Seller Warranties 20.1 The Seller warrants that at the Date of this Contract:
(a) the Seller will be able to complete at Completion;
(b) the Seller has no knowledge of any unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment, order or writ affecting the Land; and
(d) the Seller is not aware of any material change in the matters disclosed in the Housing Development Requirements.
20.2 The Seller warrants that on Completion:
(a) the Seller will have the capacity to complete;
(b) there will be no unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment order or writ affecting the Land; and
(d) the Seller is not aware of any encroachments by or upon the Land except as disclosed. This warranty does not extend to the location of any dividing fence.
20.3 The Seller gives no warranties as to the present state of repair of any of the Improvements or condition of the Land, except as required by law.
Contractor Warranties 7.12.1 If and to the extent Developer obtains general or limited warranties from any Contractor in favor of Developer with respect to design, materials, workmanship, equipment, tools, supplies, software or services, Developer also shall cause such warranty to be expressly extended to TxDOT and any third parties for whom Work is being performed or equipment, tools, supplies or software is being supplied by such Contractor; provided that the foregoing requirement shall not apply to standard, pre-specified manufacturer warranties of mass- marketed materials, products (including software products), equipment or supplies where the warranty cannot be extended to TxDOT using commercially reasonable efforts. TxDOT agrees to forebear from exercising remedies under any such warranty so long as Developer or a Lender is diligently pursuing remedies thereunder. To the extent that any Contractor warranty would be voided by reason of Developer's negligence in incorporating material or equipment into the Work, Developer shall be responsible for correcting such defect.
7.12.2 Contractor warranties (if any) are in addition to all rights and remedies available under the CDA Documents or applicable Law or in equity, and shall not limit Developer’s liability or responsibility imposed by the CDA Documents or applicable Law or in equity with respect to the Work, including liability for design Defects, latent construction Defects, strict liability, breach, negligence, willful misconduct or fraud.
Purchaser Warranties 8.1. The Purchaser warrants to the Seller as at the Execution Date, and, save as expressly provided otherwise, as at the Completion Date in terms of the warranties set out in Schedule 4 (“Purchaser Warranties”).
8.2. The Purchaser acknowledges that the Seller has entered into this Agreement in reliance on, amongst others things, the Purchaser Warranties.
8.3. If after the Execution Date (i) it is brought to the knowledge of the Purchaser that any of the Purchaser Warranties were untrue, inaccurate or misleading in any material respect as of the Execution Date, or (ii) any event occurs or any matter arises which to the knowledge of the Purchaser results or could reasonably be expected to result in any of the Purchaser Warranties being untrue, inaccurate or misleading in any material respect at Completion had the Purchaser Warranties been repeated as at the Completion Date, the Purchaser shall notify the Seller in writing as soon as reasonably practicable and in any event prior to the Completion Date. Any such notifications shall be disregarded with respect to determining whether the condition set forth in Clause 3.1(iii) has been satisfied and for the purposes of Clause 10.
Buyer Warranties 38.1 The Buyer represents and warrants that:
(a) it has full power and capacity to enter into this Contract;
(b) it has the financial capacity to perform its obligations;
(c) it does not require the consent of any third party to this Contract or to perform its obligations;
(d) they are aware of the rights given to purchasers by sections 217-219 (inclusive)of the Act ;
(e) that any alteration, variation or matter referred to in clause 13 of this Contract will not materially prejudice their position and the Buyer agrees to be bound by any such matters or alterations;
(f) it has not relied on or been induced to enter into this Contract by any representation or warranty made by the Seller, a consultant of the Seller, an agent of the Seller or any other person other than as expressly set out in this Contract;
(g) it has relied on its own independent investigations and enquiries about the Scheme, the development and the Lot in entering into this Contract;
(h) it has had the opportunity to obtain independent legal, financial, taxation and accounting advice in relation to the Lot and this Contract; and
(i) the Buyer was not introduced to the lot by any person other than the Agent.
38.2 The Buyer agrees that information in brochures, models or other material of any description in connection with the sale of the Lot are indicative only and are not to be relied on or if relied on, the Buyer acknowledges that it elects to do so at its own risk and with full understanding that the Lot and Scheme may vary from the information in those items as represented in any of them, in accordance with the terms of this Contract. Where there is any inconsistency between plans, the sizes, dimensions and measurements on the draft survey plan contained in the Disclosure Statement (as amended from time to time) prevails.
