Initiation of Projects; and Performance and Delays Sample Clauses

Initiation of Projects; and Performance and Delays. The Steering Committee shall determine which Projects to submit to DELTAGEN to initiate work on such Projects under the Development Program. Each Party shall use reasonable commercial efforts to fulfill their obligations with respect to each Project as set forth herein (including the Work Plan), and to perform its other obligations under this Agreement; provided that, with respect to DELTAGEN's activities under the Development Program, HYSEQ acknowledges and agrees that the performance of such activities may involve a number of technologically complex steps and that any time periods for performance, whether set out in the Work Plan or elsewhere in this Agreement, may be subject to change due to potential technological difficulties encountered, and any such delays or technical issues shall not be considered a breach by DELTAGEN under this Agreement. If a Project is delayed because either Party determines that there are any technical issues with respect to a Project of a material nature, it shall notify the Steering Committee in writing describing the delayed task and the reasons for such delay. After receiving such notice, if necessary, the Steering Committee shall meet to review the reason for such delays and any technical issues raised by the notifying Party, to consider how best to proceed and whether to modify the Work Plan (including to adjust any timelines contained therein), if and to the extent necessary. If requested by the Steering Committee, the Parties shall provide information to the Steering Committee to assist it in its review of the Project. The Steering Committee may vote at any time to discontinue or suspend a Project if the Steering Committee determines that it is commercially reasonable or necessary to do so. DELTAGEN may determine, in its reasonable business judgment, to [***]; provided, however, that DELTAGEN shall notify HYSEQ in writing within three (3) business days of such determination and shall [***]. Upon such decision by the Steering Committee or DELTAGEN, as applicable, to [***], the applicable Project Gene shall immediately become a Rejected Project Gene.
AutoNDA by SimpleDocs
Initiation of Projects; and Performance and Delays. The Steering Committee shall determine which Projects to submit to DELTAGEN to initiate work on such Projects under the * Confidential portions of this document have been redacted and have been filed separately with the Commission.

Related to Initiation of Projects; and Performance and Delays

  • Continuity of Service and Performance Unless otherwise agreed in writing, the Parties shall continue to provide service and honor all other commitments under this Agreement during the course of a Dispute with respect to all matters not subject to such Dispute.

  • Payment and Performance of Obligations Pay and perform all material Obligations under this Agreement and the other Loan Documents, and pay or perform (a) all taxes, assessments and other governmental charges that may be levied or assessed upon it or any of its property, and (b) all other indebtedness, obligations and liabilities in accordance with customary trade practices; except to the extent that IPT or the Borrower is contesting any item described in clauses (a) or (b) of this Section 7.5 in good faith and is maintaining adequate reserves with respect thereto in accordance with GAAP.

  • Guaranty of Payment and Performance Guarantor’s obligations under this Guaranty constitute an unconditional guaranty of payment and performance and not merely a guaranty of collection.

  • Portfolio Expense and Performance Data The Trust shall provide such data regarding each Portfolio’s expense ratios and investment performance as the Company shall reasonably request, to facilitate the registration and sale of the Variable Contracts. Without limiting the generality of the forgoing, the Trust shall provide the following Portfolio expense and performance data on a timely basis to facilitate the Company’s preparation of its annually updated registration statement for the Variable Contracts (and as otherwise reasonably requested by the Company), but in no event later than 10 calendar days after the close of each Portfolio’s fiscal year: (a) The gross “Annual Portfolio Company Expenses” for each Portfolio calculated in accordance with Item 3 of Form N-1A, before any expense reimbursements or fee waiver arrangements (and in accordance with (i) Instruction 16 to Item 4 of Form N-4, and (ii) Instruction 4(a) to Item 4 of Form N-6); (b) The net “Annual Portfolio Company Expenses” (aka “Total Annual Fund Operating Expenses”) for each Portfolio calculated in accordance with Item 3 of Form N-1A, that include any expense reimbursements or fee waiver arrangements (and in accordance with (i) Instruction 17 to Item 4 of Form N-4, (ii) Instruction 4 to Item 17 of Form N-4, (iii) Instruction 4(b) to Item 4 of Form N-6, and (iv) Instruction 4 to Item 18 of Form N-6), and the period for which the expense reimbursements or fee waiver arrangement is expected to continue and whether it can be terminated by the Portfolio (or Fund); and (c) The “Average Annual Total Returns” for each Portfolio (before taxes) as calculated pursuant to Item 4(b)(2)(iii) of Form N-1A (for the 1, 5, and 10 year periods, and in accordance with (i) Instruction 7 to Item 17 of Form N-4, and (ii) Instruction 7 to Item 18 of Form N-6).

