Health and Sanitation During Construction of Project and Alterations Sample Clauses

Health and Sanitation During Construction of Project and Alterations. At all times during and in relation to construction of the Project and for any Alterations, Tenant, its contractors and subcontractors must meet and comply with all federal, state and local environmental, health and safety codes, regulations, statutes and other applicable laws, and shall take any and all necessary action to immediately comply with said laws upon knowing or having reason to know of such noncompliance.
Sample 1

Related to Health and Sanitation During Construction of Project and Alterations

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Construction of the Tenant Improvements 3.1 The Leased Premises consists of two existing, contiguous spaces which were previously leased to other tenants. Tenant is taking the Leased Premises in its “as is” condition, subject to modifications as shown on the Plans (as hereafter defined) to be prepared by Tenant (“Tenant Improvements”). The Landlord shall provide all necessary labor and materials and perform all the work required to complete the Tenant Improvements in order to ready the same for Tenant’s occupancy. Tenant’s designated representative for all work pertaining to the Tenant Improvements shall be Xxxx Xxxxxxxx or such other person as is designated in writing by Tenant (“Representative”). The Landlord shall supervise and direct the work on the Tenant Improvements using Landlord’s best skill and attention, and Landlord shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the work on the Tenant Improvements. Landlord warrants to the Tenant that all materials and equipment incorporated in the Tenant Improvements will be new unless otherwise specified, and that all work on the Tenant Improvements will be of good quality, free from known faults and defects, and in substantial conformity with the Plans. (a) Landlord shall complete the Tenant Improvements in a good and workmanlike manner and in substantial accordance with plans and specifications (“Plans”) to be prepared by Tenant’s architect, CUH2A. The Plans shall be provided to Landlord on or before September 1, 2003 and shall be in sufficient detail to permit Landlord to apply for a building permit for the Tenant Improvements (which Landlord shall promptly do), and to prepare a construction budget for the construction of the Tenant Improvements (“Construction Budget”). In the event Tenant does not deliver the Plans to Landlord by the date set forth above, such failure shall not delay the date for commencement of the rent, which shall be presumed to be the projected Commencement Date set forth in paragraph 2. The Construction Budget shall set forth the lump sum amount payable by Tenant to Landlord for the construction of the Tenant Improvements, which amount shall include Landlord’s standard xxxx-up for general conditions, overhead and profit, which total in the aggregate 20%. The only exception to the lump sum amount shall be the actual fees charged by the Township of South Brunswick for construction permits in connection with the Tenant Improvements, which sums shall be paid by Tenant as set forth hereafter. Landlord shall submit the Construction Budget to Tenant for its approval. Tenant shall give written notice to Landlord within five business days of receipt, as to whether or not the Construction Budget is acceptable. If Tenant does not accept the Construction Budget during such five business day period, then the parties agree to negotiate in good faith to reach an agreement on the Construction Budget. Landlord shall not be obligated to order any equipment or commence work until Tenant has approved the Construction Budget. A complete set of the agreed upon Plans, and the agreed upon Construction Budget, shall be initialed by and distributed to Landlord and Tenant. (b) Neither the Construction Budget nor the Plans shall be changed or altered in any way except by change order approved in writing by Landlord and Tenant (“Change Order”). All Change Orders shall be valid and binding upon Landlord and Tenant only if authorized by written Change Order signed by Landlord and Tenant’s Representative prior to commencement of the work on the Tenant Improvements reflected thereby. The cost or credit to the Tenant due to any Change Order shall be determined per the terms of such Change Order. In the event the Change Order increases the cost set forth in the Construction Budget, then Landlord shall submit an invoice to Tenant and Tenant shall pay the invoice upon completion of work or upon the ordering of any equipment, whichever is applicable. The Landlord shall have the right to substitute for the materials and equipment required by the Plans, materials and equipment of equal quality and standard, provided said substitutions conform with applicable building codes and are the subject of a Change Order. Each and every Change Order shall state whether the change will entail a delay in the date of Substantial Completion. Any Change Order requested by Tenant which results in a delay to the date of Substantial Completion shall not delay the date