Initial Insurance Representations to BNPPLC and Other Interested Parties Sample Clauses

Initial Insurance Representations to BNPPLC and Other Interested Parties. NAI represents, acknowledges and agrees that: 1. Any Construction Period Policies not previously obtained will be obtained by NAI (or by the primary Contractor engaged by NAI to perform the Work), and the initial premiums for all Construction Period Policies will be paid, before NAI requests Construction Advances that cause the Lease Balance to exceed $2,000,000; and notwithstanding anything to the contrary in the Construction Agreement, BNPPLC may refuse to fund any Construction Advances that would cause the Lease Balance to exceed $2,000,000 prior to such time as BNPPLC is satisfied that NAI has obtained and paid the premiums for the Construction Period Policies. Moreover, in the case of the Builder’s Risk Policy, the premium must be paid or prepaid for the entire period through the projected Completion Date before the Lease Balance exceeds $2,000,000. 2. The coverages provided by the Construction Period Policies will not be terminated or modified to reduce, limit or qualify coverages in any material respect without BNPPLC’s prior written consent in each case by reason of any act or omission on the part of NAI or anyone acting for or authorized to act for NAI (including any Contractor engaged by NAI to obtain the Construction Period Policies for NAI). Without limiting the foregoing, NAI will not do or authorize any act or omission that could cause the coverage provided with respect to any Improvements by the Builder’s Risk Policy to expire or lapse before the Completion Date. 3. NAI must notify BNPPLC with reasonable promptness of any possible damage claims known to NAI that NAI believes are, individually or taken together, reasonably likely to a exceed seventy-five percent (75%) of any aggregate limit of the Builder’s Risk Policy required herein. 4. NAI will endeavor in good faith to cause each certificate of insurance which is provided to BNPPLC by an insurer, or its authorized representative, at the request of NAI in regard to any Construction Period Policies to include the following express provision: This is to certify that the policies of insurance described herein have been issued to the Insured for whom this certificate is executed and are in force at this time. In the event of cancellation or non-renewal of coverage affecting the certificate holder, other than by reason of nonpayment of premium, thirty (30) days prior written notice will be given to the certificate holder by certified mail or registered mail, return receipt requested. In the eve...
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs

Related to Initial Insurance Representations to BNPPLC and Other Interested Parties

  • Limitation on Liability of the Company, the Master Servicer and Others Neither the Company, the Master Servicer nor any of the directors, officers, employees or agents of the Company or the Master Servicer shall be under any liability to the Trust Fund or the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Company, the Master Servicer or any such Person against any breach of warranties or representations made herein or any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder. The Company, the Master Servicer and any director, officer, employee or agent of the Company or the Master Servicer may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Company, the Master Servicer and any director, officer, employee or agent of the Company or the Master Servicer shall be indemnified by the Trust Fund and held harmless against any loss, liability or expense incurred in connection with any legal action relating to this Agreement or the Certificates, other than any loss, liability or expense related to any specific Mortgage Loan or Mortgage Loans (except as any such loss, liability or expense shall be otherwise reimbursable pursuant to this Agreement) and any loss, liability or expense incurred by reason of willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties hereunder. Neither the Company nor the Master Servicer shall be under any obligation to appear in, prosecute or defend any legal or administrative action, proceeding, hearing or examination that is not incidental to its respective duties under this Agreement and which in its opinion may involve it in any expense or liability; provided, however, that the Company or the Master Servicer may in its discretion undertake any such action, proceeding, hearing or examination that it may deem necessary or desirable in respect to this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action, proceeding, hearing or examination and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund, and the Company and the Master Servicer shall be entitled to be reimbursed therefor out of amounts attributable to the Mortgage Loans on deposit in the Custodial Account as provided by Section 3.10 and, on the Distribution Date(s) following such reimbursement, the aggregate of such expenses and costs shall be allocated in reduction of the Accrued Certificate Interest on each Class entitled thereto in the same manner as if such expenses and costs constituted a Prepayment Interest Shortfall.

