Hurricane Preparedness Sample Clauses

Hurricane Preparedness. During such periods of time as are designated by the United States Weather Bureau as being a hurricane warning, the Design-Build Firm, at no cost to the City, shall take all precautions necessary to secure the Project site in response to all threatened storm events, regardless of whether the Project Manager has given notice of same. Compliance with any specific hurricane warning or alert precautions will not constitute additional work. Suspension of the Work caused by a threatened or actual storm event, regardless of whether the City has directed such suspension, will entitle the Design-Build Firm to additional Contract time as non-compensable, excusable delay, and shall not give rise to a claim for compensable delay.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Hurricane Preparedness. ‌ Within thirty (30) calendar days of GMP submission CM shall submit to the City a Hurricane Preparedness Plan (Plan). The Plan shall include the measure to be taken by the Construction Manager in case of a hurricane or tropical storm. During such periods of time as are designated by the United States Weather Bureau as being a tropical storm/hurricane warning or alert, or at such other time deemed necessary by the City’s Project Manager the Construction Manager, at no cost beyond the GMP to the City, shall implement the Plan to secure the Project site in response to all threatened storm events, regardless of whether the City or Consultant has given notice of same. Failure of the City to direct the Construction Manager to implement the Plan shall not relieve the Construction Manager for sole responsibility for implementation of the Plan. Any damage to materials and equipment resulting from Construction Manager’s failure to implement the plan shall be removed and replaced at no cost to the City. Additional work relating to hurricane warning or alert at the Project site will be addressed by a Change Order. Suspension of the Construction Work caused by a threatened or actual storm event, regardless of whether the City has directed such suspension, will entitle the Construction Manager to additional time as non-compensable, excusable delay, and shall not give rise to a claim for compensable delay.
Sample 1
Hurricane Preparedness. During such periods of time as are designated by the United States Weather Bureau or Miami-Dade County as being a severe weather event, including a hurricane watch or warning, the Contractor, at no cost to the Village, must take all precautions necessary to secure any Work in response to all threatened storm events, regardless of whether the Contractor has been given notice of same, in accordance with the Miami-Dade County Code. Compliance with any specific severe weather event or alert precautions will not constitute additional work. Suspension of the Work caused by a threatened or actual storm event, regardless of whether the Village has directed such suspension, will entitle the Contractor to additional Contract Time as non-compensable, excusable delay.
Sample 1
Hurricane Preparedness. During such periods of time as are designated by the United States Weather Bureau as being a hurricane warning, the Contractor, at no cost to the Town, shall immediately respond by taking all precautions necessary to secure any Work threatened by storm events, regardless of whether the Contractor has been given notice of same by Project Manager or other Town representative. Compliance with any specific hurricane warning or alert precautions will not constitute additional work. Suspension of the Work caused by a threatened or actual storm event, regardless of whether the Town has directed such suspension, will entitle the Contractor to additional Contract time as non-compensable, excusable delay, and shall not give rise to a claim for compensable delay.
Sample 1
Hurricane Preparedness. The Tenant shall follow the County's emergency evacuation and hurricane plan as set forth for the CSF Building.
Sample 1
Hurricane Preparedness. In the event of a hurricane, HYC (Private Management) will use its best efforts to move (if applicable) and secure the yacht at the owner’s expense and the owner authorises such.
Sample 1
Hurricane Preparedness. User shall comply with City of Miami requirements regarding hurricanes, as the same may be amended from time to time.
Sample 1
AutoNDA by SimpleDocs

Related to Hurricane Preparedness

  • Flood If any of the Improvements are located in an area identified by the Federal Emergency Management Agency (or any successor to that agency) as a “Special Flood Hazard Area,” flood Insurance in the amount required by Lender.

  • Earthquake including land shock waves or tremors before, during or after a volcanic eruption;

  • Earthquake Insurance If Lessor desires to obtain some form of earthquake insurance in the future, if and when available, on terms acceptable to Lessor as determined in the sole and absolute discretion of Lessor, then as a condition of Lessor agreeing to waive the requirement for earthquake insurance, Lessee agrees that it will pay, as additional Rent, which shall be included in the monthly CAC, an amount not to exceed Forty Seven Thousand Eight Hundred and Thirty Three Dollars ($47,833) per year.

