Arbitration, Damages, Warranties Notwithstanding any language to the contrary, no interpretation of this contract shall find that the State or its agencies have agreed to binding arbitration, or the payment of damages or penalties. Further, the State of Kansas and its agencies do not agree to pay attorney fees, costs, or late payment charges beyond those available under the Kansas Prompt Payment Act (K.S.A. 75-6403), and no provision will be given effect that attempts to exclude, modify, disclaim or otherwise attempt to limit any damages available to the State of Kansas or its agencies at law, including but not limited to the implied warranties of merchantability and fitness for a particular purpose.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
Liability and Damages The liability provisions of the Terms shall apply except as explicitly agreed otherwise in this DPA.
Indemnity/Liability You shall indemnify, and hold harmless RIM, the RIM Group of Companies, RIM's affiliates, suppliers, successors, agents, authorised distributors, (including Airtime Service Providers) and assigns and each of their directors, officers, employees and independent contractors (each a "RIM Indemnified Party") from any damages, losses, costs or expenses (including reasonable lawyers’ fees and costs) incurred by a RIM Indemnified Party, and at the RIM Indemnified Party’s request defend at Your expense any third party claim or proceeding brought against the RIM Indemnified Party, arising from: (a) infringement of patents or other intellectual property or proprietary rights arising from combining with or using any device (other than a BlackBerry Handheld Product), system or service in connection with Your BlackBerry Solution or any portion thereof; or (b) Your breach of this Agreement or any Addendum to this Agreement. No remedy herein conferred upon RIM is intended to be, nor shall it be construed to be, exclusive of any other remedy provided herein or as allowed by law or in equity, but all such remedies shall be cumulative.
NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE
NO LIABILITY FOR CONSEQUENTIAL DAMAGES In no event shall Xxxxxxxx Software GmbH or its distributors be liable for any damages whatsoever (including, without limitation, damages for loss of business profits, business interruption, loss of business information, or any other pecuniary loss) arising out of the use of or inability to use this Software and related materials, even if Xxxxxxxx Software GmbH has been advised of the possibility of such damages. Because some states do not allow the exclusion or limitation of liability for consequential or incidental damages, the above limitation may not apply to you.
Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Liability Disclaimer THE INFORMATION, SOFTWARE, PRODUCTS, AND SERVICES INCLUDED IN OR AVAILABLE THROUGH THE SITE MAY INCLUDE INACCURACIES OR TYPOGRAPHICAL ERRORS. CHANGES ARE PERIODICALLY ADDED TO THE INFORMATION HEREIN. VG TALENT & SERVICES LLC AND/OR ITS SUPPLIERS MAY MAKE IMPROVEMENTS AND/OR CHANGES IN THE SITE AT ANY TIME. VG TALENT & SERVICES LLC AND/OR ITS SUPPLIERS MAKE NO REPRESENTATIONS ABOUT THE SUITABILITY, RELIABILITY, AVAILABILITY, TIMELINESS, AND ACCURACY OF THE INFORMATION, SOFTWARE, PRODUCTS, SERVICES AND RELATED GRAPHICS CONTAINED ON THE SITE FOR ANY PURPOSE. TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, ALL SUCH INFORMATION, SOFTWARE, PRODUCTS, SERVICES AND RELATED GRAPHICS ARE PROVIDED "AS IS" WITHOUT WARRANTY OR CONDITION OF ANY KIND. VG TALENT & SERVICES LLC AND/OR ITS SUPPLIERS HEREBY DISCLAIM ALL WARRANTIES AND CONDITIONS WITH REGARD TO THIS INFORMATION, SOFTWARE, PRODUCTS, SERVICES AND RELATED GRAPHICS, INCLUDING ALL IMPLIED WARRANTIES OR CONDITIONS OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE AND NON- INFRINGEMENT. TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, IN NO EVENT SHALL VG TALENT & SERVICES LLC AND/OR ITS SUPPLIERS BE LIABLE FOR ANY DIRECT, INDIRECT, PUNITIVE, INCIDENTAL, SPECIAL, CONSEQUENTIAL DAMAGES OR ANY DAMAGES WHATSOEVER INCLUDING, WITHOUT LIMITATION, DAMAGES FOR LOSS OF USE, DATA OR PROFITS, ARISING OUT OF OR IN ANY WAY CONNECTED WITH THE USE OR PERFORMANCE OF THE SITE, WITH THE DELAY OR INABILITY TO USE THE SITE OR RELATED SERVICES, THE PROVISION OF OR FAILURE TO PROVIDE SERVICES, OR FOR ANY INFORMATION, SOFTWARE, PRODUCTS, SERVICES AND RELATED GRAPHICS OBTAINED THROUGH THE SITE, OR OTHERWISE ARISING OUT OF THE USE OF THE SITE, WHETHER BASED ON CONTRACT, TORT, NEGLIGENCE, STRICT LIABILITY OR OTHERWISE, EVEN IF VG TALENT & SERVICES LLC OR ANY OF ITS SUPPLIERS HAS BEEN ADVISED OF THE POSSIBILITY OF DAMAGES. BECAUSE SOME STATES/JURISDICTIONS DO NOT ALLOW THE EXCLUSION OR LIMITATION OF LIABILITY FOR CONSEQUENTIAL OR INCIDENTAL DAMAGES, THE ABOVE LIMITATION MAY NOT APPLY TO YOU. IF YOU ARE DISSATISFIED WITH ANY PORTION OF THE SITE, OR WITH ANY OF THESE TERMS OF USE, YOUR SOLE AND EXCLUSIVE REMEDY IS TO DISCONTINUE USING THE SITE. VG Talent & Services reserves the right, in its sole discretion, to terminate your access to the Site and the related services or any portion thereof at any time, without notice. To the maximum extent permitted by law, this agreement is governed by the laws of the State of Wyoming and you hereby consent to the exclusive jurisdiction and venue of courts in Wyoming in all disputes arising out of or relating to the use of the Site. Use of the Site is unauthorized in any jurisdiction that does not give effect to all provisions of these Terms, including, without limitation, this section. You agree that no joint venture, partnership, employment, or agency relationship exists between you and VG Talent & Services as a result of this agreement or use of the Site. VG Talent & Services's performance of this agreement is subject to existing laws and legal process, and nothing contained in this agreement is in derogation of VG Talent & Services's right to comply with governmental, court and law enforcement requests or requirements relating to your use of the Site or information provided to or gathered by VG Talent & Services with respect to such use. If any part of this agreement is determined to be invalid or unenforceable pursuant to applicable law including, but not limited to, the warranty disclaimers and liability limitations set forth above, then the invalid or unenforceable provision will be deemed superseded by a valid, enforceable provision that most closely matches the intent of the original provision and the remainder of the agreement shall continue in effect. Unless otherwise specified herein, this agreement constitutes the entire agreement between the user and VG Talent & Services with respect to the Site and it supersedes all prior or contemporaneous communications and proposals, whether electronic, oral or written, between the user and VG Talent & Services with respect to the Site. A printed version of this agreement and of any notice given in electronic form shall be admissible in judicial or administrative proceedings based upon or relating to this agreement to the same extent and subject to the same conditions as other business documents and records originally generated and maintained in printed form. It is the express wish to the parties that this agreement and all related documents be written in English.
No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.
