IN RIGHTS IN FAVOUR OF THE AUTHORITY Sample Clauses

IN RIGHTS IN FAVOUR OF THE AUTHORITY. The FM Contractor will not exercise or seek to exercise any right which may be or becomes available to it to terminate or treat as terminated or repudiated the FM Agreement or its employment under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than thirty (30) Business Days’ prior written notice specifying the FM Contractor's ground for terminating or treating as terminated or repudiated the FM Agreement or its employment under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the FM Agreement. Within such period of notice: the Authority may give written notice to the FM Contractor that the Authority will thenceforth become the client under the FM Agreement to the exclusion of the Contractor and thereupon the FM Contractor will admit that the Authority is its client under the FM Agreement and the FM Agreement will be and remain in full force and effect notwithstanding any of the said grounds; if the Authority has given such notice as aforesaid or under clause 7.3, the Authority shall accept liability for the Contractor's obligations under the FM Agreement and will as soon as practicable thereafter remedy any outstanding breach by the Contractor including for the avoidance of doubt any non-payment of sums due to the FM Contractor that properly has been included in the FM Contractor's specified grounds pursuant to clause 7.1 (and which has been notified to the Authority) and which is capable of remedy; and if the Authority has given such notice as aforesaid or under clause 7.3, the Authority will from the service of such notice become responsible for all sums properly payable to the FM Contractor under the FM Agreement accruing due after the service of the FM Contractor's notice but the Authority will in paying such sums be entitled to the same rights of set-off and deduction as would have applied to the Contractor under the FM Agreement.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The FM Contractor will not exercise or seek to exercise any right which may be or becomes available to it to terminate or treat as terminated or repudiated the FM Agreement or its employment under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than thirty (30) Business Days’ prior written notice specifying the FM Contractor's ground for terminating or treating as terminated or repudiated the FM Agreement or its employment under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the FM Agreement. Within such period of notice:
Sample 1
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The Building Contractor will not exercise or seek to exercise any right which may be or become available to it to terminate or treat as terminated or repudiated the Building Contract or its engagement under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than [thirty (30)] days' prior written notice specifying the Building Contractor's ground for terminating or treating as terminated or repudiated the Building Contract or its engagement under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the Building Contract. Within such period of notice:
Sample 1
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The Consultant will not exercise or seek to exercise any right which may be or become available to it to terminate or treat as terminated or repudiated the Appointment or its engagement under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than [thirty (30)] days' prior written notice specifying the Consultant's ground for terminating or treating as terminated or repudiated the Appointment or its engagement under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the Appointment. Within such period of notice:
Sample 1
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The Building Contractor will not exercise or seek to exercise any right which may be or become available to it to terminate or treat as terminated or repudiated the Building Contract or its engagement under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than [thirty (30)]twenty (20) Business Days’ prior written (seven (7) days' prior written notice of suspension in the event of non payment under the Building Contract) notice specifying the Building Contractor's ground for terminating or treating as terminated or repudiated the Building Contract or its engagement under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the Building Contract. Within such period of notice:
Sample 1
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The SubcontractorPrincipal Building Sub-Contractor will not exercise or seek to exercise any right which may be or become available to it to terminate or treat as terminated or repudiated the Subcontract or its engagement under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than [thirty (30)] days'twenty (20) Business Days’ prior written notice (and seven (7) days’ prior written notice of suspension in the event of non-payment under the Subcontract) specifying the SubcontractorPrincipal Building Sub-Contractor's ground for terminating or treating as terminated or repudiated the Subcontract or its engagement under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the Subcontract. Within such period of notice:
Sample 1
IN RIGHTS IN FAVOUR OF THE AUTHORITY. The Consultant will not exercise or seek to exercise any right which may be or become available to it to terminate or treat as terminated or repudiated the Appointment or its engagement under it or discontinue or suspend the performance of any duties or obligations thereunder without first giving to the Authority not less than [thirty (30)] daystwenty (20) Business Days' prior written notice (and seven (7) days’ prior written notice of suspension in the event of non-payment under the Appointment) specifying the Consultant's ground for terminating or treating as terminated or repudiated the Appointment or its engagement under it or discontinuing or suspending its performance thereof and stating the amount (if any) of monies outstanding under the Appointment. Within such period of notice:
Sample 1
AutoNDA by SimpleDocs

Related to IN RIGHTS IN FAVOUR OF THE AUTHORITY

  • IN FAVOUR OF HSBC BANK PLC a company incorporated under the laws of England and Wales whose office is at 0 Xxxxxx Xxxxxx, Xxxxxx X00 0XX, Xxxxxxx (the “Trustee”) as trustee for the Beneficiaries.