for the commencement of the payment of rent. (a) The Landlord may secure and advance payment for the construction permits and for all other permits and governmental fees, licenses and inspections necessary for the proper execution and completion of the Tenant Improvements. Tenant shall pay such amounts to Landlord not later than 10 business days after receipt of an invoice therefore Landlord shall not, however, be responsible for securing any environmental or operating permits or certifications which are required in order for Tenant to actually conduct its business. (b) Tenant shall be responsible for providing Landlord with, and bearing the cost of sufficient copies of the Plans, and sufficient copies of any revisions made to the Plans, in order to obtain the permits and efficiently manage the construction of the Tenant Improvements. In the event any Change Orders are required during construction, Tenant shall be responsible for all costs related to the preparation and reproduction of plans therefore, unless the Change Order was solely initiated by Landlord, in which case Landlord shall be responsible for such costs. After construction is complete, Tenant shall be responsible for all costs related to the reproduction of “as built” Plans. In all instances where Plans are required, Tenant shall provide Landlord with a reproducible set. Landlord will also be provided with a current plot file containing the Plans at no cost to Landlord. Tenant agrees to have its Architect execute Exhibit “A” affirming Landlord’s right to the Plans. (a) Tenant shall pay Landlord directly for the construction costs of Tenant Improvements in accordance with the schedule attached hereto as Exhibit “B”. The only exception to Tenant’s responsibility to pay for all construction costs shall be for the work necessary to upgrade the existing HVAC reheat system currently in the space previously occupied by Biomira, Inc. (currently known as 0000 Xxxxxxxx Xxxxxxxxx), which cost is estimated to be $150,000 and will he divided equally between the parties. In the event Tenant fails to pay to Landlord any sum set forth on Exhibit “B” when it is due, Landlord shall not be obligated to commence or continue work on the Tenant Improvements. Such failure to pay shall constitute a default under this Lease, but shall not delay the Commencement Date of this Lease, which shall be presumed to be the projected Commencement Date set forth in paragraph 2; or any of Tenant’s obligations hereunder including, without limitation, Tenant’s obligation to pay all Rent. In the event that Tenant fails to pay to Landlord, upon Substantial Completion of the Tenant Improvements, a sum equal to the remaining balance then due, such failure shall constitute a default under this Lease; and Tenant shall not be permitted to occupy the Leased Premises; and Tenant shall commence payment of all Rent; and Landlord shall be entitled to all rights and remedies available hereunder, at law or in equity, which rights shall be cumulative. All sums so owing to Landlord shall constitute Additional Rent and shall be subject to the imposition of late charges as provided in this Lease. (b) Apart from extensions of time for delays and extensions of the date for the payment of rent, no payment or allowance of any kind shall be claimed by Tenant, or made to the Landlord as compensation for damages on account of any delay from any cause in the completion of the Tenant Improvements, whether such delay be avoidable or unavoidable, anything in this Agreement inconsistent herewith or to the contrary notwithstanding. 3.5 Tenant shall be responsible for the design and installation of its own phone, data and communication systems which systems shall be installed in a manner not to interfere with Landlord’s construction efforts. During construction of Tenant Improvements, a representative of Tenant shall inspect the site no less frequently than once a week and verify and agree that the work in progress has been completed in a manner acceptable to Tenant. 3.6 The Tenant Improvements shall be commenced upon issuance of the building permit by governmental entities having jurisdiction therefor and, subject to authorized adjustments, Substantial Completion is estimated to be achieved on or about January 15, 2004. As used herein the term “Substantial Completion” shall mean that the Leased Premises have been built and completed in substantial conformity with the Plans, and a temporary or permanent certificate of occupancy or a temporary or permanent certificate of acceptance (“CO/CA”) has been issued permitting Tenant to use and occupy the Leased Premises, even though minor details, adjustments or punch list items which shall not materially impair Tenant’s use and enjoyment of the Leased Premises may not have been finally completed, but which work Landlord agrees shall be diligently pursued to final completion. Tenant shall allow Landlord and its contractors to enter the Leased Premises during normal working hours after issuance of the CO/CA to complete remaining minor work or punch list items, provided Landlord gives advance notice and makes reasonable efforts not to interfere with Tenant’s operations. It is agreed that for the purpose of this Lease, wherever and whenever the term Substantial Completion is used, it shall not include items of maintenance, service, punch list, or guarantee. If the date of Substantial Completion occurs on a day other than the first day of a month, rent from such day until the first day of the following month shall be prorated (at a rate of 1/30th of the monthly rent per day). During said period of partial monthly occupancy, all other terms and conditions of this Lease shall apply.