Inspections; Defective Work Sample Clauses

Inspections; Defective Work. Contractor shall communicate regularly with PM/CM regarding PM/CM’s inspection of completed portions of the Work for conformity with the Specifications and for freedom from defects. Contractor shall accompany PM/CM on such inspections as necessary under the circumstances. In the event that PM/CM notifies Contractor of defective work that: (a) has the potential to have a material impact on the Cost of the Work or the Project Schedule; or(b) indicates a systemic problem (i.e., a persistent, widespread and/or material problem for the Project) with any piece of equipment, any portion of the Work, or the performance of any Major Equipment Supplier or Subcontractor, Contractor shall within 3 Business Days notify and provide relevant information to the Owner. Such information shall include the nature and extent of the problem, the cost and delay associated with the defective Work (if known), and the steps that Contractor and PM/CM are taking to remedy the defective performance, including any remedies that they are pursuing under the applicable contract.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Inspections; Defective Work. 9.1 The Subcontractor shall provide sufficient, safe, and proper facilities at all times, for the inspection of the Work by Terremark, the Architect or their authorized representatives in the field, at shops, or at any other place where materials required thereunder are in the course of preparation, manufacture, treatment, or storage. The Subcontractor shall, within twenty-four hours after receiving written notice from Terremark to that effect, proceed to take down all portions of the Work, and remove from the premises all material, whether worked or unworked, which the Architect or Terremark shall condemn as unsound or improper, or as in any way failing to conform to the Plans and Specifications and the Subcontractor at is own cost and expense shall make good all work damaged or destroyed thereby and replace all materials removed with proper materials.
Sample 1Sample 2
Inspections; Defective Work. MGE Construct shall communicate regularly with PM/CM regarding PM/CM’s inspection of completed portions of the Work for conformity with the Specifications and for freedom from defects. MGE Construct shall accompany PM/CM on such inspections as necessary under the circumstances. In the event that PM/CM notifies MGE Construct of defective work that: (a) has the potential to have a material impact on the Cost of the Work or the Project Schedule; or (b) indicates a systemic problem (i.e., a persistent, widespread and/or material problem for the Project) with any piece of equipment, any portion of the Work, or the performance of any Major Equipment Supplier or Subcontractor, MGE Construct shall within three (3) Business Days notify and provide relevant information to the Owners. Such information shall include the nature and extent of the problem, the cost and delay associated with the defective Work (if known), and the steps that MGE Construct and PM/CM are taking to remedy the defective performance, including any remedies that they are pursuing under the applicable contract.
Sample 1
Inspections; Defective Work. The CONTRACTOR shall communicate regularly with PM/CM regarding PM/CM’s inspection of completed portions of the Work for conformity with the Specifications and for freedom from defects. The CONTRACTOR shall accompany PM/CM on such inspections as necessary under the circumstances.
Sample 1
Inspections; Defective Work. Contractor shall communicate regularly with PM/CM regarding PM/CM’s inspection of completed portions of the Work for conformity with the Specifications and for absence of defects. Contractor shall accompany PM/CM on such inspections, and shall notify Owners’ PCO or other representative so that such representative may also attend such inspections, as necessary under the circumstances. In the event that PM/CM notifies Contractor of defective work that: (a) has the potential to have a material impact on the Cost of the Work or the Project Schedule; or (b) indicates a systemic problem (i.e., a persistent, widespread and/or material problem for the Project) with any piece of equipment, any portion of the Work, or the performance of any Major Equipment Supplier or Subcontractor, Contractor shall within three (3) Business Days notify and provide relevant information to the Owner. Such information shall include the nature and extent of the problem, the cost and delay associated with the defective Work (if known), and the steps that Contractor and PM/CM are taking to remedy the defective performance, including any remedies that they are pursuing under the applicable subcontract.
Sample 1

Related to Inspections; Defective Work

  • Defective Work Work that, for any reason, is not in compliance with the Contract Documents. Defective Work is usually identified in a Notice of Non-Compliant Work.

  • Nonconforming Work 5.6.1 Rejection, Removal and Replacement of Nonconforming Work

  • Latent Defects Notwithstanding anything to the contrary set forth herein, no acceptance, or deemed acceptance, by City pursuant to this Section shall be applicable with respect to any Latent Defects. An acceptance, or deemed acceptance, by City pursuant to this Section shall not mean that City has accepted, or the other party has been relieved of, responsibility for: (i) compliance with the Laws; (ii) the proper application of construction means or methods; or (iii) correcting any portion of the Project if it later is determined that any portion of the Project is inconsistent with the Final Documents and Drawings.

  • Outside Work All work necessary to the assembling, installation, erection, operation, maintenance, repair, control, in- spection and supervision of all electrical apparatus, devices, wires, cables, supports, insulators, conduc- tors, ducts and raceways when part of distributing systems outside of buildings, railroads and outside the directly related railroad property and yards. In- stalling and maintaining the catenary and trolley work on railroad property, and bonding of rails. All underground ducts and cables when they are in- stalled by and are part of the system of a distrib- uting company, except in power stations during new construction, including ducts and cables to adjacent switch racks or substations. All outdoor substations and electrical connections up to and including the setting of transformers and the connecting of the secondary buses thereto. Outside work to include renewable electrical energy sources such as solar photovoltaic, geothermal, wind, biomass, wave, etc., and other distributed en- ergy installations such as fuel cells, microturbines, etc.

  • Creative Work The Executive agrees that all creative work and work product, including but not limited to all technology, business management tools, processes, software, patents, trademarks, and copyrights developed by the Executive during the term of this Agreement, regardless of when or where such work or work product was produced, constitutes work made for hire, all rights of which are owned by the Employer. The Executive hereby assigns to the Employer all rights, title, and interest, whether by way of copyrights, trade secret, trademark, patent, or otherwise, in all such work or work product, regardless of whether the same is subject to protection by patent, trademark, or copyright laws.

  • Warranty Work Failure by the Contractor to take corrective action within twenty four (24) hours after personal or telephonic notice by the County's OC Public Works on items affecting essential use of the facility, safety or the preservation of property, and within ten (10) calendar days following written notice on other deficiencies, will result in the County taking whatever corrective action it deems necessary. All costs resulting from such action by the County will be claimed against Contractor or, if necessary, the Contractor's Performance Bond.

  • Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected. 35.2 Every time notice of a Defect is given, the Contractor shall correct the notified Defect within the length of time specified by the Engineer’s notice.

  • ACCEPTANCE OF DEFECTIVE OR NON-CONFORMING WORK 13.3.1 The State may accept defective or nonconforming Work pursuant to Paragraph 13.2.1

  • REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.

  • Unsafe Work Conditions No Employee shall be disciplined for refusal to work on a job which in the opinion of: (a) A member of a safety committee; or (b) A person designated by a safety committee; or (c) A safety officer after an on-site inspection and following discussion with a representative of the Employer, does not meet the standards established pursuant to the Workers' Compensation Act.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!