  • GOVERNING LAW AND OTHER REPRESENTATIONS: DIR Customer [ ] Unit of Texas Local Government hereby certifying that is has statutory authority to perform its duties hereunder pursuant to Chapter , Texas Code. [ X ] Non-Texas State agency or unit of local government of another state hereby certifying that it has statutory authority to enter in to this Interlocal Agreement and perform its duties hereunder pursuant to Idaho Code § 67-2807

  • Limitation on Liability of the Master Servicer and Others (a) The Master Servicer undertakes to perform such duties and only such duties as are specifically set forth in this Agreement. (b) No provision of this Agreement shall be construed to relieve the Master Servicer from liability for its own negligent action, its own negligent failure to act or its own willful misconduct; provided, however, that the duties and obligations of the Master Servicer shall be determined solely by the express provisions of this Agreement, the Master Servicer shall not be liable except for the performance of such duties and obligations as are specifically set forth in this Agreement; no implied covenants or obligations shall be read into this Agreement against the Master Servicer and, in absence of bad faith on the part of the Master Servicer, the Master Servicer may conclusively rely, as to the truth of the statements and the correctness of the opinions expressed therein, upon any certificates or opinions furnished to the Master Servicer and conforming to the requirements of this Agreement. (c) None of the Master Servicer, the Seller or the Depositor or any of the directors, officers, employees or agents of any of them shall be under any liability to the Trustee or the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Master Servicer, the Seller or the Depositor or any such person against any liability that would otherwise be imposed by reason of willful misfeasance, bad faith or negligence in its performance of its duties or by reason of reckless disregard for its obligations and duties under this Agreement. The Master Servicer, the Seller and the Depositor and any director, officer, employee or agent of any of them shall be entitled to indemnification by the Trust Fund and will be held harmless against any loss, liability or expense incurred in connection with any legal action relating to this Agreement or the Certificates other than any loss, liability or expense incurred by reason of willful misfeasance, bad faith or negligence in the performance of his or its duties hereunder or by reason of reckless disregard of his or its obligations and duties hereunder. The Master Servicer, the Seller and the Depositor and any director, officer, employee or agent of any of them may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Master Servicer shall be under no obligation to appear in, prosecute or defend any legal action that is not incidental to its duties to master service the Mortgage Loans in accordance with this Agreement and that in its opinion may involve it in any expenses or liability; provided, however, that the Master Servicer may in its sole discretion undertake any such action that it may deem necessary or desirable in respect to this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund and the Master Servicer shall be entitled to be reimbursed therefor out of the Collection Account it maintains as provided by Section 4.02.

  • Limitations on Liability of the Master Servicer and Others Subject to the obligation of the Master Servicer to indemnify the Indemnified Persons pursuant to Section 7.03: (a) Neither the Master Servicer nor any of the directors, officers, employees or agents of the Master Servicer shall be under any liability to the Indemnified Persons, the Seller, the Trust Fund or the Certificateholders for taking any action or for refraining from taking any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Master Servicer or any such Person against any breach of warranties or representations made herein or any liability which would otherwise be imposed by reason of such Person's willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder. (b) The Master Servicer and any director, officer, employee or agent of the Master Servicer may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. (c) The Master Servicer, the Custodian and any director, officer, employee or agent of the Master Servicer or the Custodian shall be indemnified by the Trust and held harmless thereby against any loss, liability or expense (including reasonable legal fees and disbursements of counsel) incurred on their part that may be sustained in connection with, arising out of, or related to, any claim or legal action (including any pending or threatened claim or legal action) relating to this Agreement, the Certificates or any Servicing Agreement (except to the extent that the Master Servicer is indemnified by the Servicer thereunder), other than (i) any such loss, liability or expense related to the Master Servicer's failure to perform its duties in compliance with this Agreement (except as any such loss, liability or expense shall be otherwise reimbursable pursuant to this Agreement), or to the Custodian's failure to perform its duties under the Custodial Agreement, respectively, or (ii) any such loss, liability or expense incurred by reason of the Master Servicer's or the Custodian's willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or under the Custodial Agreement, as applicable, or by reason of reckless disregard of obligations and duties hereunder or under the Custodial Agreement, as applicable. (d) The Master Servicer shall not be under any obligation to appear in, prosecute or defend any legal action that is not incidental to its duties under this Agreement and that in its opinion may involve it in any expense or liability; provided, however, the Master Servicer may in its discretion, with the consent of the Trustee (which consent shall not be unreasonably withheld), undertake any such action which it may deem necessary or desirable with respect to this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund, and the Master Servicer shall be entitled to be reimbursed therefor out of the Master Servicer Collection Account as provided by Section 4.03. Nothing in this Subsection 7.04(d) shall affect the Master Servicer's obligation to supervise, or to take such actions as are necessary to ensure, the servicing and administration of the Mortgage Loans pursuant to Subsection 3.01(a). (e) In taking or recommending any course of action pursuant to this Agreement, unless specifically required to do so pursuant to this Agreement, the Master Servicer shall not be required to investigate or make recommendations concerning potential liabilities which the Trust might incur as a result of such course of action by reason of the condition of the Mortgaged Properties but shall give notice to the Trustee if it has notice of such potential liabilities. (f) The Master Servicer shall not be liable for any acts or omissions of any Servicer, except as otherwise expressly provided herein.