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Maintenance Repairs and Alterations A. Except to the extent such obligations are imposed upon Landlord hereunder, Tenant shall, at its sole cost and expense, maintain the interior of the Premises in good order, condition and repair throughout the entire Lease Term, ordinary wear and tear excepted. Tenant agrees to keep the areas visible from outside the Premises in a neat, clean and attractive condition at all times. Tenant shall, within thirty (30) days after Landlord’s written demand therefor, reimburse Landlord for the cost of all repairs, replacements and alterations (collectively, “Repairs”) in and to the Premises, Building and Property and the facilities and systems thereof, plus an administration charge often percent (10%) of such cost, the need for which Repairs arises out of (and provided Landlord has given prior written notice to Tenant of such need): (1) Tenant’s use of the Premises in contravention of the terms and conditions of this Lease, or Tenant’s failure to perform maintenance or repairs which are Tenant’s obligation hereunder, (2) the installation, removal, use or operation of Tenant’s Property, if undertaken by Landlord at Tenant’s request or by virtue of Tenant’s default in undertaking such obligations, (3) the moving of Tenant’s Property into or out of the Building, or (4) the act, omission, misuse or negligence of Tenant, its agents, contractors, employees or invitees. B. Tenant shall not make or allow to be made any alterations, additions or improvements to the Premises (collectively, “Alterations”), without first obtaining the written consent of Landlord, which consent shall not be unreasonably withheld or delayed; provided however, Tenant shall have the right to perform, without Landlord’s consent, certain Alterations that do not cost in excess of $25,000.00 in the aggregate (at any one time), and do not affect any mechanical or electrical or life safety systems or plumbing in the Building, provided that advance notice has been given to Landlord in each instance. Landlord reserves the right to require Tenant to remove at the end of the Lease Term any Alterations installed without the Landlord’s consent. Prior to commencing any such Alterations and as a condition to obtaining Landlord’s consent where necessary, Tenant shall deliver to Landlord plans and specifications acceptable to Landlord; names and addresses of contractors reasonably acceptable to Landlord; copies of contracts; necessary permits and approvals; evidence of contractor’s and subcontractor’s insurance in accordance with Section 13 hereof; and a payment bond or other security, all in form and amount satisfactory to Landlord. Tenant shall be responsible for insuring that all such persons procure and maintain insurance coverage against such risks, in such amounts and with such companies as Landlord may reasonably require. All Alterations shall be constructed in a good and workmanlike manner using Building standard materials or other new materials of equal or greater quality. Landlord, to the extent reasonably necessary to avoid any disruption to the tenants and occupants of the Building, shall have the right to designate the time when any Alterations may be performed and to otherwise designate reasonable rules, regulations and procedures for the performance of work in the Building. Upon completion of the Alterations, Tenant shall deliver to Landlord “as-built” plans, contractor’s affidavits and full and final waivers of lien and receipted bills covering all labor and materials. All Alterations shall comply with the insurance requirements and with applicable codes, ordinances, laws and regulations. Tenant shall reimburse Landlord upon demand for all reasonable sums, if any, expended by Landlord for third party examination of the architectural, mechanical, electrical and plumbing plans for any Alterations. In addition, if Landlord so requests, Landlord shall be entitled to oversee the construction of any Alterations, and in such event, Tenant shall reimburse Landlord for Landlord’s actual out of pocket costs incurred in connection therewith, which may include the cost of management personnel working outside of Normal Business Hours. Landlord’s approval of Tenant’s plans and specifications for any Alterations performed for or on behalf of Tenant shall not be deemed to be representation by Landlord that such plans and specifications comply with applicable insurance requirements, building codes, ordinances, laws or, regulations or that the Alterations constructed in accordance with such plans and specifications will be adequate for Tenant’s use.

