresses. The Subcontractor shall commence the Subcontractor's Work promptly within five days after the date of the notice to proceed. The Subcontractor shall commence, continue, and complete its performance of the Project in a prompt and diligent manner at such times, in such order, and in such manner, as directed by the Contractor or in accordance with the Schedule of Work without hindering the Work of the Contractor or any other subcontractor, and so as to insure completion as directed by the Contractor. Any time specified for the completion of this Agreement, or portion thereof, is a material provision of this Agreement. The Subcontractor shall proceed with the Subcontractor's Work, including all necessary submittals, mock-ups and deliveries, so as to progress and complete its Work in accordance with the Contractor’s most current Schedule of Work or as directed by the Contractor. Whenever, in the Contractor's judgment, the Subcontractor fails or is in danger of failing to maintain its part of the Schedule of the Work, Subcontractor shall, without additional compensation, work such overtime and/or additional shifts as the Contractor may direct.
3.2 The Subcontractor shall be responsible for and will prepare for performance of Subcontractor's Work, including, without limitation thereto, the submission of shop drawings, samples, tests, and field dimensions, determination of labor requirements and ordering of materials as required to meet the most current Schedule of Work or the direction of the Contractor. Subcontractor shall notify Contractor when portions of its Work are ready for inspection.
3.3 The Subcontractor will furnish periodic progress reports of the Subcontractor's Work as requested including the progress of materials or equipment to be provided under this Agreement that may be in the course of preparation or manufacture. Deliveries to the site must be prearranged on at least 24 hours notice, unless Subcontractor will be present to receive them.
3.4 The Subcontractor shall cooperate with the Contractor and subcontractors whose work may interfere with the Subcontractor's Work and participate in t...
Prosecution of the Work. The Construction Manager shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Master Schedule. If the delay is an Inexcusable Delay, as defined below, the Construction Manager shall prepare a recovery schedule for the City’s review and approval, showing how the Construction Manager will compensate for the delays and achieve Substantial Completion by the date shown on the Master Schedule. If the Construction Manager is unable to demonstrate how it will overcome Inexcusable Delays, the City may order the Construction Manager to employ such extraordinary measures as are necessary to bring the Work into conformity with the date of Substantial Completion set forth therein, the costs of which shall be included as part of the Cost of the Work. If the delay is an Excusable Delay, as defined below, the City shall either (A) authorize an equitable extension in the Master Schedule to account for such delay, and equitably adjust the GMP on account of such delay or (B) request that the Construction Manager prepare a recovery schedule showing how (if possible) the Construction Manager can achieve Substantial Completion by the date shown on the Master Schedule, and equitably adjust the applicable GMP in accordance with the Change Order provisions of this Agreement related to any extraordinary activities required of the Construction Manager on account of such recovery schedule.
Prosecution of the Work. 2.2.1 The Contractor shall proceed with the Work and every part and detail thereof in a prompt and diligent manner and shall do the several parts thereof at such times and in such order as the OR and the Owner may direct and in accordance with Project Schedule.
2.2.2 Where the dates for the commencement and completion of any portion of the Work or for deliveries of Material and Equipment are not specified, the Contractor shall commence such Work or make such deliveries within the time set forth in a Notice from the Owner or the OR to do so, but in no event later than three (3) days after receipt of such Notice if no time period is set forth in such Notice. Such work or deliveries shall be prosecuted and completed with all possible diligence, or as otherwise directed by the Owner or the OR.
2.2.3 The Contractor shall prosecute and complete the Work:
2.2.3.1 in strict accordance with the Contract Documents;
2.2.3.2 in such manner as may be necessary to maintain the progress of construction on the Project;
2.2.3.3 in accordance with the Project Schedule and any other time schedules, starting dates, completion dates and milestones established by the Owner or the OR for any portion of the Work;
2.2.3.4 to the full satisfaction of the Owner; and
2.2.3.5 no later than the Completion Date.
2.2.4 The Contractor agrees to supply all necessary Materials and Equipment, labor, and all other items required, in the quantities, and at the times necessary, to complete the Contract Work in accordance with the Project Schedule and all Work Schedules approved by the Owner.
Prosecution of the Work. The Grantee agrees to prosecute all work under this Agreement continuously and diligently and to meet all milestones contained in the Agreement. The Grantee further agrees that no charges or claims for damages shall be made by it for any delays or hindrances from any cause whatsoever during the progress of any portion of the work specified in this Agreement. Time extensions will be granted only for excusable delays that arise from unforeseeable causes beyond the control and without the fault or negligence of the Grantee, including but not restricted to, acts of God, acts of the public enemy, acts of the State in either its sovereign or contractual capacity, acts of another sub-grantee or sub-contractor in the performance of a contract with the State, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, or delays of subcontractors or suppliers arising from unforeseeable causes beyond the control and without the fault or negligence of either the Grantee or the sub-grantees, sub-contractors or suppliers.
Prosecution of the Work. The Job Order Contractor shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Job Order Schedule. If the delay is an Inexcusable Delay, as defined below, the Job Order Contractor shall prepare a recovery schedule for the City’s review and approval, showing how the Job Order Contractor will compensate for the delays and achieve Substantial Completion by the date shown on the Job Order Schedule. If the Job Order Contractor is unable to demonstrate how it will overcome Inexcusable Delays, the City may order the Job Order Contractor to employ such extraordinary measures as are necessary to bring the Work into conformity with the date of Substantial Completion set forth therein, the costs of which shall be included as part of the Cost of the Work. If the delay is an Excusable Delay, as defined below, the City shall either:
(A) authorize an equitable extension in the Job Order Schedule to account for such delay, and equitably adjust the Job Order Contractor’s compensation on account of such delay; or (B) request that the Job Order Contractor prepare a recovery schedule showing how (if possible) the Job Order Contractor can achieve Substantial Completion by the date shown on the Job Order Schedule, and equitably adjust Job Order Contractor’s compensation in accordance with the Change Order provisions of this Contract related to any extraordinary activities required of the Job Order Contractor on account of such recovery schedule.
