Insurance during the Construction Period Sample Clauses

Insurance during the Construction Period. For the Construction Period, the Concessionaire shall effect and maintain, or cause to be effected and maintained, at its own expense, insurance policies as may be required to be maintained by the Lenders, under Applicable Laws and/ or such insurances that are necessary or desirable in accordance with Good Industry Practice.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Insurance during the Construction Period. The Concessionaire shall effect and maintain, or cause to be effected and maintained, at no cost to the Authority during the construction period such insurances up to such maximum sums as may be required under and in accordance with the Financing Documents, Applicable Laws and such insurance as the Concessionaire may reasonably consider necessary or desirable in accordance with Good Industry Practice, which shall include, but not limited to (a) Contractor‟s all risk, including design defect, (ii) Workmen Compensation,
Sample 1
Insurance during the Construction Period. The Concessionaire shall effect and maintain, or cause to be effected and maintained, at no cost to GOTN, HD during the construction period such insurances up to such maximum sums as may be required under and in accordance with the Financing Documents, Applicable Laws and such insurance as the Concessionaire may reasonably consider necessary or desirable in accordance with Good Industry Practice, which shall include, but not limited to (a) Contractor’s all risk, including design defect, (ii) Workmen Compensation, (iii) Construction Plant and Machinery, (iv) Advance Loss of Profits and (v) Third Pary Liability. The Concessionaire shall also effect and maintain such insurance as may be necessary for mitigating the risks that may devolve on GOTN,HD as a consequence of any act of omission by the Concessionaire during the Construction Period
Sample 1
Insurance during the Construction Period. The Concessionaire shall, at its cost and expense, obtain and maintain during the Construction Period such insurances as are customary by a prudent and competent contractor in accordance with Good Industry Practice in comparable projects, including the following: For all the assets constructed/purchased by the Concessionaire including the assets handed over to Concessionaire by the Grantor: (a) contractor’s all risks insurance, owner-controlled; (b) third party liability insurance including property damage and bodily injury to personnel of the Grantor and others who may enter the Concession Area; (c) workmen’s compensation insurance; (d) marine cargo insurance including removal of the wreck of any craft deployed by Concessionaire; and (e) any other insurance (including compulsory insurances in Timor-Leste) that may be necessary to protect the Concessionaire, its employees and its assets including all Force Majeure Events that are insurable and not otherwise covered in items (a) to (d).
Sample 1
Insurance during the Construction Period. The TSP shall effect and maintain or cause to be effected and maintained during the Construction Period, insurance against various risks, with suitable deductibles and with suitable endorsements and co-insured as may be necessary in accordance with Prudent Utility Practices and such insurances as may be required under: a) any of the Financing Agreements, and b) the Laws.
Sample 1
Insurance during the Construction Period. The Concessionaire shall, at its cost and expense, purchase and maintain during the Construction Period such insurances as are customary in comparable projects, including the following: For all the assets constructed/purchased by the Concessionaire including the assets handed over to Concessionaire by the Grantor:
Sample 1
Insurance during the Construction Period. Policies to be taken out by the Private Party and maintained during the Construction Period or up to Scheduled Commencement Date where noted3. Cover: The construction all risk insurance policy issued in respect of any construction Works (the "CAR policy") will provide protection against loss of/or destruction or damage to the relevant construction Works. The CAR policy cover shall include London Engineering Group 3 – Defective Design Improvement exlusion (LEG3, 2006) clause or similar wording which shall cover the costs necessary to replace, repair or rectify any physical damage due to a defect in design, plan, specification, materials or workmanship but exclude the cost of improvements associated with such defect Perils will be on an all risks basis to cover loss or damage from any cause including, without limitation, fire, lightning, explosion, xxxxx, xxxxxxx, flood, earthquake, transit and off site storage4.
Sample 1
AutoNDA by SimpleDocs
Insurance during the Construction Period. The Concessionaire shall effect and maintain, or cause to be effected and maintained, at no cost to MPRDC during the Construction Period such insurance up to such maximum sums as may be required under and in accordance with the Financing Documents, Applicable Laws and such insurance to cover the entire cost incurred on the project as is considered necessary by MPRDC in accordance with Good Industry Practice.. The Concessionaire shall also include insurance of all insurable Force Majeure events as defined in Clause 28. The Concessionaire shall also effect and maintain such insurance as may be necessary for mitigating the risks that may devolve on MPRDC as a consequence of any act of omission by the Concessionaire during the Construction Period.
Sample 1

Related to Insurance during the Construction Period

  • Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic. (ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.

  • Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.

  • Remedies; Obtaining the Collateral Upon Default Each Assignor agrees that, if any Event of Default shall have occurred and be continuing, then and in every such case, the Collateral Agent, in addition to any rights now or hereafter existing under applicable law, shall have all rights as a secured creditor under the Uniform Commercial Code in all relevant jurisdictions and may: (i) personally, or by agents or attorneys, immediately take possession of the Collateral or any part thereof, from such Assignor or any other Person who then has possession of any part thereof with or without notice or process of law, and for that purpose may enter upon such Assignor's premises where any of the Collateral is located and remove the same and use in connection with such removal any and all services, supplies, aids and other facilities of such Assignor; (ii) instruct the obligor or obligors on any agreement, instrument or other obligation (including, without limitation, the Receivables and the Contracts) constituting the Collateral to make any payment required by the terms of such agreement, instrument or other obligation directly to the Collateral Agent; (iii) withdraw all monies, securities and instruments in the Cash Collateral Account for application to the Obligations in accordance with Section 7.4 hereof; (iv) sell, assign or otherwise liquidate any or all of the Collateral or any part thereof in accordance with Section 7.2 hereof, or direct the relevant Assignor to sell, assign or otherwise liquidate any or all of the Collateral or any part thereof, and, in each case, take possession of the proceeds of any such sale or liquidation; (v) take possession of the Collateral or any part thereof, by directing the relevant Assignor in writing to deliver the same to the Collateral Agent at any place or places designated by the Collateral Agent, in which event such Assignor shall at its own expense:

  • Allocations During the Controlled Accumulation Period During the Controlled Accumulation Period (A) an amount equal to the product of (I) the sum of the Class B Principal Percentage and the Collateral Principal Percentage and (II) the Principal Allocation Percentage and (III) the Series 1997-1 Allocation Percentage and (IV) the aggregate amount of Collections of Principal Receivables deposited in the Collection Account on such Deposit Date, shall be allocated to the Series 1997-1 Certificateholders and retained in the Collection Account until applied as provided herein and (B) an amount equal to the product of (I) the Class A Principal Percentage and (II) the Principal Allocation Percentage and (III) the Series 1997-1 Allocation Percentage and (IV) the aggregate amount of Collections of Principal Receivables deposited in the Collection Account on such Deposit Date (such product for any such date, a "Percentage Allocation") shall be allocated to the Series 1997-1 Certificateholders and retained in the Collection Account until applied as provided herein; provided, however, that if the sum of such Percentage Allocation and all preceding Percentage Allocations with respect to the same Monthly Period exceeds the Controlled Deposit Amount for the related Distribution Date, then such excess shall not be treated as a Percentage Allocation and shall be first, if any other Principal Sharing Series is outstanding and in its amortization period or accumulation period, retained in the Collection Account for application, to the extent necessary, as Shared Principal Collections on the related Distribution Date, and second paid to the Holders of the Transferor Certificates only if the Transferor Amount on such Deposit Date is greater than the Required Transferor Amount (after giving effect to all Principal Receivables transferred to the Trust on such day) and otherwise shall be deposited in the Special Funding Account.

  • TERM OF THE CONTRACT This Contract begins on 07/01/2015 and ends on 06/30/2016. DSHS has the option, in its sole discretion, to renew the Contract. DSHS is not responsible for payment under this Contract before both parties have signed the Contract or before the start date of the Contract, whichever is later.

  • During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Partial Disposal During Term of Service Agreement Throughout the Term of the Service Agreement, LEA may request partial disposal of Student Data obtained under the Service Agreement that is no longer needed. Partial disposal of data shall be subject to LEA’s request to transfer data to a separate account, pursuant to Article II, section 3, above.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!