Conduct of Local Church Operations From the date of this Disaffiliation Agreement through and until the Closing, the Local Church: (a) will conduct its operations substantially in accordance with past practice and will use commercially reasonable efforts, subject to the foregoing, to maintain and preserve its operations and organization consistent with past practice and efficient and economical management, (b) will not take any action that is inconsistent with its charitable purposes under Section 501(c)(3) of the Code or that otherwise adversely affects its tax-exempt status, and (c) will not take any action that would cause its representations and warranties in this Disaffiliation Agreement not to remain true and correct as of Closing, except with the prior written consent of the Annual Conference.
Outside Activities of Limited Partners Subject to any agreements entered into by a Limited Partner or its Affiliates with the General Partner, Partnership or a Subsidiary, any Limited Partner and any officer, director, employee, agent, trustee, Affiliate or stockholder of any Limited Partner shall be entitled to and may have business interests and engage in business activities in addition to those relating to the Partnership, including business interests and activities in direct competition with the Partnership or that are enhanced by the activities of the Partnership. Neither the Partnership nor any Partners shall have any rights by virtue of this Agreement in any business ventures of any Limited Partner or Assignee. Subject to such agreements, none of the Limited Partners nor any other Person shall have any rights by virtue of this Agreement or the partnership relationship established hereby in any business ventures of any other Person, other than the Limited Partners benefiting from the business conducted by the General Partner, and such Person shall have no obligation pursuant to this Agreement to offer any interest in any such business ventures to the Partnership, any Limited Partner or any such other Person, even if such opportunity is of a character which, if presented to the Partnership, any Limited Partner or such other Person, could be taken by such Person.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Authority of the Asset Manager (a) Except as set forth in Section 2(e) below and in any guidance as may be established from time to time by the managing member of the Series or the Advisory Board, the Asset Manager shall have sole authority and complete discretion over the care, custody, maintenance and management of the Series #TICKER Asset and to take any action that it deems necessary or desirable in connection therewith. The Asset Manager is authorized on behalf of the Series to, among other things:
(i) purchase and maintain insurance coverage for the Series #TICKER Asset for the benefit of the Series;
(ii) engage third party independent contractors for the care, custody, maintenance and management of the #TICKER Asset;
(iii) develop standards for the care and transportation of the Series #TICKER Asset while in and outside of storage, as applicable;
(iv) reasonably make all determinations regarding the calculation of fees, expenses and other amounts relating to the Series #TICKER Asset paid by the Asset Manager hereunder;
(v) deliver invoices to the managing member of the Company for the payment of all fees and expenses incurred by the Series in connection with the maintenance and operation of the Series #TICKER Asset and ensure delivery of payments to third parties for any such services; and
(vi) generally perform any other act necessary to carry out its obligations under this Agreement.
(b) The Asset Manager shall have full responsibility for the maintenance of the Series #TICKER Asset and handling of inspections.
(c) The Asset Manager shall devote such time to its duties under this Agreement as may be deemed reasonably necessary by the Asset Manager in light of the understanding that such duties are expected to be performed only at occasional or irregular intervals.
(d) The Asset Manager may delegate all or any of its duties under this Agreement to any Person who shall perform such delegated duties under the supervision of the Asset Manager on such terms as the Asset Manager shall determine.
(e) Notwithstanding any other provision of this Agreement to the contrary, the Asset Manager shall not have the authority to:
(i) acquire any asset or service for an amount equal to or greater than 1% of the value of the Series #TICKER Asset as of such date, individually, or 3% of the value of the Series #TICKER Asset as of such date, in the aggregate, without the prior consent of the managing member of the Series; or
(ii) sell, transfer or convey the Series #TICKER Asset, provided, however, that the Asset Manager may deliver to the managing member of the Company any offers received by the Asset Manager to purchase the Series #TICKER Asset and any research or analysis prepared by the Asset Manager regarding the potential sale of the Series #TICKER Asset, including market analysis, survey results or information regarding any inquiries received and information regarding potential purchasers.