38.3 The Buyer acknowledges and agrees that it has had the opportunity, prior to signing this Contract, to obtain an independent valuation in relation to the Lot and that no representations or warranties about the likely value of the lot at completion has been made by the Seller, a consultant of the Seller, an agent of the Seller.
38.4 The Buyer acknowledges and agrees that it had the opportunity to investigate the Land and the financial viability and/or performance of any investment in the Lot prior to signing this Contract and during the statutory 5 day cooling off period.
REPRESENTATIONS, COVENANTS AND WARRANTIES The Company represents, covenants and warrants as follows:
Representations Complete None of the representations or warranties made by the Company herein or in any Schedule hereto, including the Company Disclosure Schedule, or in any certificate furnished by the Company pursuant to this Agreement, when all such documents are read together in their entirety, contains or will contain upon the consummation of the Offer any untrue statement of a material fact, or omits or will omit upon the consummation of the Offer to state any material fact necessary in order to make the statements contained herein or therein, in the light of the circumstances under which made, not misleading.
Contractor’s Representations and Warranties Contractor represents and warrants that neither the execution of this Agreement by Contractor, nor the acts contemplated hereby, nor compliance by Contractor with any provisions hereof will:
a) Violate any provision of the charter documents of Contractor;
b) Violate any laws, rules, regulations, or any judgment, decree, order, regulation or rule of any court or governmental authority applicable to Contractor; or
c) Violate, or be in conflict with, or constitute a default under, or permit the termination of, or require the consent of any person under, any agreement to which Contractor may be bound, the occurrence of which in the aggregate would have a material adverse effect on the properties, business, prospects, earnings, assets, liabilities, or condition (financial or otherwise) of Contractor.
Vendor Warranties 6.1 The vendor warrants that these general conditions 1 to 35 are identical to the general conditions 1 to 35 in the form of contract of sale of land published by the Law Institute of Victoria Limited and the Real Estate Institute of Victoria Pty Ltd in the month and year set out at the foot of this page.
6.2 The warranties in general conditions 6.3 and 6.4 replace the purchaser’s right to make requisitions and inquiries.
6.3 The vendor warrants that the vendor:
(a) has, or by the due date for settlement will have, the right to sell the land; and
(b) is under no legal disability; and
(c) is in possession of the land, either personally or through a tenant; and
(d) has not previously sold or granted any option to purchase, agreed to lease or granted a pre-emptive right which is current over the land and which gives another party rights which have priority over the interest of the purchaser; and
(e) will at settlement be the holder of an unencumbered estate in fee simple in the land; and
(f) will at settlement be the unencumbered owner of any improvements, fixtures, fittings and goods sold with the land.
6.4 The vendor further warrants that the vendor has no knowledge of any of the following:
(a) public rights of way over the land;
(b) easements over the land;
(c) lease or other possessory agreement affecting the land;
(d) notice or order directly or indirectly affecting the land which will not be dealt with at settlement, other than the usual rate notices and any land tax notices;
(e) legal proceedings which would render the sale of the land void or voidable or capable of being set aside.
6.5 The warranties in general conditions 6.3 and 6.4 are subject to any contrary provisions in this contract and disclosures in the section 32 statement.
6.6 If sections 137B and 137C of the Building Act 1993 apply to this contract, the vendor warrants that:
(a) all domestic building work carried out in relation to the construction by or on behalf of the vendor of the home was carried out in a proper and workmanlike manner; and
(b) all materials used in that domestic building work were good and suitable for the purpose for which they were used and that, unless otherwise stated in the contract, those materials were new; and
(c) domestic building work was carried out in accordance with all laws and legal requirements, including, without limiting the generality of this warranty, the Building Act 1993 and regulations made under the Building Act 1993.
6.7 Words and phrases used in general condition 6.6 which are defined in the Building Act 1993 have the same meaning in general condition 6.6.
Customer Warranties Customer warrants that (i) if an entity, it is duly organized and validly existing in good standing; (ii) it is duly authorized to execute, deliver, and perform its obligations under this Agreement; (iii) when duly executed and delivered by each Party, the Agreement will constitute Customer’s legal, valid, and binding obligation, enforceable against it in accordance with its terms; (iv) it is not insolvent and is paying all of its debts as they become due; (v) any payments made pursuant to the Agreement are intended by it to be a substantially contemporaneous exchange for new value given to it; (vi) each payment made of a debt incurred by it under this Agreement is or was in the ordinary course of its business or financial affairs, and (vii) all information supplied by Customer is complete and accurate.
Customer Warranty Customer’s and its End Users’ use of the Services must always comply with all applicable Laws and this Agreement.