  • Shortages Claims for shortages in the amount of Products shipped by Patheon will be dealt with by reasonable agreement of the parties.

  • Environmental Hazards (a) Except for matters described in Section 18(b), Borrower shall not cause or permit any of the following:

  • Sprinklers Subject to any terms, conditions and limitations set forth herein, Landlord shall provide an operative sprinkler system consisting of mains, laterals, and heads “AS IS” on the date of delivery of the Premises to Tenant. Tenant shall pay for piping distribution, drops and relocation of, or additional, sprinkler system heads and Building firehose or firehose valve cabinets, if Tenant’s Plans and/or any applicable Laws necessitate such.

  • Disaster Recovery PFPC shall enter into and shall maintain in effect with appropriate parties one or more agreements making reasonable provisions for emergency use of electronic data processing equipment to the extent appropriate equipment is available. In the event of equipment failures, PFPC shall, at no additional expense to the Fund, take reasonable steps to minimize service interruptions. PFPC shall have no liability with respect to the loss of data or service interruptions caused by equipment failure, provided such loss or interruption is not caused by PFPC's own willful misfeasance, bad faith, gross negligence or reckless disregard of its duties or obligations under this Agreement.

  • Casualty Damage A. If all or any part of the Premises is damaged by fire or other casualty, Tenant shall immediately notify Landlord in writing. During any period of time that all or a material portion of the Premises is rendered untenantable as a result of a fire or other casualty, the Rent shall xxxxx for the portion of the Premises that is untenantable and not used by Tenant. Landlord shall have the right to terminate this Lease if: (1) the Building or the Project shall be damaged so that, in Landlord’s reasonable judgment, substantial alteration or reconstruction of the Building or the Project shall be required (whether or not the Premises has been damaged); (2) Landlord is not permitted by Law to rebuild the Building or the Project in substantially the same form as existed before the fire or casualty; (3) the Premises have been materially damaged and there is less than eighteen (18) months of the Term remaining on the date of the casualty; (4) any Mortgagee requires that the insurance proceeds be applied to the payment of the mortgage debt; or (5) a material uninsured loss to the Building or the Project occurs. Landlord may exercise its right to terminate this Lease by notifying Tenant in writing within 90 days after the date of the casualty. If Landlord does not terminate this Lease, Landlord shall commence and proceed with reasonable diligence to repair and restore the Building and the Premises Improvements (excluding any Alterations that were performed by Tenant in violation of this Lease). However, in no event shall Landlord be required to spend more than the insurance proceeds received by Landlord. Landlord shall not be liable for any loss or damage to Tenant’s Property or to the business of Tenant resulting in any way from the fire or other casualty or from the repair and restoration of the damage. Landlord and Tenant hereby waive the provisions of any Law relating to the matters addressed in this Article, and agree that their respective rights for damage to or destruction of the Premises shall be those specifically provided in this Lease. Tenant shall have the right to terminate this Lease i 1: (a) a substantial portion of the Premises has been damaged by fire or other casualty and such damage cannot reasonably be repaired (as reasonably determined by Landlord) within 60 days after Landlord’s receipt of all required permits to restore the Premises; (b) there is less than eighteen (18) months of the Term remaining on the date of such casualty; and (c) Tenant provides Landlord with written notice of its intent to terminate within thirty (30) days after the date of the fire or other casualty.

  • Accidents and Claims The Manager shall promptly investigate and report in detail to the Owner all accidents, claims for damage relating to the ownership, operation or maintenance of the Properties, and any damage or destruction to the Properties and the estimated costs of repair thereof, and shall prepare for approval by the Owner all reports required by an insurance company in connection with any such accident, claim, damage, or destruction. Such reports shall be given to the Owner promptly and any report not so given within ten (10) days after the occurrence of any such accident, claim, damage or destruction shall be noted in the report delivered to the Owner pursuant to Section 2.5(b). The Manager is authorized to settle any claim against an insurance company arising out of any policy and, in connection with such claim, to execute proofs of loss and adjustments of loss and to collect and provide receipts for loss proceeds.

Time is Money Join Law Insider Premium to draft better contracts faster.