Amendment of Limited Liability Company Agreement (a) Except as otherwise provided in this Section 8.1, this Agreement may be amended, in whole or in part, with: (i) the approval of the Board (including the vote of a majority of the Independent Directors, if required by the 0000 Xxx) without the Members approval; and (ii) if required by the 1940 Act, the approval of the Members by such vote as is required by the 0000 Xxx.
(b) Any amendment that would:
(i) increase the obligation of a Member to make any contribution to the capital of the Company;
(ii) reduce the Capital Account of a Member other than in accordance with Article V; or
(iii) modify the events causing the dissolution of the Company; may be made only if (i) the written consent of each Member adversely affected thereby is obtained prior to the effectiveness thereof or (ii) such amendment does not become effective until (A) each Member has received written notice of such amendment and (B) any Member objecting to such amendment has been afforded a reasonable opportunity (pursuant to such procedures as may be prescribed by the Board) to tender its entire Interest for repurchase by the Company.
(c) The power of the Board to amend this Agreement at any time without the consent of the other Members as set forth in paragraph (a) of this Section 8.1 shall specifically include the power to:
(i) restate this Agreement together with any amendments hereto that have been duly adopted in accordance herewith to incorporate such amendments in a single, integrated document;
(ii) amend this Agreement (other than with respect to the matters set forth in Section 8.1(b) hereof) to effect compliance with any applicable law or regulation or to cure any ambiguity or to correct or supplement any provision hereof that may be inconsistent with any other provision hereof; and
(iii) amend this Agreement to make such changes as may be necessary or advisable to ensure that the Company will not be treated as an association or a publicly traded partnership taxable as a corporation as defined in Section 7704(b) of the Code for U.S. federal income tax purposes.
(d) The Board shall cause written notice to be given of any amendment to this Agreement to each Member, which notice shall set forth (i) the text of the proposed amendment or (ii) a summary thereof and a statement that the text of the amendment thereof will be furnished to any Member upon request.
Approval by Limited Partners (a) Except as provided in Section 14.3(d) and Section 14.3(e), the General Partner, upon its approval of the Merger Agreement or the Plan of Conversion, as the case may be, shall direct that the Merger Agreement or the Plan of Conversion, as applicable, be submitted to a vote of Limited Partners, whether at a special meeting or by written consent, in either case in accordance with the requirements of Article XIII. A copy or a summary of the Merger Agreement or the Plan of Conversion, as the case may be, shall be included in or enclosed with the notice of a special meeting or the written consent and, subject to any applicable requirements of Regulation 14A pursuant to the Exchange Act or successor provision, no other disclosure regarding the proposed merger, consolidation or conversion shall be required.
(b) Except as provided in Section 14.3(d) and Section 14.3(e), the Merger Agreement or Plan of Conversion, as the case may be, shall be approved upon receiving the affirmative vote or consent of the holders of a Unit Majority unless the Merger Agreement or Plan of Conversion, as the case may be, effects an amendment to any provision of this Agreement that, if contained in an amendment to this Agreement adopted pursuant to Article XIII, would require for its approval the vote or consent of a greater percentage of the Outstanding Units or of any class of Limited Partners, in which case such greater percentage vote or consent shall be required for approval of the Merger Agreement or the Plan of Conversion, as the case may be.
(c) Except as provided in Section 14.3(d) and Section 14.3(e), after such approval by vote or consent of the Limited Partners, and at any time prior to the filing of the certificate of merger or articles of conversion pursuant to Section 14.4, the merger, consolidation or conversion may be abandoned pursuant to provisions therefor, if any, set forth in the Merger Agreement or Plan of Conversion, as the case may be.