  • Repairs and Alterations (14.1) Tenant shall keep and maintain the Leased Premises in good repair and condition; keep in good running order the heating and air conditioning systems, electric wiring, toilets, water pipes, water, gas and electric fixtures; replace all locks and deliver keys to Landlord after replacement of locks, trimmings, glass and plate glass broken during the tenancy, regardless of the manner in which same may have been broken, unstop all water fixtures that may become choked and repair all water pipes and plumbing that may burst. If any elevators, escalators, lifts, machinery or appliances (herein called "equipment") are situate on the Leased Premises, Tenant shall care for, maintain and repair same, and shall indemnify and save harmless Landlord from any liability or claims for damages or injuries to persons and property arising therefrom. Tenant shall not make any alterations of, additions to or changes in the Leased Premises or equipment without the prior written consent of Landlord, which consent shall not be unreasonably withheld, and all alterations, changes and improvements, by whomsoever made, shall be the property of Landlord. (14.2) Tenant agrees that all additions and improvements and attached equipment and fixtures installed in or on the Leased Premises by the Tenant, including but not being limited to, electric wiring, electric fixtures, show window reflectors, screens, screen doors, awnings, awnings frames floor coverings, landscaping, furnaces and air conditioning machinery and equipment, shall immediately become the property of the Landlord and shall not be removed by Tenant at the termination of this Lease, unless requested to do so by the Landlord, in which event Tenant agrees to do so and to repair promptly any damage caused by such removal. (14.3) Nothing contained in this Lease shall be construed as requiring Landlord to make any repairs, except of a structural nature. Landlord shall maintain and make all necessary structural repairs to the foundations, load bearing walls and roof. This does not include the repairing of any glass or moving parts such as passage and overhead doors. (The Tenant will maintain the ------ common areas as outlined in the Addendum.) alterations, rebuilding, replacements, changes or additions placed by Tenant thereon, in as good condition and repair as the same were in at the commencement of the original term, normal wear and tear excepted; provided, however, Tenant shall not be required to return the Leased Premises and equipment in as good condition as aforesaid if the same are damaged or destroyed by fire or otherwise, unless caused by Tenant's fault or negligence which is not adequately covered by insurance.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Improvements and Alterations (a) Landlord shall deliver the Premises to Tenant, and Tenant agrees to accept the Premises from Landlord in its existing “AS-IS”, “WHERE-IS” and “WITH ALL FAULTS” condition, and Landlord shall have no obligation to refurbish or otherwise improve the Premises throughout the Lease Term; provided, however, and notwithstanding the foregoing to the contrary Landlord’s sole construction obligation under this Lease is set forth in the Work Letter attached hereto as Exhibit B. In addition, with respect to the area in the Suite 600 Space generally shown in Exhibit I attached hereto and incorporated herein for all purposes, Landlord at its sole cost and expense, agrees (i) to add five 12” Building standard cooling only VAV boxes, (ii) that a new supply air plenum will be added to the box and the supply air tap-outs will be cut in, (iii) that a total of four 12-inch supply air diffusers will be installed in a quadrant pattern, and (iv) that all thermostats will be relocated to their respective zones. (b) Any alterations, additions, or improvements made by or on behalf of Tenant to the Premises (“Alterations”) shall be subject to Landlord’s prior written consent. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Laws and shall construct, at its sole cost and expense, any alteration or modification required by Laws as a result of any Alterations. All Alterations shall be constructed at Tenant’s sole cost and expense and in a good and workmanlike manner by contractors reasonably acceptable to Landlord and only good grades of materials shall be used. All plans and specifications for any Alterations shall be submitted to Landlord for its approval. Landlord may monitor construction of the Alterations. Tenant shall reimburse Landlord for all out-of-pocket sums, if any paid by Landlord for third party examination of Tenant’s plans and specifications for any Alterations. In addition, Tenant shall be obligated to pay Landlord a coordination fee equal to ten percent (10%) of the actual costs of any of such Alterations, which coordination fee shall be paid to Landlord promptly following the completion of the construction of the Alterations. Such coordination fee will be deemed to cover all of Landlord’s costs and expenses for Landlord’s employees or contractors, including but not limited to management personnel, engineers and other consultants involved in review, approval coordination and/or supervision of the Alterations. Landlord’s right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to see that such plans and specifications or construction comply with applicable laws, codes, rules and regulations. Without limiting the other grounds upon which Landlord may refuse to approve any contractor or subcontractor Landlord may take into account the desirability of maintaining harmonious labor relations at the Project. Landlord may also require that all life safety related work and all mechanical electrical plumbing and roof related work be performed by contractors designated by Landlord. Landlord shall have the right, in its sole discretion to instruct Tenant to remove those improvements or Alterations from the Premises which (i) were not approved in advance by Landlord (ii) were not built in conformance with the plans and specifications approved by Landlord or (iii) Landlord specified during its review of plans and specifications for Alterations would need to be removed by Tenant upon the expiration of this Lease. Except as set forth in the preceding sentence, Tenant shall not be obligated to remove such Alterations at the expiration of this Lease. Landlord shall not unreasonably withhold or delay its approval with respect to what improvements or Alterations Landlord may require Tenant to remove at the expiration of the Lease. If upon the termination of this Lease, Landlord require Tenant to remove any or all of such Alterations from the Premises, then Tenant, al Tenant’s sole cost and expense, shall promptly remove such Alterations and improvements and Tenant shall repair and restore the Premises to its original condition as of the Commencement Date, reasonable wear and tear excepted. Any Alterations remaining in the Premises following the expiration of the Lease Term or following the surrender of the Premises from Tenant to Landlord, shall become the property of Landlord unless Landlord notifies Tenant otherwise. Tenant shall provide Landlord with the identities and mailing addresses of

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.