Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement, or (b) that Licensee’s use of the Licensed Software infringes on any intellectual property rights of such third party, provided, however, that Licensee’s use is consistent with the terms of this Agreement and that the Action is not caused by the use of the Licensed Software or any component thereof in combination with any other system, equipment or Software where but for such use, the Action for infringement would not lie. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification of Licensee Drake hereby agrees to indemnify and hold Licensee harmless from and against any and all liabilities, losses, costs, expense, damages, and deficiencies during the term of this Agreement, including, without limitation, court costs and reasonable attorney fees, which directly or indirectly arise out of, result from or relate to any and all liabilities, obligations, or claims, whether accrued, absolute, contingent, or otherwise, which have as a basis the intellectual property ownership of the Software. Licensee agrees to notify Drake of such claims in writing within thirty (30) days of becoming aware of said claim.
INDEMNIFICATION PROVISIONS Contractor agrees to indemnify, defend with counsel approved in writing by County, and hold County, its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) harmless from any claims, demands or liability of any kind or nature, including but not limited to personal injury or property damage, arising from or related to the services, products or other performance provided by Contractor pursuant to this Contract. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County or County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither party shall request a jury apportionment.
Indemnification; Remedies The Company shall indemnify the Purchaser, each affiliate of the Purchaser, and each of the following parties participating in a Securitization Transaction: each Sponsor; each issuing entity; each Person (including, but not limited to, any Master Servicer if applicable) responsible for the preparation, execution or filing of any report required to be filed with the Commission with respect to such Securitization Transaction, or for execution of a certification pursuant to Rule 13a-14(d) or Rule 15d-14(d) under the Exchange Act with respect to such Securitization Transaction; each broker dealer acting as underwriter, placement agent or initial purchaser, each Person who controls any of such parties or the Depositor (within the meaning of Section 15 of the Securities Act and Section 20 of the Exchange Act); and the respective present and former directors, officers, employees, agents and affiliates of each of the foregoing and of the Depositor (each, an “Indemnified Party”), and shall hold each of them harmless from and against any claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses and related costs, judgments, and any other costs, fees and expenses that any of them may sustain arising out of or based upon:
Survival Indemnification All representations, warranties and covenants contained in this Agreement and the indemnification contained herein shall survive (a) the acceptance of this Agreement by the Company, (b) changes in the transactions, documents and instruments described herein which are not material or which are to the benefit of Subscriber, and (c) the death or disability of Subscriber. Subscriber acknowledges the meaning and legal consequences of the representations, warranties and covenants in Article II hereof and that the Company has relied upon such representations, warranties and covenants in determining Subscriber's qualification and suitability to purchase the Securities. Subscriber hereby agrees to indemnify, defend and hold harmless the Company, its officers, directors, employees, agents and controlling persons, from and against any and all losses, claims, damages, liabilities, expenses (including attorneys' fees and disbursements), judgments or amounts paid in settlement of actions arising out of or resulting from the untruth of any representation of Subscriber herein or the breach of any warranty or covenant herein by Subscriber. Notwithstanding the foregoing, however, no representation, warranty, covenant or acknowledgment made herein by Subscriber shall in any manner be deemed to constitute a waiver of any rights granted to it under the Securities Act or state securities laws.
Limitation of Liability and Indemnification State Street shall be held to a standard of reasonable care in carrying out its duties under this Agreement. State Street shall be responsible for the performance of only such duties as are set forth in this Agreement and, except as otherwise provided under Section XVI, shall have no responsibility for the actions or activities of any other party, including other service providers. State Street shall have no liability for any error of judgment or mistake of law or for any loss or damage resulting from the performance or nonperformance of its duties hereunder unless caused by or resulting from the negligence, reckless misconduct, willful malfeasance or lack of good faith of State Street, its officers or employees and, in such event, such liability will be subject to the limitations set forth in Section XIII herein. STATE STREET SHALL NOT BE LIABLE FOR ANY SPECIAL, INDIRECT, INCIDENTAL, OR CONSEQUENTIAL DAMAGES OF ANY KIND WHATSOEVER (INCLUDING, WITHOUT LIMITATION, ATTORNEYS’ FEES) IN ANY WAY DUE TO THE TRUST’S USE OF THE SERVICES DESCRIBED HEREIN OR THE PERFORMANCE OF OR FAILURE TO PERFORM STATE STREET’S OBLIGATIONS UNDER THIS AGREEMENT. This disclaimer applies without limitation to claims regardless of the form of action, whether in contract (including negligence), strict liability, or otherwise and regardless of whether such damages are foreseeable. The Trust, or, if applicable, the relevant Portfolio, will indemnify and hold harmless State Street and its stockholders, directors, officers, employees, agents, and representatives (collectively, the “Trust Indemnified Persons”) for, and will pay to the Trust Indemnified Persons the amount of, any actual and direct damages, whether or not involving a third-party claim (collectively, the “Damages”), arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) pursuant to this Agreement which does not constitute negligence, reckless misconduct, willful malfeasance or lack of good faith in fulfilling the terms and obligations of this Agreement, (ii) any act or omission by the Trust (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement, or (iii) any act or omission by the Trust (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to State Street or any other Trust Indemnified Person. State Street will indemnify and hold harmless the Trust, and its respective shareholders, trustees, directors, officers, agents, and representatives (collectively, the “State Street Indemnified Persons”) for, and will pay to the State Street Indemnified Persons the amount of, any Damages, arising from or in connection with (i) any act or omission by State Street (or any of its affiliates) which constitutes a breach of any representation, warranty, term, or obligation contained in this Agreement or (ii) any act or omission by State Street (or any of its affiliates) which constitutes negligence, reckless misconduct, willful malfeasance, or lack of good faith in fulfilling the terms and obligations of this Agreement; provided, however, that State Street shall not be required to provide indemnification for damages arising from errors caused by inaccurate prices received from independent pricing services and reasonably relied upon by State Street. In the event that State Street is required to provide indemnification under this Section XII, its liability shall be limited as described under Section XIII below. The remedies provided in this paragraph are not exclusive of or limit any other remedies that may be available to the Trust or any other State Street Indemnified Person. The indemnification and limitation of liability contained herein shall survive the termination of this Agreement.
Indemnification by Buyer Subject to the other terms and conditions of this Article VIII, Buyer shall indemnify and defend each of Seller and its Affiliates and their respective Representatives (collectively, the “Seller Indemnitees”) against, and shall hold each of them harmless from and against, and shall pay and reimburse each of them for, any and all Losses incurred or sustained by, or imposed upon, the Seller Indemnitees based upon, arising out of, with respect to or by reason of:
NEGATION OF WARRANTIES AND INDEMNIFICATION 12.01 PHS offers no warranties other than those specified in Article 1.
