Use of Explosives When the use of explosives is necessary for the prosecution of the work, the Contractor shall exercise the utmost care not to endanger life or property, including new work. The Contractor shall be responsible for all damage resulting from the use of explosives. All explosives shall be stored in a secure manner in compliance with all laws and ordinances, and all such storage places shall be clearly marked. Where no local laws or ordinances apply, storage shall be provided satisfactory to the Engineer and, in general, not closer than 1,000 feet (300 m) from the work or from any building, road, or other place of human occupancy. The Contractor shall notify each property Owner and public utility company having structures or facilities in proximity to the site of the work of his/her intention to use explosives. Such notice shall be given sufficiently in advance to enable them to take such steps as they may deem necessary to protect their property from injury. The use of electrical blasting caps shall not be permitted on or within 1,000 feet (300 m) of the airport property.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
CLOSURE TO PREVENT DAMAGE In accordance with Contract Clause G-220 STATE SUSPENDS OPERATION, the Contract Administrator will suspend road work or hauling right-of-way timber, forest products, or rock under the following conditions: Wheel track rutting exceeds 6 inches on roads. Surface or base stability problems persist. Weather is such that satisfactory results cannot be obtained in an area of operations. When, in the opinion of the Contract Administrator excessive road damage or rutting may occur. Operations must stop unless authority to continue working or hauling is granted in writing by the Contract Administrator. In the event that surface or base stability problems persist, Purchaser shall cease operations, or perform corrective maintenance or repairs, subject to specifications within this road plan. Before and during any suspension, Purchaser shall protect the work from damage or deterioration.
Offtake constraints due to Backdown The Solar Power Developer and Buying Entity shall follow the forecasting and scheduling process as per the regulations in this regard by the Appropriate Commission. The Government of India, as per Clause 5.2(u) of the Indian Electricity Grid Code (IEGC), encourages a status of “must-run” to solar power projects. Accordingly, no solar power plant, duly commissioned, should be directed to back down by a Discom/ Load Dispatch Centre (LDC). In the eventuality of backdown, including backdown on account of non-dispatch of power due to non-compliance with “Order No. 23/22/2019- R&R dated 28.06.2019 of Ministry of Power regarding Opening and maintaining of adequate Letter of Credit (LC) as Payment Security Mechanism under Power Purchase Agreements by Distribution Licensees” and any clarifications or amendment thereto, except for the cases where the Backdown is on account of events like consideration of grid security or safety of any equipment or personnel or other such conditions, subject to the submission of documentary evidences from the competent authority, the SPD shall be eligible for a minimum generation compensation, from Buying Entity, restricted to the following and there shall be no other claim, directly or indirectly against SECI: Duration of Backdown Provision for Generation Compensation Hours of Backdown during a monthly billing cycle. Generation Compensation = 100% of [(Average Generation per hour during the month) X (number of backdown hours during the month)] X PPA tariff Where, Average Generation per hour during the month (kWh) = Total generation in the month (kWh) ÷ Total hours of generation in the month
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.
POSSESSION OF GAS AN INDEMNIFICATION 1. As between the parties hereto, Seller shall be deemed to be in control and possession of the gas deliverable hereunder until it shall have been delivered to Buyer at the Point of Delivery after which Buyer shall be deemed to be in control and possession thereof.
Excuse from Performance The Parties shall be excused from performing their respective obligations hereunder if they are prevented from so performing by reason of floods, earthquakes, other acts of nature, war, civil insurrection, riots, acts of any government (including judicial action), and other similar catastrophic events which are beyond the control of and not the fault of the Party claiming excuse from performance hereunder. Labor unrest, including but not limited to strike, work stoppage or slowdown, sick-out, picketing, or other concerted job action conducted by Contractor's employees or directed at Contractor is not an excuse from performance and Contractor shall be obligated to continue to provide service notwithstanding the occurrence of any or all of such events. The Party claiming excuse from performance shall, within two (2) Business Days after such Party has notice of such cause, give the other Party notice of the facts constituting such cause and asserting its claim to excuse under this Section. If either Party validly exercises its rights under this Section, the Parties hereby waive any claim against each other for any damages sustained thereby. The partial or complete interruption or discontinuance of Contractor's services caused by one or more of the events described in this Section shall not constitute a default by Contractor under this Agreement. Notwithstanding the foregoing, however, if Contractor is excused from performing its obligations hereunder for any of the causes listed in this Section for a period of thirty (30) calendar days or more, the SCWMA shall nevertheless have the right, in its sole discretion, to terminate this Agreement by giving ten (10) calendar days notice to Contractor unless Contractor has demonstrated, by the thirtieth (30th) calendar day, to the satisfaction of the SCWMA that the Contractor will resume services no later than the sixtieth (60th) day following the date service was interrupted or discontinued by Contractor.
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
