Gaming Enterprise Site Selection Construction and Financing
Gaming Enterprise Site Selection Construction and Financing Sample Clauses
Related to Gaming Enterprise Site Selection Construction and Financing
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
LOCATION AND DESCRIPTION OF THE PROPERTY The subject property is a single-storey terraced house bearing the postal address of Xx. 00, Xxxxxx 00/XX0, Xxxxxx Xxxxx Xxxxxxx, 00000 Xxxxxxx Xxxxx, Xxxxxx. The subject property will be sold on an “as is where is basis” and subject to a reserve price of RM310,000.00 (RINGGIT MALAYSIA THREE HUNDRED TEN THOUSAND ONLY) and subject to the Conditions of Sale and by way of an Assignment from the above Assignee/Bank subject to the consent being obtained by the Purchaser from the Developer and other relevant authorities if any, including all terms, conditions, stipulations and covenants which were and may be imposed by the Developer and the relevant authorities. Any arrears of quit rent, assessments and service or maintenance charges which may be lawfully due to any relevant authority or the Developer up to the date of auction sale of the property shall be paid out of the purchase money upon receipt of full purchase price. All other fees, costs and charges relating to the transfer and assignment of the property shall be borne by the successful Purchaser. Online bidders are further subject to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx. All intending bidders are required to deposit 10% of the fixed reserve price for the said property by Bank Draft or Cashier’s Order in favour of UOBM for KRISHNAMAL A/P MURLIGIAH & XXXXXXXXXXX A/L XXXXXXX or remit the same through online banking transfer, one (1) working day before auction date. The balance of the purchase money shall be paid by the Purchaser within one hundred and twenty (120) days from the date of auction sale to UNITED OVERSEAS BANK (MALAYSIA) BHD via Real Time Electronics Transfer of Funds and Securities (XXXXXX). For online bidders please refer to the Terms & Conditions on xxx.xxxxxxxxxxxxxxxx.xxx on the manner of payment of the deposit. FOR FURTHER PARTICULARS, please contact M/S HOE & MOIRA, of Xxxxx 000X (Xxxxx), 0xx Xxxxx, Xxxxx Xxxxxx Xxxxxx, Xxxxxxxxxx Xxxx, 00000 Xxxxxx, Xxxxxxxx. (Ref:H&M/MT/Z4P/CB23/16) Tel.: 00-000 0000, Fax: 00-000 0000) the Assignee herein or the undermentioned Auctioneer. Suite C-20-3A, Level 20, Block C, Megan Avenue II, / XXXXX XXXXX BIN XXXXXX 00, Xxxxx Xxx Xxxx Xxxx, 50450 Kuala Lumpur (Licensed Auctioneers) Tel No.: 00-0000 0000 Fax No.: 00-0000 0000 Our Ref: LIAN/UOB1035HM Website: xxx.xxxxxxxxxxxxxxxx.xxx E-mail: xxxx@xxxxxxxxxxxxxxxx.xxx [berkuatkuasa dari 1.11.2022, perniagaan perbankan pengguna (consumer banking business) CITIBANK BERHAD (No. Syarikat: 199401011410 (297089-M) telah dipindahmilik kepada xxx diletakhakkan kepada UOB di bawah Perintah Letakhak bertarikh 12.10.2022 melalui Mahkamah Tinggi Kuala Lumpur Saman Pemula No. WA-24NCC-903-09/2022] Dalam menjalankan xxx xxx kuasa xxxx telah diberikan kepada Pihak Pemegang Serahhak/Bank dibawah Perjanjian Kemudahan, Penyerahanhak xxx Surat Kuasa Wakil kesemuanya Bertarikh 09hb Julai, 2001 diantara Pihak Penyerahhak, Pihak Pelanggan xxx Pihak Pemegang Serahhak/Bank yang diperbuat dalam perkara diatas, adalah dengan ini diisytiharkan bahawa Pihak Pemegang Serahhak/Bank tersebut dengan bantuan Pelelong yang tersebut dibawah.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
CONSTRUCTION AND RENOVATION Construction and renovation projects for a state, local, territorial, or Tribal government’s principal Emergency Operations Center (EOC) as defined by the State Administrative Agency are allowable under the EMPG Program. Written approval must be provided by FEMA prior to the use of any EMPG Program funds for construction or renovation. Requests for EMPG Program funds for construction of an EOC must be accompanied by an EOC Investment Justification (located in the Related Documents tab of the EMPG xxxxxx.xxx posting) to their Regional EMPG Manager for review. Additionally, recipients are required to submit a SF-424C Form and Budget detail citing the project costs. When applying for