Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.
Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Lenders’ notice addresses under Section 13.3.1; or (g) discretion of any Lender mean the sole and absolute discretion of such Person. All calculations of fundings of the Loans, and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision.
Litigation and Environmental Matters (a) There are no actions, suits or proceedings by or before any arbitrator or Governmental Authority pending against or, to the knowledge of the Borrower, threatened against or affecting the Borrower or any of its Subsidiaries (i) as to which there is a reasonable possibility of an adverse determination and that, if adversely determined, could reasonably be expected, individually or in the aggregate, to result in a Material Adverse Effect (other than the Disclosed Matters) or (ii) that involve this Agreement or the Transactions.
(b) Except for the Disclosed Matters and except with respect to any other matters that, individually or in the aggregate, could not reasonably be expected to result in a Material Adverse Effect, neither the Borrower nor any of its Subsidiaries (i) has failed to comply with any Environmental Law or to obtain, maintain or comply with any permit, license or other approval required under any Environmental Law, (ii) has become subject to any Environmental Liability, (iii) has received notice of any claim with respect to any Environmental Liability or (iv) knows of any basis for any Environmental Liability.
(c) Since the date of this Agreement, there has been no change in the status of the Disclosed Matters that, individually or in the aggregate, has resulted in, or materially increased the likelihood of, a Material Adverse Effect.
Preparation of Environmental Reports At the request of the Administrative Agent from time to time if the Administrative Agent reasonably suspects the presence of any Hazardous Materials on any property of the Borrower or its Subsidiaries, provide to the Administrative Agent within sixty (60) days after such request, at the expense of the Borrower, an environmental site assessment report for any Specified Real Estate described in such request, prepared by a nationally recognized environmental consulting firm (or other environmental consulting firm reasonably acceptable to the Administrative Agent), indicating the presence or absence of Hazardous Materials and the estimated cost of any compliance, removal or remedial action in connection with any Hazardous Materials on such properties; without limiting the generality of the foregoing, if the Administrative Agent determines at any time that a material risk exists that any such report will not be provided within the time referred to above, the Administrative Agent may retain an environmental consulting firm to prepare such report at the expense of the Borrower, and such Loan Party hereby grants and agrees to cause any Subsidiary that owns any property described in such request to grant at the time of such request to the Administrative Agent, such firm and any agents or representatives thereof an irrevocable non-exclusive license, subject to the rights of tenants, to enter onto their respective properties to undertake such an assessment.
Reports of Foreclosures and Abandonments of Mortgaged Property Following the foreclosure sale or abandonment of any Mortgaged Property, the Servicer shall report such foreclosure or abandonment as required pursuant to Section 6050J of the Code.
Certain Environmental Matters (i) The Company and its subsidiaries (x) are in compliance with all, and have not violated any, applicable federal, state, local and foreign laws (including common law), rules, regulations, requirements, decisions, judgments, decrees, orders and other legally enforceable requirements relating to pollution or the protection of human health or safety, the environment, natural resources, hazardous or toxic substances or wastes, pollutants or contaminants (collectively, “Environmental Laws”); (y) have received and are in compliance with all, and have not violated any, permits, licenses, certificates or other authorizations or approvals required of them under any Environmental Laws to conduct their respective businesses; and (z) have not received notice of any actual or potential liability or obligation under or relating to, or any actual or potential violation of, any Environmental Laws, including for the investigation or remediation of any disposal or release of hazardous or toxic substances or wastes, pollutants or contaminants, and have no knowledge of any event or condition that would reasonably be expected to result in any such notice, and (ii) there are no costs or liabilities associated with Environmental Laws of or relating to the Company or its subsidiaries, except in the case of each of (i) and (ii) above, for any such matter as would not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect; and (iii) except as described in each of the Pricing Disclosure Package and the Prospectus, (x) there is no proceeding that is pending, or that is known to be contemplated, against the Company or any of its subsidiaries under any Environmental Laws in which a governmental entity is also a party, other than such proceeding regarding which it is reasonably believed no monetary sanctions of $100,000 or more will be imposed, (y) the Company and its subsidiaries are not aware of any facts or issues regarding compliance with Environmental Laws, or liabilities or other obligations under Environmental Laws or concerning hazardous or toxic substances or wastes, pollutants or contaminants, that could reasonably be expected to have a material effect on the capital expenditures, earnings or competitive position of the Company and its subsidiaries, and (z) none of the Company or its subsidiaries anticipates material capital expenditures relating to any Environmental Laws.
Award of Construction Contract and Other Future Contracts 6.2.1 A-E is hereby informed that provisions of the Public Contract Code, the Political Reform Act of 1974, other statutes, regulations, and COUNTY policy prohibit, as an impermissible conflict of interest, the award of a contract for the construction of the project(s) on which A-E performed architectural-engineering services under this A-E CONTRACT. A-E is hereby informed that these statutes and regulations could also prohibit the award to A-E of design or other contracts on future phases related to tasks performed by A-E under this CONTRACT. This prohibition applies also to a subcontractor of or parent company of the firm that performed architectural-engineering tasks under this CONTRACT.
Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.