  • Limitation on Liability of the Depositor, the Master Servicer and Others Neither the Depositor, the Master Servicer nor any of the directors, officers, employees or agents of the Depositor or the Master Servicer shall be under any liability to the Trust Fund or the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Depositor, the Master Servicer or any such Person against any breach of warranties or representations made herein or any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder. The Depositor, the Master Servicer and any director, officer, employee or agent of the Depositor or the Master Servicer may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Depositor, the Master Servicer and any director, officer, employee or agent of the Depositor or the Master Servicer shall be indemnified by the Trust Fund and held harmless against any loss, liability or expense incurred in connection with any legal action relating to this Agreement or the Certificates, other than any loss, liability or expense related to any specific Mortgage Loan or Mortgage Loans (except as any such loss, liability or expense shall be otherwise reimbursable pursuant to this Agreement) and any loss, liability or expense incurred by reason of willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties hereunder. Neither the Depositor nor the Master Servicer shall be under any obligation to appear in, prosecute or defend any legal or administrative action, proceeding, hearing or examination that is not incidental to its respective duties under this Agreement and which in its opinion may involve it in any expense or liability; provided, however, that the Depositor or the Master Servicer may in its discretion undertake any such action, proceeding, hearing or examination that it may deem necessary or desirable in respect to this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action, proceeding, hearing or examination and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund, and the Depositor and the Master Servicer shall be entitled to be reimbursed therefor out of amounts attributable to the Mortgage Loans on deposit in the Custodial Account as provided by Section 3.10 and, on the Distribution Date(s) following such reimbursement, the aggregate of such expenses and costs shall be allocated in reduction of the Accrued Certificate Interest on each Class entitled thereto in the same manner as if such expenses and costs constituted a Prepayment Interest Shortfall.

  • Limitation on Liability of the Depositor and Others Neither the Depositor nor any of its directors, officers, employees or agents shall be under any liability to the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Depositor or any such Person against any breach of representations or warranties made by it herein or protect the Depositor or any such Person from any liability which would otherwise be imposed by reasons of willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder. The Depositor and any director, officer, employee or agent of the Depositor may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Depositor and any director, officer, employee or agent of the Depositor shall be indemnified by the Trust Fund and held harmless against any loss, liability or expense incurred in connection with any audit, controversy or judicial proceeding relating to a governmental taxing authority or any legal action relating to this Agreement or the Certificates, other than any loss, liability or expense incurred by reason of willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties hereunder. The Depositor shall not be under any obligation to appear in, prosecute or defend any legal action that is not incidental to its respective duties hereunder and which in its opinion may involve it in any expense or liability; provided, however, that the Depositor may in its discretion undertake any such action (or direct the Trustee to undertake such actions for the benefit of the Certificateholders) that it may deem necessary or desirable in respect of this Agreement and the rights and duties of the parties hereto and interests of the Trustee and the Certificateholders hereunder. In such event, the legal expenses and costs of such action and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund, the Depositor shall be entitled to be reimbursed therefor out of the Distribution Account.

  • Limitation on Liability of the Seller and Others The duties and obligations of the Seller in its capacity as the interim servicer of the Mortgage Loans shall be determined solely by the express provisions of this Agreement, the Seller as interim servicer shall not be liable except for the performance of such duties and obligations as are specifically set forth in this Agreement and no implied covenants or obligations shall be read into this Agreement against the Seller as interim servicer. Neither the Seller nor any of the directors, officers, employees or agents of the Seller shall be under any liability to the Purchaser for any action taken or for refraining from the taking of any action in accordance with Customary Servicing Procedures and otherwise in good faith pursuant to this Agreement or for errors in judgment; provided, however, that this provision shall not protect the Seller as interim servicer against any liability resulting from any breach of any representation or warranty made herein, or from any liability specifically imposed on the Seller as interim servicer herein; and, provided further, that this provision shall not protect the Seller as interim servicer against any liability that would otherwise be imposed by reason of the willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of the obligations or duties hereunder. The Seller and any director, officer, employee or agent of the Seller may rely on any document of any kind which it in good faith reasonably believes to be genuine and to have been adopted or signed by the proper authorities respecting any matters arising hereunder. Subject to the terms of Subsection 12.01, the Seller shall have no obligation to appear with respect to, prosecute or defend any legal action which is not incidental to the Seller’s duty to service the Mortgage Loans in accordance with this Agreement.