funds to construct communication towers Sub-Recipients must submit evidence that the Federal Communication Commission’s (FCC) Section 106 review process has been completed and submit all documentation resulting from that review to Grants Program Directorate (GPD) prior to submitting materials for EHP review. Sub-Recipients are also encouraged to have completed as many steps as possible for a successful EHP review in support of their proposal for funding (e.g., coordination with their State Historic Preservation Office to identify potential historic preservation issues and to discuss the potential for project effects, compliance with all state and EHP laws and requirements). Projects for which the Sub-Recipient believes an Environmental Assessment (EA) may be needed, as defined in as defined in DHS Instruction Manual 023-01-001-01, Revision 01, FEMA Directive 108-1 and FEMA Instruction 108-1-1, must also be identified to the FEMA EMPG Regional Program Manager within six months of the award, and completed EHP review materials must be submitted no later than 12 months before the end of the period of performance. EHP review packets should be sent to xxxxxxxxxx@xxxx.xxx. EMPG Program Sub-Recipients using funds for construction projects must comply with the Xxxxx-Xxxxx Act (40 U.S.C. §§ 3141 et seq.). Grant Sub-Recipients must ensure that their contractors or subcontractors for construction projects pay workers no less than the prevailing wages for laborers and mechanics employed on projects of a character similar to the contract work in the civil subdivision of the state in which the work is to be performed. Additional information regarding compliance with the Xxxxx- Xxxxx Act, including Department of Labor (DOL) wage determinations, is available from the following website: xxxxx://xxx.xxx.xxx/whd/govcontracts/dbra.htm In general, Sub-Recipients should consult with their Grant Manager prior to making any investment that does not clearly meet the allowable expense criteria established in this Guidance.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Use of State Facilities Where there is available appropriate meeting space in buildings owned or leased by the State, MSEA-SEIU shall be allowed reasonable use of such space at reasonable times for specific meetings, including space suitable for meetings in private between MSEA-SEIU staff representatives or stewards and employees in the investigation and processing of grievances. In addition, in buildings owned or leased by the State that have video conferencing facilities, MSEA-SEIU may be allowed reasonable use of those facilities. Advance arrangements for the use of State facilities shall be made with the department or agency concerned. MSEA-SEIU shall reimburse the State for any additional expense incurred in allowing use of such space. No other employee organization, except such as have been certified or recognized as the bargaining agent for other State employees, shall have the right to meeting space in State facilities for purposes pertaining to terms and conditions of employment of employees. The use of State facilities for meetings shall be in non-work areas or where work is not in progress. Other than meetings in private between MSEA- SEIU staff representatives or stewards and employees in the investigation and processing of grievances, all meetings in State facilities shall be during the off- duty time of employees attending and, in all instances, attendance shall be voluntary. Arrangements for any meetings in State facilities will be made so as to avoid interference with the department's or agency's operations or violation of the department's or agency's security.
Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.
Location and Facilities The Executive will be furnished with the working facilities and staff customary for executive officers with the title and duties set forth in Section 1 and as are necessary for him to perform his duties. The location of such facilities and staff shall be at the principal administrative offices of the Company and the Bank, or at such other site or sites customary for such offices.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
