General Construction Agreement Sample Clauses

General Construction Agreement. Construction Agent shall prior to July 31, 2024 enter into an amendment to the General Construction Agreement (the “GMP Amendment”) providing for (a) a final completion date thereunder of not later than the Outside Completion Date and (b) a guaranteed maximum price under the General Construction Agreement that, when taken together with the Project Costs payable under all of the Project Agreements, is not in excess of $750,000,000 (the “Required GMP Amount”); provided, that Construction Agent shall not incur Project Costs in excess of $240,000,000 under any Project Agreement, including the General Construction Agreement, until Construction Agent has satisfied the clauses (a) and (b) of this Section 2.5. All Project Specific Agreements relating to the General Construction Agreement, Architect Agreement and any other Major Project Agreement that are necessary for the completion of the Facility shall be entered into prior to, or contemporaneous with, the GMP Amendment.
Sample 1
AutoNDA by SimpleDocs
General Construction Agreement. Staxxxxx Xxrm of Agreement Between Owner and Contractor dated January _, 2000, by and between WWLLC as Owner, and PCL Construction Services, Inc., as Contractor. Exhibit A Legal Description LOT I A TRACT OF LAND IN THE SOUTH ONE-HALF OF SECTION 7, TOWNSHIP 3 SOUTH, RANGE 72 WEST OF THE 6TH P.M., CITY OF BLACK HAWK, COUNTY OF GILPIN, STATE XX XXXXXXXX, XXXXX X XXXX XX XXX XxXXXXXXXXX XXXXXSION, XXX ELEPHANT LODE, THE EAGLE NEST LODE, AND CERTAIN TRACTS ON THE WEST SIDE Or RICHMAN STREET, ALL BEING PART OF THE LANDS DESCRIBED IN BOOK 627 PAXX 000, BOOK 627 PAGE 228, BOOK 627 PAGE 230, BOOK 627 PAGE 232, BOOK 627 PAGE237, BOOK 627 PAGE 24 1, BOOK 627 PAGE 254, AND BOOK 628 PAGE 35, MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT A POINT WHICH BEARS N. 42006'59"E A DISTANCE OF 628-59 FEET FROM CORNER NO. 21 OF THE SECURITY PLACER, MINERAL SURVEY NO. 5664; THENCE ALONG THE FOLLOWING COURSES: THENCE S00045'35"E. A DISTANCE OF 177.47 FEET TO A POINT. THENCE ON A NON-TANGENT CURVE TO THE RIGHT CONTAINING A CENTRAL ANGLE OF 35049'51 ", A RADIUS OF 255.50 FEET, AN ARC LENGTH OF 159.78 FEET, A CHORD BEARING OF S I 7009'20"W, A CHORD DISTANCE OF 157.19 FEET TO A POINT; THENCE S64030'00"W, A DISTANCE OF 75.71 FEET TO A POINT, THENCE ON A CURVE TO THE RIGHT CONTAINING A CENTRAL ANGLE OF 10053'05", A RADIUS OF 1298.20 FEET, AN ARC LENGTX XX 000.00 XXXX, X XXXXX XEARING OF N56049'58"W, A CHORD DISTANCE OF 246.26 FEET TO A POINT; THENCE N51027'30"W, A DISTANCE OF 241.02 FEET TO A POINT; THENCE N2901 I'40"E, A DISTANCE OF 12.36 FEET TO A POINT; THENCE N53019'44"W, A DISTANCE OF 117.41 FEET TO A POINT, THENCE N52030'00"E, A DISTANCE OF 571.84 FEET TO A POINT, THENCE S 17013'3 8"E, A DISTANCE OF 79.93 FEET TO A POINT; THENCE ON A CURVE TO THE LEFT CONTAINING A CENTRAL ANGLE OF 10002'07", A RADIUS OF 219.50 FEET, AN ARC LENGTH XX 00.00 XXXX, X XXXXX XXXRING OF S22014'42"E, A CHORD DISTANCE OF 38.40 FEET TO A POINT; THENCE S27015'45"E, A DISTANCE OF 181.68 FEET TO A POINT; THENCE ON A CURVE TO THE RIGHT CONTAINING A CENTRAL ANGLE OF 26030'10", A RADIUS OF 180.50 FEET, AN ARC LENGTH XX 00.00 XXXX, X XXXXX XXXRING OF S 14000'40"E, A CHORD DISTANCE OF 82.75 FEET TO THE POINT OF BEGINNING, COUNTY OF GILPIN, STATE OF COLORADO. PARCEL R -------- TRACT OF LAND SITUATE ON THE EAST SIDE OF RICHMAN STREET IN THE CITY OF BLACK HAWK, DESCRIBED AS FOLLOWS: XXXXXXNG AT HIGHWAY #119 RIGHT-OF-WAY MONUMENT STATION 842+40. THENCE NORTH 2302 1'40" WEST, 142.92 FEET TO THE NORTHWEST CORNER OF...
Sample 1
General Construction Agreement. Stxxxxxx Xorm of Agreement Between Owner and Contractor dated January 25, 2000, by and between WVY'LLC as Owner, and PCL Construction Services, Inc., as Contractor.
Sample 1