  • Concerning the Warrant Agent and Other Matters 8.1. Any instructions given to the Warrant Agent orally, as permitted by any provision of this Warrant Agreement, shall be confirmed in writing by the Company as soon as practicable. The Warrant Agent shall not be liable or responsible and shall be fully authorized and protected for acting, or failing to act, in accordance with any oral instructions which do not conform with the written confirmation received in accordance with this Section 8.1. (a) Whether or not any Warrants are exercised, for the Warrant Agent’s services as agent for the Company hereunder, the Company shall pay to the Warrant Agent such fees as may be separately agreed between the Company and Warrant Agent and the Warrant Agent’s out of pocket expenses in connection with this Warrant Agreement, including, without limitation, the fees and expenses of the Warrant Agent’s counsel. While the Warrant Agent endeavors to maintain out-of-pocket charges (both internal and external) at competitive rates, these charges may not reflect actual out-of-pocket costs, and may include handling charges to cover internal processing and use of the Warrant Agent’s billing systems. (b) All amounts owed by the Company to the Warrant Agent under this Warrant Agreement are due within 30 days of the invoice date. Delinquent payments are subject to a late payment charge of one and one-half percent (1.5%) per month commencing 45 days from the invoice date. The Company agrees to reimburse the Warrant Agent for any attorney’s fees and any other costs associated with collecting delinquent payments. (c) No provision of this Warrant Agreement shall require Warrant Agent to expend or risk its own funds or otherwise incur any financial liability in the performance of any of its duties under this Warrant Agreement or in the exercise of its rights.

  • Limitation on Liability of the Servicer and Others Neither the Servicer nor any of the directors, officers, employees or agents of the Servicer shall be under any liability to the Trust Fund or the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect any director, officer, employee or agent of the Servicer against any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder, nor shall this provision protect the Servicer against any liability that would otherwise be imposed by reason of negligence in the performance of duties hereunder. The Servicer and any director, officer, employee or agent of the Servicer may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Servicer and any director, officer, employee or agent of the Servicer shall be indemnified by the Trust Fund and held harmless against any loss, liability or expense incurred in connection with any legal action relating to this Agreement or the Certificates, other than any loss, liability or expense, in the case of the Servicer and any director, officer, employee or agent of the Servicer, incurred by reason of willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties hereunder or, in the case of the Servicer, as Servicer, incurred by reason of negligence in the performance of any duties hereunder. The Servicer shall not be under any obligation to appear in, prosecute or defend any legal action which is not incidental to its duties to service the Loans in accordance with this Agreement and which in its opinion may involve it in any expense or liability; provided, however, that the Servicer may in its discretion undertake any such action which it may deem necessary or desirable in respect of this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Fund, and the Servicer shall be entitled to be reimbursed therefor out of the Custodial Account for P&I as provided by Section 3.3.

  • Limitation on Liability of the Depositor, the Servicer and Others None of the Depositor, the Servicer or any of the directors, officers, employees or agents of the Depositor or of the Servicer shall be under any liability to the Trust Estate or the Certificateholders for any action taken or for refraining from the taking of any action in good faith pursuant to this Agreement, or for errors in judgment; provided, however, that this provision shall not protect the Depositor, the Servicer or any such Person against any breach of warranties or representations made herein or any liability which would otherwise be imposed by reason of willful misfeasance, bad faith or gross negligence in the performance of duties or by reason of reckless disregard of obligations and duties hereunder. The Depositor, the Servicer and any director, officer, employee or agent of the Depositor or the Servicer may rely in good faith on any document of any kind prima facie properly executed and submitted by any Person respecting any matters arising hereunder. The Depositor, the Servicer and any director, officer, employee or agent of the Depositor or the Servicer shall be indemnified by the Trust Estate and held harmless against any loss, liability or expense incurred in connection with any legal action relating to this Agreement or the Certificates, other than any loss, liability or expense related to any specific Mortgage Loan or Mortgage Loans (except as any such loss, liability or expense shall be otherwise reimbursable pursuant to this Agreement) and any loss, liability or expense incurred by reason of willful misfeasance, bad faith or gross negligence in the performance of duties hereunder or by reason of reckless disregard of obligations and duties hereunder. Neither of the Depositor nor the Servicer shall be under any obligation to appear in, prosecute or defend any legal action which is not incidental to its respective duties under this Agreement and which in its opinion may involve it in any expense or liability; provided, however, that the Depositor or the Servicer may in its discretion undertake any such action which it may deem necessary or desirable in respect to this Agreement and the rights and duties of the parties hereto and the interests of the Certificateholders hereunder. In such event, the legal expenses and costs of such action and any liability resulting therefrom shall be expenses, costs and liabilities of the Trust Estate, and the Depositor and the Servicer shall be entitled to be reimbursed therefor out of amounts attributable to the Mortgage Loans on deposit in the Servicer Custodial Account as provided by Section 3.11.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!