Pupil Safety and Fingerprinting CONTRACTOR shall comply with all provisions of the Education Code which protect the safety of any pupil that may come in contact with employees of the CONTRACTOR. Pursuant to Education Code section 45125.1, CONTRACTOR shall conduct criminal background checks of ALL employees of CONTRACTOR assigned to the PROJECT site, and shall certify that no employees who have been convicted of serious or violent felonies, as specified in Education Code Section 45125.1, will have contact with pupils, by utilizing the General Certification Regarding Background Checks Form. As part of such certification, CONTRACTOR must provide the District with a list of all employees providing services pursuant to this Agreement, and designate which sites such employees will be assigned. In performing the services set forth in this Agreement, CONTRACTOR shall not utilize any employees who are not included on the above-referenced list. At District’s sole discretion, District may make a finding, as authorized under Education Code section 45125.1, that CONTRACTOR’s employees will have only “limited contact” with pupils. In accordance with Education Code Section 45125.2, a CONTRACTOR performing construction, reconstruction, rehabilitation or repair services to a school facility shall not be required to perform Section 45125.1 background checks of all employees assigned to the PROJECT site if such CONTRACTOR installs a physical barrier at the worksite to limit employee contact with pupils and/or provides continual supervision and monitoring of all employees of the CONTRACTOR by an employee of the CONTRACTOR whom the Department of Justice has ascertained has not been convicted of a violent or serious felony. Such CONTRACTOR shall certify to the District its compliance with one of the aforementioned alternatives under Education Code Section 45125.2 pertaining to pupil safety with the form entitled CONSTRUCTION CONTRACTOR CERTIFICATION REGARDING BACKGROUND CHECKS which is on file at the Administrative Office of the DISTRICT. Contractor’s failure to comply with the law or Article VI, Paragraph 4 of this Agreement shall be considered a material breach of this Agreement upon where this Agreement may be terminated, at District’s sole discretion, without any further compensation to Contractor.
COMPLIANCE WITH HEALTH, SAFETY, AND ENVIRONMENTAL REGULATIONS The Contractor, it’s Subcontractors, and their respective employees, shall comply fully with all applicable federal, state, and local health, safety, and environmental laws, ordinances, rules and regulations in the performance of the services, including but not limited to those promulgated by the City and by the Occupational Safety and Health Administration (OSHA). In case of conflict, the most stringent safety requirement shall govern. The Contractor shall indemnify and hold the City harmless from and against all claims, demands, suits, actions, judgments, fines, penalties and liability of every kind arising from the breach of the Contractor’s obligations under this paragraph.
HEALTH, SAFETY AND ENVIRONMENT 41.1 In the performance of this Contract, Contractor and Operator shall conduct Petroleum Operations with due regard to health, safety and the protection of the environment (“HSE”) and the conservation of natural resources, and shall in particular:
Health and Safety Training Regular employees and auxiliary employees in posted positions shall participate in a Health and Safety Training session once in a calendar year. The training program offered by the Employer must be approved by the joint Health and Safety Committee prior to such training commencing. Training will be provided during normal work hours and employees shall suffer no loss of pay or benefits.
Environmental Health and Safety i. Environment, Health and Safety Performance. Seller acknowledges and accepts full and sole responsibility to maintain an environment, health and safety management system ("EMS") appropriate for its business throughout the performance of this Contract. Buyer expects that Seller’s EMS shall promote health and safety, environmental stewardship, and pollution prevention by appropriate source reduction strategies. Seller shall convey the requirement of this clause to its suppliers. Seller shall not deliver goods that contain asbestos mineral fibers.
Health and Safety Requirements The Contractor and his subcontractors ensure at all times compliance with safety regulations imposed by any Act of Parliament, ordinance or any regulation or by¬law of any local or statutory authority. Occupational Health and Safety Act (Act of 1993-Section 37) The Contractor shall comply with: The Occupational Health and Safety Xxx, 0000, and all Regulations made there under; All Eskom Safety and Operating Procedures listed in this Works Information. The Contractor acknowledges that it is fully aware of the requirements of all the above and undertakes to employ only people who have been duly authorised in terms thereof and who have received sufficient training to ensure that they can comply therewith. The Contractor undertakes not to do, or not to allow anything to be done which will contravene any of the provisions of the Act, Regulations or Safety and Operating Procedures. The Contractor shall appoint a person who will liaise with the Eskom Safety Officer responsible for the premises relevant to this contract. The person so appointed shall, on request: Supply the Eskom Safety Officer with copies of minutes of all Health and Safety Committee meetings, whenever he is required to do so; Supply the Eskom Safety Officer with copies of all appointments in respect of employees employed on this contract, in terms of the Act and Regulations and shall advise the Eskom Safety Officer of any changes thereto. Eskom may, at any stage during the currency of this agreement, be entitled to: Do safety audits at the Contractor’s premises, its work-places and on its employees; Refuse any employee, sub-contractor or agent of the Contractor access to its premises if such person has been found to commit any unlawful act or any unsafe working practice or is found to be not authorised or qualified in terms of the Act;
ENVIRONMENT, SAFETY AND HEALTH PROTECTION (a) Seller shall perform this Agreement in a manner that ensures adequate protection for workers, the public, and the environment, and shall be accountable for actions of itself and its lower-tier subcontractors, agents and employees. Seller shall exercise a degree of care commensurate with the work and the associated hazards. Seller shall ensure that management of environment, safety and health (ES&H) functions and activities is an integral and visible part of Seller’s work planning and execution process. In the event that Xxxxxx fails to comply with this Agreement, Company may, without prejudice to any other legal or contractual rights, issue an order stopping all or any part of the work; thereafter a start order for resumption of work may be issued at Company’s discretion. Seller shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage. In addition, Company may require, in writing, that Seller remove from the work any employee the Company deems unsafe, incompetent, careless, or otherwise objectionable.
Health & Safety (a) The Employer and the Union agree that they mutually desire to maintain standards of safety and health in the Home, in order to prevent injury and illness and abide by the Occupational Health and Safety Act as amended from time to time.
Health and Safety Standards Contractor shall abide by all health and safety standards set forth by the State of California and/or the County of Xxxxxx pursuant to the Injury and Illness Prevention Program. If applicable, Contractor must receive all health and safety information and training from County.
Safety and Compliance The Company commits to make all management and employees aware of all the changes to the Occupational Health and Safety Act and Regulations. This should be done via training courses and or union seminars. The conducting of the training and or seminars shall be at times convenient to the company.