  • Power of the Authority to undertake works (i) In the event the Parties are unable to agree to the proposed Change of Scope Orders in accordance with Clause 13.2, the Authority may, after giving notice to the Contractor and considering its reply thereto, award such Works or services to any person or agency on the basis of open competitive bidding. It is also agreed that the Contractor shall provide assistance and cooperation to the person or agency who undertakes the works or services hereunder. The Contractor shall not be responsible for rectification of any Defects, but the Contractor shall carry out maintenance of such works after completion of Defect Liability Period of work by other person or agency during the remaining period of this agreement without any extra payment. (ii) The Works undertaken in accordance with this Clause 13.5 shall conform to the Specifications and Standards and shall be carried out in a manner that minimises the disruption in operation of the Project Highway. The provisions of this Agreement, insofar as they relate to Works and Tests, shall apply mutatis mutandis to the Works carried out under this Clause 13.5.

  • Access to the Authority and the Authority’s Engineer (i) The Right of Way given to the Contractor hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement. (ii) The Contractor shall ensure, subject to all relevant safety procedures, that the Authority has un-restricted access to the Site during any emergency situation, as decided by the Authority’s Engineer.

  • March-in Rights The Performer agrees that, with respect to any subject invention in which it has retained title, DARPA has the right to require the Performer, an assignee, or exclusive licensee of a subject invention to grant a non-exclusive license to a responsible applicant or applicants, upon terms that are reasonable under the circumstances, and if the Performer, assignee, or exclusive licensee refuses such a request, DARPA has the right to grant such a license itself if DARPA determines that: 1. Such action is necessary because the Performer or assignee has not taken effective steps, consistent with the intent of this Agreement, to achieve practical application of the subject invention; 2. Such action is necessary to alleviate health or safety needs which are not reasonably satisfied by the Performer, assignee, or their licensees; 3. Such action is necessary to meet requirements for public use and such requirements are not reasonably satisfied by the Performer, assignee, or licensees; or 4. Such action is necessary because the agreement required by paragraph (H) of this Article has not been obtained or waived or because a licensee of the exclusive right to use or sell any subject invention in the United States is in breach of such Agreement.

  • Certain Rights With the approval of Beneficiary, Trustee shall have the right to take any and all of the following actions: (a) to select, employ and advise with counsel (who may be, but need not be, counsel for Beneficiary) upon any matters arising hereunder, including the preparation, execution and interpretation of the Security Documents, and shall be fully protected in relying as to legal matters on the advice of counsel; (b) to execute any of the trusts and powers hereof and to perform any duty hereunder either directly or through his agents or attorneys; (c) to select and employ, in and about the execution of his duties hereunder, suitable accountants, engineers and other experts, agents and attorneys-in-fact, either corporate or individual, not regularly in the employ of Trustee, and Trustee shall not be answerable for any act, default or misconduct of any such accountant, engineer or other expert, agent or attorney-in-fact, if selected with reasonable care, or for any error of judgment or act done by Trustee in good faith, or be otherwise responsible or accountable under any circumstances whatsoever, except for Trustee’s gross negligence or bad faith; and (d) to take any and all other lawful action as Beneficiary may instruct Trustee to take to protect or enforce Beneficiary’s rights hereunder. Trustee shall not be personally liable in case of entry by him, or anyone entering by virtue of the powers herein granted him, upon the Mortgaged Property for debts contracted or liability or damages incurred in the management or operation of the Mortgaged Property. Trustee shall have the right to rely on any instrument, document or signature authorizing or supporting any action taken or proposed to be taken by him hereunder, believed by him in good faith to be genuine. Trustee shall be entitled to reimbursement for expenses incurred by him in the performance of his duties hereunder and to reasonable compensation for such of his services hereunder as shall be rendered. Grantor will, from time to time, pay the compensation due to Trustee hereunder and reimburse Trustee for, and save him harmless against, any and all liability and expenses which may be incurred by him in the performance of his duties.

  • Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder. (ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works. (iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor: (a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre. (b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7 (c) all environmental clearances as required under Clause 4.3.8 (iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.

  • The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).

  • Certain Rights of the Agent The Agent shall have the right to take any action with respect to the Collateral, on behalf of all of the Secured Parties. To the extent practical, the Agent shall request instructions from the Secured Parties with respect to any material act or action (including failure to act) in connection with the Agreement or any other Transaction Document, and shall be entitled to act or refrain from acting in accordance with the instructions of a Majority in Interest; if such instructions are not provided despite the Agent’s request therefor, the Agent shall be entitled to refrain from such act or taking such action, and if such action is taken, shall be entitled to appropriate indemnification from the Secured Parties in respect of actions to be taken by the Agent; and the Agent shall not incur liability to any person or entity by reason of so refraining. Without limiting the foregoing, (a) no Secured Party shall have any right of action whatsoever against the Agent as a result of the Agent acting or refraining from acting hereunder in accordance with the terms of the Agreement or any other Transaction Document, and the Debtors shall have no right to question or challenge the authority of, or the instructions given to, the Agent pursuant to the foregoing and (b) the Agent shall not be required to take any action which the Agent believes (i) could reasonably be expected to expose it to personal liability or (ii) is contrary to this Agreement, the Transaction Documents or applicable law.

  • Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.

  • Without limiting any of the rights of Indemnitee under the Articles as they may be amended from time to time, this Agreement constitutes the entire agreement between the parties hereto with respect to the subject matter hereof and supersedes all prior agreements and understandings, oral, written and implied, between the parties hereto with respect to the subject matter hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!