  • Monitoring of Contract Performance The Contractor shall comply with the monitoring arrangements set out in the Monitoring Requirements Schedule including, but not limited to, providing such data and information as the Contractor may be required to produce under the Contract.

  • Accuracy of Representations and Performance of Covenants The representations and warranties made by the Company in this Agreement were true when made and shall be true as of the Closing Date (except for changes therein permitted by this Agreement) with the same force and effect as if such representations and warranties were made at and as of the Closing Date. Additionally, the Company shall have performed and complied with all covenants and conditions required by this Agreement to be performed or complied with by the Company.

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

  • Execution, Delivery and Performance The execution, delivery and performance of this Agreement and the documents or instruments required under this Agreement will not violate any provision of any existing law or regulation binding on the Manager, or any order, judgment, award or decree of any court, arbitrator or governmental authority binding on the Manager, or the governing instruments of, or any securities issued by, the Manager or of any mortgage, indenture, lease, contract or other agreement, instrument or undertaking to which the Manager is a party or by which the Manager or any of its assets may be bound, the violation of which would have a material adverse effect on the business operations, assets or financial condition of the Manager and its subsidiaries, taken as a whole, and will not result in, or require, the creation or imposition of any lien on any of its property, assets or revenues pursuant to the provisions of any such mortgage indenture, lease, contract or other agreement, instrument or undertaking.

  • Payment and Performance Bonds A payment bond and performance is required for a public works contract involving expenditure in excess of twenty-five thousand dollars ($25,000) and no work can be commenced prior to both bonds being approved the County. The Contractor shall furnish, at time of signing the Contract, one surety bond which shall protect the laborers and material men and shall be for $60,000, in accordance with Section 9554 of the Civil Code, and one surety bond in the amount of $60,000, guaranteeing the faithful performance of the Contract. If at any time the value of the total task orders is expected to exceed $60,000, the Contractor shall furnish, in a manner acceptable to the County, evidence that the Contractor is bonded to the expected total value of outstanding task orders for both the faithful performance and laborers and material men bonds. Contractor shall not be entitled to, nor shall County authorize, task orders when the total outstanding value of the task orders under this contract exceeds the bond values for which the County is an obligee. Said bonds to be approved by the office of the County Counsel and the County Executive Office of Orange County. Such bonds shall be the forms provided in these specifications and issued and executed by an admitted surety insurer (authorized to transact surety insurance in California). (e.g., if the bonds are issued through a surplus line broker, both the surplus line broker and the insurer with whom he is doing business for purposes of this project must be licensed in California to issue such bonds.) The faithful performance bond shall be issued by a Surety company with a minimum insurance rating of A- (Secure Best’s Rating) and VIII (Financial Size Category) as determined by the most current edition of the Best’s Key Rating Guide/Property-Casualty/United States or xxxxxx.xxx. The Surety Company must also be authorized to write in California by the Department of the Treasury, and must be listed on the most current edition of the Department of Treasury’s Listing of Approved Securities. If any surety upon any bond furnished in connection with this Contract becomes unacceptable to the County, or if any such surety fails to furnish reports as to his financial condition from time to time as requested by OC Public Works, the Contractor shall promptly furnish such additional security as may be required by OC Public Works or the Board of Supervisors from time to time to protect the interests of the County and of persons supplying labor or materials in the prosecution of the Work contemplated by this Contract. If the County increases the total Contract amount the Contractor is to provide a new bond for the new total Contract amount or a bond for the difference.

  • Payment and Performance Borrower will pay all amounts due under the Loan Documents in accordance with the terms thereof and will observe, perform and comply with every covenant, term and condition expressed or implied in the Loan Documents. Borrower will cause each other Restricted Person to observe, perform and comply with every such term, covenant and condition.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!