(d) Notwithstanding anything else contained in this Article XIV or in this Agreement, the General Partner is permitted, without Limited Partner approval, to convert the Partnership or any Group Member into a new limited liability entity, to merge the Partnership or any Group Member into, or convey all of the Partnership’s assets to, another limited liability entity that shall be newly formed and shall have no assets, liabilities or operations at the time of such conversion, merger or conveyance other than those it receives from the Partnership or other Group Member if (i) the General Partner has received an Opinion of Counsel that the conversion, merger or conveyance, as the case may be, would not result in the loss of limited liability under the laws of the jurisdiction governing the other limited liability entity (if that jurisdiction is not Delaware) of any Limited Partner as compared to its limited liability under the Delaware Act or cause the Partnership to be treated as an association taxable as a corporation or otherwise to be taxed as an entity for federal income tax purposes (to the extent not previously treated as such), (ii) the sole purpose of such conversion, merger, or conveyance is to effect a mere change in the legal form of the Partnership into another limited liability entity and (iii) the General Partner determines that the governing instruments of the new entity provide the Limited Partners and the General Partner with substantially the same rights and obligations as are herein contained.
(e) Additionally, notwithstanding anything else contained in this Article XIV or in this Agreement, the General Partner is permitted, without Limited Partner approval, to merge or consolidate the Partnership with or into another limited liability entity if (i) the General Partner has received an Opinion of Counsel that the merger or consolidation, as the case may be, would not result in the loss of the limited liability of any Limited Partner under the laws of the jurisdiction governing the other limited liability entity (if that jurisdiction is not Delaware) as compared to its limited liability under the Delaware Act or cause the Partnership to be treated as an association taxable as a corporation or otherwise to be taxed as an entity for federal income tax purposes (to the extent not previously treated as such), (ii) the merger or consolidation would not result in an amendment to this Agreement, other than any amendments that could be adopted pursuant to Section 13.1, (iii) the Partnership is the Surviving Business Entity in such merger or consolidation, (iv) each Unit outstanding immediately prior to the effective date of the merger or consolidation is to be an identical Unit of the Partnership after the effective date of the merger or consolidation, and (v) the number of Partnership Interests to be issued by the Partnership in such merger or consolidation does not exceed 20% of the Partnership Interests (other than Incentive Distribution Rights) Outstanding immediately prior to the effective date of such merger or consolidation.
(f) Pursuant to Section 17-211(g) of the Delaware Act, an agreement of merger or consolidation approved in accordance with this Article XIV may (i) effect any amendment to this Agreement or (ii) effect the adoption of a new partnership agreement for the Partnership if it is the Surviving Business Entity. Any such amendment or adoption made pursuant to this Section 14.3 shall be effective at the effective time or date of the merger or consolidation.
No Physical Presence of Quorum and Participation by Audio or Video; Disaster Declaration The ability of the Board to meet in person with a quorum physically present at its meeting location may be affected by the Governor or the Director of the Ill. Dept. of Public Health issuing a disaster declaration related to a public health emergency. The Board President or, if the office is vacant or the President is absent or unable to perform the office’s duties, the Vice President determines that an in- person meeting or a meeting conducted under the Quorum and Participation by Audio or Video Means subhead above, is not practical or prudent because of the disaster declaration; if neither the President nor Vice President are present or able to perform this determination, the Superintendent shall serve as the duly authorized designee for purposes of making this determination. The individual who makes this determination for the Board shall put it in writing, include it on the Board’s published notice and agenda for the audio or video meeting and in the meeting minutes, and ensure that the Board meets every OMA requirement for the Board to meet by video or audio conference without the physical presence of a quorum.
Limitation on Out-of-State Litigation - Texas Business and Commerce Code § 272 This is a requirement of the TIPS Contract and is non-negotiable. Texas Business and Commerce Code § 272 prohibits a construction contract, or an agreement collateral to or affecting the construction contract, from containing a provision making the contract or agreement, or any conflict arising under the contract or agreement, subject to another state’s law, litigation in the courts of another state, or arbitration in another state. If included in Texas construction contracts, such provisions are voidable by a party obligated by the contract or agreement to perform the work. By submission of this proposal, Vendor acknowledges this law and if Vendor enters into a construction contract with a Texas TIPS Member under this procurement, Vendor certifies compliance.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
Limited Liability Company Agreement The Member hereby states that except as otherwise provided by the Act or the Certificate of Formation, the Company shall be operated subject to the terms and conditions of this Agreement.