Related to General Construction Agreement

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Neutral Construction The parties to this Agreement agree that this Agreement was negotiated fairly between them at arm's length and that the final terms of this Agreement are the product of the parties' negotiations. Each party represents and warrants that it has sought and received legal counsel of its own choosing with regard to the contents of this Agreement and the rights and obligations affected hereby. The parties agree that this Agreement shall be deemed to have been jointly and equally drafting by them, and that the provisions of this Agreement therefore should not be construed against a party or parties on the grounds that such party or parties drafted or was more responsible for the drafting of any such provision(s).

  • Initial Construction Landlord shall fully construct the base Building in accordance with the preliminary base building plans, including, without limitation, floor plans, elevations and site plan(s) (collectively, the "PBBP") and Base Building Outline Specifications attached hereto as Exhibits B-1 and B-2, respectively (all of such work being collectively referred to as the "Landlord's Work"). In the event of differences between the PBBP or the Landlord's Plans (as hereinafter defined) and the Base Building Outline Specifications, the Base Building Outline Specifications shall govern and control until the Landlord's Plans (as hereinafter defined) are prepared. A complete set of final base Building plans and construction drawings and specifications, such drawings and specifications to include a detail schedule of core base Building finish items such as, but not limited to, carpets, doors, hardware, ceiling grids/tiles, lavatory fixtures, light fixtures, window blinds, lobby finishes and paint/wall coverings (collectively, the "Landlord's Plans") shall be prepared by Landlord, at its sole cost and expense. Landlord and Tenant agree to work together with Landlord's architect, Symmes Maini and McKex Xxxociates, Inc. in order to achieve a design that meets the standard set forth below. Furthermore, Landlord agrees to use good faith and diligent efforts to deliver the Landlord's Plans to Tenant on or before May 1, 2000. Upon receipt, Tenant shall have seven (7) business days to comment upon the Landlord's Plans. Landlord and Tenant shall use reasonable efforts to reach agreement on the Landlord's Plans as soon thereafter as possible. In reaching agreement, Landlord and Tenant shall each approve portions of the Landlord's Plans that are in acceptable form and shall note their respective objections to the portions that are unacceptable to each of them so as to enable Landlord to continue construction and order materials in a timely manner. In the event that Landlord's Plans conform with the PBBP, but Tenant does not approve the Landlord's Plans within seven (7) business days of receipt thereof from Landlord, then the Outside Delivery Date (as hereinafter defined) shall be extended for a number of days equal to the number of Tenant Plan Delay Days, as such term is hereinafter defined. The number of Tenant Plan Delay Days are defined as and shall be calculated by determining the actual number of days as certified by Landlord and its architect that the Term Commencement Date was delayed by such Tenant's failure to approve the Landlord's Plans within the required seven (7) business days. Landlord agrees to provide Tenant with written notice of such determination, such notice to include reasonable detail describing the cause of the delay and the number of Tenant Plan Delay Days as certified by Landlord and its architect. If Tenant and Tenant's Architect (as hereinafter defined)

  • General Construction Principles Words in any gender are deemed to include the other genders. The singular is deemed to include the plural and vice versa. The headings and underlined paragraph titles are for guidance only and have no significance in the interpretation of this Agreement.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.

  • Legal Construction In the event that any one or more of the terms, provisions, or agreements that are contained in this Agreement shall be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable in any respect for any reason, the invalid, illegal, or unenforceable term, provision, or agreement shall not affect any other term, provision, or agreement that is contained in this Agreement and this Agreement shall be construed in all respects as if the invalid, illegal, or unenforceable term, provision, or agreement had never been contained herein.

  • Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.

  • Defined Terms Construction 1.01 Defined Terms 1.02 Construction ARTICLE II LOAN 2.01 Loan Terms 2.02 Prepayment Premium 2.03 Exculpation 2.04 Application of Payments 2.05 Usury Savings 2.06 Floating Rate Mortgage - Third Party Cap Agreement ARTICLE III LOAN SECURITY AND GUARANTY 3.01 Security Instrument

Time is Money Join Law Insider Premium to draft better contracts faster.